The responsibility of the contractor for project deficiencies

Directory of Open Access Journals (Sweden)

Pušac Jovana

2011-01-01

Full Text Available In this paper the author analyzes a civil law responsibility of the Contractor for project deficiencies resulting in reduced quality of the construction, i.e. not affecting its solidity. Primary obligation of the Contractor is to perform works in compliance with professional standards, the contract and the approved project. The Contractor cannot change the approved project at will, even when he has designed it. Hence, the question must be raised of the obligation of the Contractor to strictly abide by the project, assigned to him by the Authority, regardless of evident deficiencies of the Project and of his responsibility for performing works in compliance with the said project resulting in deficiencies in the construction, that is construction works. If the latter hypothesis is correct, then it must be established what deficiencies in the project fall under the responsibility of the Contractor (visible or hidden, i.e. the issue of dividing responsibility between the Project Designer and the Contractor in terms of the project deficiencies must be set up and solved. Finally, it is also important to define the realization of rights and duties of the Contractor in case the Contractor has to recede from the Project. In this paper the author tries to offer detail and complete answers to raised questions.

Contractor safety

International Nuclear Information System (INIS)

Blanton, M.L.; Montgomery, E.W.

1991-01-01

The recent trend in the United States and Shell Oil Company EandP has been to increase use of contractors to do specialized work. Many companies now use contractors almost exclusively for operations such as drilling, well workovers, construction, and many specialty and routine maintenance tasks. Today, approximately 75% of Shell Oil Company's actual operating work force in EandP is contract. Clearly, HSandE considerations must become an increasingly important part of the contractor selection process. This paper reports on the Shell Oil Company's evolution from a bidder selection process to a program of Matching Owner and Contractor. Well has begun to expand efforts to make better assessments of contractor's HSandE capabilities and values in pre-bid considerations. Focus is on pre-bid evaluations to select contractors that have strong HSandE commitments and values. Contractor safety performance in this industry must be brought up to the same standards as operating companies. In Shell Oil EandP is only willing to contractors who can and are willing to do that

75 FR 42164 - Notice of Final Determination Updating the List of Products Requiring Federal Contractor...

Science.gov (United States)

2010-07-20

... List of Products Requiring Federal Contractor Certification as to Forced or Indentured Child Labor... Guidelines for Maintenance of the List of Products Requiring Federal Contractor Certification as to Forced or.... 13126 (``Prohibition of Acquisition of Products Produced by Forced or Indentured Child Labor''), in...

Contractor management

NARCIS (Netherlands)

Ustailieva, E.; Starren, A.

2013-01-01

Companies function more and more in networks (i.e. contractor chains with contractors, suppliers and/or other companies. This asks for several companies/parties to work together to get the work done. Working in contractor chains is very common in sectors like maintenance, construction, cleaning, and

77 FR 35883 - Defense Federal Acquisition Regulation Supplement; Contractors Performing Private Security...

Science.gov (United States)

2012-06-15

.... The essence of the definition cannot be changed substantially in the DFARS from that in the... recommended that the final rule define the contractor's obligation to cooperate, as in the mandatory... define the scope and limitations of the contractor's obligation to cooperate with Government...

Optimal Contractor Selection in Construction Industry: The Fuzzy Way

Science.gov (United States)

Krishna Rao, M. V.; Kumar, V. S. S.; Rathish Kumar, P.

2018-02-01

A purely price-based approach to contractor selection has been identified as the root cause for many serious project delivery problems. Therefore, the capability of the contractor to execute the project should be evaluated using a multiple set of selection criteria including reputation, past performance, performance potential, financial soundness and other project specific criteria. An industry-wide questionnaire survey was conducted with the objective of identifying the important criteria for adoption in the selection process. In this work, a fuzzy set based model was developed for contractor prequalification/evaluation, by using effective criteria obtained from the percept of construction professionals, taking subjective judgments of decision makers also into consideration. A case study consisting of four alternatives (contractors in the present case) solicited from a public works department of Pondicherry in India, is used to illustrate the effectiveness of the proposed approach. The final selection of contractor is made based on the integrated score or Overall Evaluation Score of the decision alternative in prequalification as well as bid evaluation stages.

48 CFR 252.229-7004 - Status of contractors as a direct contractor (Spain).

Science.gov (United States)

2010-10-01

... direct contractor (Spain). 252.229-7004 Section 252.229-7004 Federal Acquisition Regulations System... contractor (Spain). As prescribed in 229.402-70(d), use the following clause: Status of Contractor as a Director Contractor (Spain) (JUN 1997) (a) “Direct Contractor,” as used in this clause, means an individual...

DOE contractor radiation safety CBT [computer based training] course

International Nuclear Information System (INIS)

Gardner, P.R.

1986-01-01

Westinghouse Hanford Company developed a generic Radiation Worker safety CBT course for Department of Energy contractors. Task analysis concentrated on actual and potential tasks and included visits to fourteen different contractor sites. Team Design and Prototype verification formed the major portion of the development phase. Lesson entry was accomplished using the WISE author system from WICAT Systems, Inc. The course features graded task simulations for both Pretest and Final; fourteen Topics in five Lessons, each Topic keyed to ''Critical Acts'' and Questions in the Pretest and Final; Automatic, Intensive, and Manual modes of instruction available for each Lesson; Practical Problems and Sample Questions associated with each Topic; and provisions for local configuration in several areas. The course is deliverable on IBM PC compatible equipment. 2 refs

From demand driven contractor selection towards value driven contractor selection

NARCIS (Netherlands)

Walraven, A.R.; Vries, de B.

2009-01-01

The procurement of a construction contractor should consider more aspects than only cost or price. Taking value and price into account to select the ‘best value for money’ bid results in adopting a structured multicriteria approach. An alternative contractor selection method is presented, which

Strategic management competencies in Scandinavian contractors

DEFF Research Database (Denmark)

Koch, Christian; Buhl, Henrik

2013-01-01

Over the past ten years, a series of contractors operating in Denmark, Norway and Sweden have slowly but surely expanded their markets beyond their previous single-country base towards operating in Scandinavia as a whole, and beyond. This expansion has been accompanied by a restructuring of company...... management and HR concepts and approaches. Methodologically, a sample of the top level leaders of the hundred largest business units at some thirty Scandinavian contractors has been analysed. The focus is on the 400 top level managers in these organisations. On the basis of a desk study, an analysis of 124...

48 CFR 46.105 - Contractor responsibilities.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor... CONTRACT MANAGEMENT QUALITY ASSURANCE General 46.105 Contractor responsibilities. (a) The contractor is..., and furnishing such information to the Government as required. (b) The contractor may be required to...

49 CFR 199.245 - Contractor employees.

Science.gov (United States)

2010-10-01

... 49 Transportation 3 2010-10-01 2010-10-01 false Contractor employees. 199.245 Section 199.245... Prevention Program § 199.245 Contractor employees. (a) With respect to those covered employees who are contractors or employed by a contractor, an operator may provide by contract that the alcohol testing...

49 CFR 199.115 - Contractor employees.

Science.gov (United States)

2010-10-01

... 49 Transportation 3 2010-10-01 2010-10-01 false Contractor employees. 199.115 Section 199.115... § 199.115 Contractor employees. With respect to those employees who are contractors or employed by a contractor, an operator may provide by contract that the drug testing, education, and training required by...

7 CFR 1726.27 - Contractor's bonds.

Science.gov (United States)

2010-01-01

... 7 Agriculture 11 2010-01-01 2010-01-01 false Contractor's bonds. 1726.27 Section 1726.27... AGRICULTURE ELECTRIC SYSTEM CONSTRUCTION POLICIES AND PROCEDURES General § 1726.27 Contractor's bonds. (a) RUS Form 168b, Contractor's Bond, shall be used when a contractor's bond is required by RUS Forms 200, 257...

48 CFR 47.207-5 - Contractor responsibilities.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor....207-5 Contractor responsibilities. Contractor responsibilities vary with the kinds of freight to be... furnished by the contractor. Otherwise, state that the contractor shall furnish clean and sound closed-type...

48 CFR 18.102 - Central contractor registration.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Central contractor... Central contractor registration. Contractors are not required to be registered in the Central Contractor.... (See 4.1102). However, contractors are required to register with CCR in order to gain access to the...

48 CFR 1845.502 - Contractor responsibility.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor responsibility. 1845.502 Section 1845.502 Federal Acquisition Regulations System NATIONAL AERONAUTICS AND SPACE... Contractors 1845.502 Contractor responsibility. ...

Workplace immersion in the final year of an undergraduate medicine course: the views of final year students and recent graduates.

Science.gov (United States)

Sen Gupta, Tarun; Hays, Richard; Woolley, Torres; Kelly, Gill; Jacobs, Harry

2014-06-01

Most medical schools require formal competence assessment of students immediately prior to graduation, but variation exists in the approach to endpoint assessments. This article reports perceptions of senior students and graduates from a school with a six-year program which has introduced final year workplace immersion placements following a barrier examination at the end of the penultimate Year 5. Final year students (22) and recent graduates (4) attended focus groups and in-depth interviews exploring their perceptions of the value of the curriculum experience during the final two years, the structure and timing of assessment, and their preparation for internship. Participants felt that the penultimate year was more pressured, and focused on passing "artificial" examinations. In contrast, the final year was more relaxed, building skills for postgraduate work and later career development. As a result, students felt well prepared for internship with some indication that the self-directed nature of the final year promoted a lifelong learning approach. The final year workplace immersion model was regarded positively by senior students of this medical school. This model may be a better way of preparing students to be junior doctors than a traditional final year heavy on theoretical learning and assessment.

48 CFR 1609.471 - Contractor certification.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor certification... EMPLOYEES HEALTH BENEFITS ACQUISITION REGULATION ACQUISITION PLANNING CONTRACTOR QUALIFICATIONS Debarment, Suspension, and Ineligibility 1609.471 Contractor certification. All FEHBP carriers and applicant carriers...

48 CFR 1602.170-4 - Contractor.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor. 1602.170-4 Section 1602.170-4 Federal Acquisition Regulations System OFFICE OF PERSONNEL MANAGEMENT FEDERAL EMPLOYEES... 1602.170-4 Contractor. Contractor means carrier. ...

48 CFR 752.7013 - Contractor-mission relationships.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor-mission....7013 Contractor-mission relationships. For use in all USAID contracts involving performance overseas.... Contractor-Mission Relationships (OCT 1989) (a) The Contractor acknowledges that this contract is an...

30 CFR 45.4 - Independent contractor register.

Science.gov (United States)

2010-07-01

... 30 Mineral Resources 1 2010-07-01 2010-07-01 false Independent contractor register. 45.4 Section... ADMINISTRATIVE REQUIREMENTS INDEPENDENT CONTRACTORS § 45.4 Independent contractor register. (a) Each independent contractor shall provide the production-operator in writing the following information: (1) The independent...

48 CFR 852.237-70 - Contractor responsibilities.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor....237-70 Contractor responsibilities. As prescribed in 837.110, insert the following clause: Contractor Responsibilities (APR 1984) The contractor shall obtain all necessary licenses and/or permits required to perform...

Operator/contractor teamwork is the key to performance improvement

International Nuclear Information System (INIS)

Robins, K.B.; Roberts, J.D.M.

1996-01-01

The contract strategies developed by the two major E and P companies operating in the North Sea emphasize teamwork between operator and contractors to achieve the common goal of maximizing project value. These strategies have had significant repercussions across the whole industry. This paper compares these strategies and concludes that although they are structurally different, they have the same fundamental objectives. It describes the evolution of what these operators consider to be their core business, with the resultant changing roles for both operator and contractor staff. Several examples of results achieved through implementing these changes are described, highlighting the need for a structured performance measurement system to quantify the success of these initiatives. Finally, the potential for even greater efficiency improvements through further industry-wide cooperation is emphasized

48 CFR 52.241-5 - Contractor's Facilities.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Contractor's Facilities....241-5 Contractor's Facilities. As prescribed in 41.501(c)(4), insert a clause substantially the same as the following: Contractor's Facilities (FEB 1995) (a) The Contractor, at its expense, unless...

48 CFR 52.247-28 - Contractor's Invoices.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Contractor's Invoices. 52....247-28 Contractor's Invoices. As prescribed in 47.207-9(c), insert the following clause in... services: Contractor's Invoices (APR 1984) The Contractor shall submit itemized invoices as instructed by...

14 CFR 1245.108 - License to contractor.

Science.gov (United States)

2010-01-01

... 14 Aeronautics and Space 5 2010-01-01 2010-01-01 false License to contractor. 1245.108 Section... INTELLECTUAL PROPERTY RIGHTS Patent Waiver Regulations § 1245.108 License to contractor. (a) Each contractor.... The license extends to the contractor's domestic subsidiaries and affiliates, if any, within the...

48 CFR 725.703 - Contractor employees.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor employees. 725... SOCIOECONOMIC PROGRAMS FOREIGN ACQUISITION Source, Origin, and Nationality 725.703 Contractor employees. (a... on employees or consultants of either contractors or subcontractors providing services under an USAID...

48 CFR 33.207 - Contractor certification.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor certification... CONTRACTING REQUIREMENTS PROTESTS, DISPUTES, AND APPEALS Disputes and Appeals 33.207 Contractor certification. (a) Contractors shall provide the certification specified in paragraph (c) of this section when...

48 CFR 1845.502-70 - Contractor-acquired property.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor-acquired... Possession of Contractors 1845.502-70 Contractor-acquired property. All contractor-acquired property must be... contractor-acquired. (2) Submission of DD Form 1419, DOD Industrial Plant Requisition, or equivalent format...

Radiation exposures for DOE and DOE contractor employees, 1989

International Nuclear Information System (INIS)

Smith, M.H.; Eschbach, P.A.; Harty, R.; Millet, W.H.; Scholes, V.A.

1992-12-01

All US Department of Energy (DOE) and DOE contractors, are required to submit occupational radiation exposure records to a central depository. In 1989, data were required to be submitted for all employees who were required to be monitored in accordance with DOE Order 5480.11 and for all visitors who had a positive exposure. The data required included the external penetrating whole-body dose equivalent, the shallow dose equivalent, and a summary of internal depositions of radioactive material above specified limits. Data regarding the exposed individuals included the individual's age, sex, and occupational category. This report is a summary of the external penetrating whole-body dose equivalents and shallow dose equivalents reported by DOE and DOE contractors for the calendar year 1989. A total of 90,882 DOE and DOE contractor employees were reported to have been monitored for whole-body ionizing radiation exposure during 1989. This represents 53.6% of all DOE and DOE contractor employees and is an increase (4.3 %) from the number of monitored employees for 1988. In addition to the employees, 12,643 visitors were monitored

48 CFR 1252.242-71 - Contractor testimony.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor testimony. 1252... Contractor testimony. As prescribed in (TAR) 48 CFR 1242.7000(b), insert the following clause: Contractor Testimony (OCT 1994) All requests for the testimony of the Contractor or its employees, and any intention to...

40 CFR 35.6600 - Contractor claims.

Science.gov (United States)

2010-07-01

... 40 Protection of Environment 1 2010-07-01 2010-07-01 false Contractor claims. 35.6600 Section 35... Actions Procurement Requirements Under A Cooperative Agreement § 35.6600 Contractor claims. (a) General... prepared by the contractor to support a claim against the recipient; and (4) The award official determines...

Financial Reporting by Selected Defense Agencies of Government Property in the Custody of Contractors

National Research Council Canada - National Science Library

1997-01-01

... over the $92 billion of Government property in the custody of contractors. After several years of planning, DoD has not developed a standard accounting system for recording, tracking, and reporting Government property in the custody of contractors...

29 CFR 500.41 - Farm labor contractor is responsible for actions of his farm labor contractor employee.

Science.gov (United States)

2010-07-01

..., prior to such employee's engagement in any activity enumerated in section 3(6) of the Act. A farm labor... farm labor contractor employee. 500.41 Section 500.41 Labor Regulations Relating to Labor (Continued... PROTECTION Registration of Farm Labor Contractors and Employees of Farm Labor Contractors Engaged in Farm...

Contractor Performance Assessment Reporting System

Data.gov (United States)

US Agency for International Development — CPARS is a web-based system used to input data on contractor performance. Reports from the system are used as an aid in awarding contracts to contractors that...

48 CFR 970.4402 - Contractor purchasing system.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor purchasing... SUPPLEMENTARY REGULATIONS DOE MANAGEMENT AND OPERATING CONTRACTS Management and Operating Contractor Purchasing 970.4402 Contractor purchasing system. ...

Hydrogen Contractors Meeting

Energy Technology Data Exchange (ETDEWEB)

Fitzsimmons, Tim [Dept. of Energy (DOE), Washington DC (United States). Office of Basic Energy Sciences. Division of Materials Sciences and Engineering

2006-05-16

This volume highlights the scientific content of the 2006 Hydrogen Contractors Meeting sponsored by the Division of Materials Sciences and Engineering (DMS&E) on behalf of the Office of Basic Energy Sciences (BES) of the U. S. Department of Energy (DOE). Hydrogen Contractors Meeting held from May 16-19, 2006 at the Crystal Gateway Marriott Hotel Arlington, Virginia. This meeting is the second in a series of research theme-based Contractors Meetings sponsored by DMS&E held in conjunction with our counterparts in the Office of Energy Efficiency and Renewable Energy (EERE) and the first with the Hydrogen, Fuel Cells and Infrastructure Technologies Program. The focus of this year’s meeting is BES funded fundamental research underpinning advancement of hydrogen storage. The major goals of these research efforts are the development of a fundamental scientific base in terms of new concepts, theories and computational tools; new characterization capabilities; and new materials that could be used or mimicked in advancing capabilities for hydrogen storage.

Cross-national research on contractor evaluation procedures in public works procurement

Science.gov (United States)

Kinoshita, Seiya; Sato, Naoyoshi; Matsumoto, Naoya

Contractor evaluation methods in Japan's public works procurement, beginning with construction business licensure, going through biennial preliminary firm rating, up to project-by-project prequalification and comprehensive point rating, were developed during the period when public works were mostly procured through designated competitive bidding. It is essential to focus attention on contractor evaluation methods for introducing different types of procurement procedures which enhance the use of technological capabilities held by private businesses. An overall review of contractor evaluation procedures should be conducted in view of the present situation, where the open competitive bidding has become mainly used in combination with comprehensive evaluation, as well as to allow for further diversification of procurement methods. In Western countries, improvements have been made for the past several years in contractor evaluation procedures with more emphasis on "Value for Money." Advanced efforts made by these countries will be useful as a reference for overhauling Japan's contractor evaluation system. This study conducts a comparative review of contractor evaluation procedures for public procurement in Western countries such as the United States, the United Kingdom and France by identifying similarities and differences between those of Japan and the above mentioned countries. This reveals that a contractor's technical or professional ability is looked at separately from its economic and financial standing in those countries studied, and there is no case like Japan in which those two factors are integrated into one for evaluation.

Building America Expert Meeting Report: Transitioning Traditional HVAC Contractors to Whole House Performance Contractors

Energy Technology Data Exchange (ETDEWEB)

Burdick, A.

2011-10-01

This report outlines findings resulting from a U.S. Department of Energy Building America expert meeting to determine how HVAC companies can transition from a traditional contractor status to a service provider for whole house energy upgrade contracting. IBACOS has embarked upon a research effort under the Building America Program to understand business impacts and change management strategies for HVAC companies. HVAC companies can implement these strategies in order to quickly transition from a 'traditional' heating and cooling contractor to a service provider for whole house energy upgrade contracting. Due to HVAC service contracts, which allow repeat interaction with homeowners, HVAC companies are ideally positioned in the marketplace to resolve homeowner comfort issues through whole house energy upgrades. There are essentially two primary ways to define the routes of transition for an HVAC contractor taking on whole house performance contracting: (1) Sub-contracting out the shell repair/upgrade work; and (2) Integrating the shell repair/upgrade work into their existing business. IBACOS held an Expert Meeting on the topic of Transitioning Traditional HVAC Contractors to Whole House Performance Contractors on March 29, 2011 in San Francisco, CA. The major objectives of the meeting were to: Review and validate the general business models for traditional HVAC companies and whole house energy upgrade companies Review preliminary findings on the differences between the structure of traditional HVAC Companies and whole house energy upgrade companies Seek industry input on how to structure information so it is relevant and useful for traditional HVAC contractors who are transitioning to becoming whole house energy upgrade contractors Seven industry experts identified by IBACOS participated in the session along with one representative from the National Renewable Energy Laboratory (NREL). The objective of the meeting was to validate the general operational

Risk analysis in the management of urban construction projects from the perspective of the employer and the contractor

Directory of Open Access Journals (Sweden)

Mohammad Taghipour

2015-12-01

Full Text Available Imbalance between anticipated and actual progress in the development of urban construction projects suggests that there are many obstacles and risks which not only causes the urban management be unsustainable, but the reconstruction and development of urban space is also seriously threatened. In this study, the library research on issues related to the risk of construction projects was done, then some interviews were conducted with experts and managers informed and involved in the projects, and finally questionnaires were distributed to identify and classify the impact of the risks of the implementation of the construction projects. After analyzing the data, the results indicated that the experts listed the most significant risks as the delays in the payment of contractors' claims and statements due to the lack of handling financial instruments, the governance of relationships rather than rules in the tenders resulting from employer actions, low commitment to the quality of work provided by their subcontractors, failure to complete the detail engineering by foreign contractors on time, weaknesses in contractors' financial resources, and offering lower prices than reasonable by contractors to win the tender. All of these require special attention and other kinds of risks are important at the next level. Finally, the solutions for eliminating or reducing risks in high-risk areas have been offered to provide tranquility for contractors and employers.

Locational Factors and Foreign Market-entry Considerations for Malaysian Contractors

Directory of Open Access Journals (Sweden)

A.R Abdul_Aziz

2012-11-01

Full Text Available Past studies on contractor internationalisation adopt a unimodelapproach. Taking up the call of a few scholars, a study isconducted, this time by integrating several extant models of fi rminternationalisation. Malaysian international contractors are usedto test this approach. Due to space limitation, this paper is focusedonly on locational factors. It begins by justifying the inclusion oflocational factors in a multi-model approach. Then it posits thatlocational disadvantage is a more intellectually appealing conceptthan locational advantages. Empirically, it shows that the surveyedcontractors evaluate a wide range of factors before making thego/no go decision to enter foreign markets. It also shows thatpsychic distance was not their major concern. Finally, the locationaldisadvantages create a market space for international contractorswith the tenacity to overcome them, which the sampled populationpossessed.

48 CFR 52.246-1 - Contractor Inspection Requirements.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Contractor Inspection....246-1 Contractor Inspection Requirements. As prescribed in 46.301, insert the following clause: Contractor Inspection Requirements (APR 1984) The Contractor is responsible for performing or having...

48 CFR 970.5244-1 - Contractor purchasing system.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor purchasing... for Management and Operating Contracts 970.5244-1 Contractor purchasing system. As prescribed in 970.4403 insert the following clause: Contractor Purchasing System (AUG 2009) (a) General. The Contractor...

48 CFR 52.204-7 - Central Contractor Registration.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Central Contractor....204-7 Central Contractor Registration. As prescribed in 4.1105, use the following clause: Central Contractor Registration (APR 2008) (a) Definitions. As used in this clause— Central Contractor Registration...

Environmental liability and the independent contractor

International Nuclear Information System (INIS)

Gilmour, B.S.

1999-01-01

The provisions of the Environmental Protection and Enhancement Act (EPEA) regarding the relationship between a company and an independent contractor were reviewed. The EPEA was introduced in September 1993 and significantly altered the environmental laws in the province of Alberta. The provisions of the EPEA that apply to the petroleum industry are conservation and reclamation as well as provisions concerning release of substances, contaminated sites and penalties. Companies that pollute may be held liable for reclamation, even if the work was carried out by an independent contractor and despite the fact that the independent contractor is not an employee of the company. Under the current EPEA laws, companies may not be able to effectively shift responsibility for environmental liabilities to independent contractors even where the contractor was negligent. This paper presented suggestions regarding contractor agreements and due diligence to help minimize the risk of liability to companies. The paper also discussed the following two types of liabilities under the EPEA's harmful substances section: (1) the obligation to clean up an affected area, and (2) fines and penalties that may be imposed when an offence is committed

48 CFR 1552.237-76 - Government-Contractor Relations.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Government-Contractor... 1552.237-76 Government-Contractor Relations. As prescribed in 1537.110(g), insert the following clause: Government-Contractor Relations (JUN 1999) (a) The Government and the Contractor understand and agree that...

40 CFR 68.87 - Contractors.

Science.gov (United States)

2010-07-01

... Protection of Environment ENVIRONMENTAL PROTECTION AGENCY (CONTINUED) AIR PROGRAMS (CONTINUED) CHEMICAL ACCIDENT PREVENTION PROVISIONS Program 3 Prevention Program § 68.87 Contractors. (a) Application. This... specialty work on or adjacent to a covered process. It does not apply to contractors providing incidental...

48 CFR 46.301 - Contractor inspection requirements.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor inspection... CONTRACT MANAGEMENT QUALITY ASSURANCE Contract Clauses 46.301 Contractor inspection requirements. The contracting officer shall insert the clause at 52.246-1, Contractor Inspection Requirements, in solicitations...

48 CFR 970.5203-3 - Contractor's organization.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor's organization... for Management and Operating Contracts 970.5203-3 Contractor's organization. As prescribed in 970.0371-9, insert the following clause: Contractor's Organization (DEC 2000) (a) Organization chart. As...

48 CFR 450.303-1 - Contractor requests.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 4 2010-10-01 2010-10-01 false Contractor requests. 450.303-1 Section 450.303-1 Federal Acquisition Regulations System DEPARTMENT OF AGRICULTURE CONTRACT MANAGEMENT EXTRAORDINARY CONTRACTUAL ACTIONS Contract Adjustments 450.303-1 Contractor requests. Contractor...

Proceedings of the fuels technology contractors review meeting

Energy Technology Data Exchange (ETDEWEB)

Malone, R.D. [ed.

1993-11-01

The Fuels Technology Contractors Review Meeting was held November 16-18, 1993, at the Morgantown Energy Technology Center (METC) in Morgantown, West Virginia. This meeting was sponsored and hosted by METC, the Office of Fossil Energy, U.S. Department of Energy (DOE). METC periodically provides an opportunity to bring together all of the R&D participants in a DOE-sponsored contractors review meeting to present key results of their research and to provide technology transfer to the active research community and to the interested public. This meeting was previously called the Natural Gas Technology Contractors Review Meeting. This year it was expanded to include DOE-sponsored research on oil shale and tar sands and so was retitled the Fuels Technology Contractors Review Meeting. Current research activities include efforts in both natural gas and liquid fuels. The natural gas portion of the meeting included discussions of results summarizing work being conducted in fracture systems, both natural and induced; drilling, completion, and stimulation research; resource characterization; delivery and storage; gas to liquids research; and environmental issues. The meeting also included project and technology summaries on research in oil shale, tar sands, and mild coal gasification, and summaries of work in natural-gas fuel cells and natural-gas turbines. The format included oral and poster session presentations. Individual papers have been processed separately for inclusion in the Energy Science and Technology database.

48 CFR 2427.305-2 - Follow-up by contractor.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Follow-up by contractor....305-2 Follow-up by contractor. (b) Contractor reports. Contractors shall complete and submit to the... Contracting Officer shall send the form to those contractors whose contract work may have required the...

Inclusion survey contractor implementation plan for fiscal years 1986-1988

Energy Technology Data Exchange (ETDEWEB)

Espegren, M.L.; Carter, T.E.; Little, C.A.; Ramos, S.J.

1987-03-01

The Radiological Surveys Activities Group (RASA) of Oak Ridge National Laboratory acts as the Inclusion Survey Contractor (ISC) to the Uranium Mill Tailings Remedial Action (UMTRA) Project of the US Department of Energy (DOE). The ISC investigates properties to determine whether the properties qualify for remedial action according to the standards set forth for the UMTRA Project by the US Environmental Protection Agency. The major work elements making up the ISC's activities are: consent form acquisition, land survey/drawing, inclusion survey, post-survey activities, survey report, file transmittal, and recommendation for a vicinity property to be included into or excluded from UMTRAP. The ISC will produce 2960 recommendations in FY 1988 for $3.98M.

Inclusion survey contractor implementation plan for fiscal years 1986-1988

International Nuclear Information System (INIS)

Espegren, M.L.; Carter, T.E.; Little, C.A.; Ramos, S.J.

1987-03-01

The Radiological Surveys Activities Group (RASA) of Oak Ridge National Laboratory acts as the Inclusion Survey Contractor (ISC) to the Uranium Mill Tailings Remedial Action (UMTRA) Project of the US Department of Energy (DOE). The ISC investigates properties to determine whether the properties qualify for remedial action according to the standards set forth for the UMTRA Project by the US Environmental Protection Agency. The major work elements making up the ISC's activities are: consent form acquisition, land survey/drawing, inclusion survey, post-survey activities, survey report, file transmittal, and recommendation for a vicinity property to be included into or excluded from UMTRAP. The ISC will produce 2960 recommendations in FY 1988 for $3.98M

32 CFR 989.23 - Contractor prepared documents.

Science.gov (United States)

2010-07-01

... 32 National Defense 6 2010-07-01 2010-07-01 false Contractor prepared documents. 989.23 Section... PROTECTION ENVIRONMENTAL IMPACT ANALYSIS PROCESS (EIAP) § 989.23 Contractor prepared documents. All Air Force... should reflect on the cover sheet they are an Air Force document. Contractor preparation information...

6 CFR 25.8 - Government contractor Defense.

Science.gov (United States)

2010-01-01

... 6 Domestic Security 1 2010-01-01 2010-01-01 false Government contractor Defense. 25.8 Section 25.8...-TERRORISM BY FOSTERING EFFECTIVE TECHNOLOGIES § 25.8 Government contractor Defense. (a) Criteria for... applicability of the government contractor defense. In determining whether to issue such Certification, the...

42 CFR 455.202 - Limitation on contractor liability.

Science.gov (United States)

2010-10-01

... 42 Public Health 4 2010-10-01 2010-10-01 false Limitation on contractor liability. 455.202 Section... § 455.202 Limitation on contractor liability. (a) A program contractor, a person, or an entity employed... contractor will not be held to have violated any criminal law and will not be held liable in any civil action...

48 CFR 32.605 - Final decisions.

Science.gov (United States)

2010-10-01

... REQUIREMENTS CONTRACT FINANCING Contract Debts 32.605 Final decisions. (a) The contracting officer shall issue a final decision as required by 33.211 if— (1) The contracting officer and the contractor are unable... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Final decisions. 32.605...

78 FR 58613 - Affirmative Action and Nondiscrimination Obligations of Contractors and Subcontractors Regarding...

Science.gov (United States)

2013-09-24

... societal problems such as income inequality and poverty. The final rule is intended to provide contractors... Accommodations: Low Cost, High Impact,'' Sept. 1, 2012. Accommodation and Compliance Series, http://askjan.org... resulting from lower staff turnover.\\16\\ According to the U.S. Business Leadership Network (USBLN...

Operator/contractor relationships

International Nuclear Information System (INIS)

Smith, J.R.; Kidwell, C.K.; Unger, V.E.; Fercho, E.; Helmer, C.M.

1992-01-01

In May 1988, Shell Western E and P Inc. (SWEPI) and partners Elf Aquitaine Petroleum and Conoco Inc. signed a letter of intent with Canadian Marine Drilling Ltd. (Canmar) for provision of exploratory drilling and marine services on leases in OCS Lease Sale 109 in the Chukchi Sea, Alaska. The 5450 blocks offered in the remote sale area west of Point Barrow ranged from 3 to 240 miles (5 to 380 km) offshore in water depths from 26 to 263 feet (8 to 80 m). The principal interest tracts were at least 75 miles (120 km) offshore and north of 70 degrees N latitude. The remoteness and total lack of any oilfield infrastructure required considerable planning and coordination between Operator and Contractor in order to carry out the three-year drilling program efficiently and safely in an environmentally harsh and, at the same time, sensitive area. SWEPI and Canmar developed a close working relationship from the start of the project through a number of participative approaches to the problems that had to be solved. This paper reports that these included strong reliance on operational planning meetings, post-season analyses, and an overall emphasis on the teamwork required of both parties to carry out the first-ever drilling program in the Chukchi Sea. This approach led to a very successful operation for both parties and emphasizes the positive benefits achievable when Operator and Contractor work as a team

Radiation exposures for DOE and DOE contractor employees, 1987

International Nuclear Information System (INIS)

1989-10-01

This report is one of series of annual reports provided by the US Department of Energy (DOE) summarizing occupational radiation exposures received by DOE and DOE contractor employees. These reports provide an overview of radiation exposures received each year, as well as identification of trends in exposures being experienced over the years. 5 figs., 30 tabs

Military Contractors - Too Much Dependence

National Research Council Canada - National Science Library

Hill, Nathan E

2008-01-01

.... There is undoubtedly a need for military contractors and there are numerous positive arguments in their favor. However, the negative arguments have not been highlighted enough recently and the scales are now out of balance. The intent of this research paper is to encourage the U.S. military to rebalance the scales and curb the over-reliance on contractors.

48 CFR 952.251-70 - Contractor employee travel discounts.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor employee travel... Contractor employee travel discounts. As prescribed in 951.7002, insert the following clause: Contractor Employee Travel Discounts (AUG 2009) (a) The Contractor shall take advantage of travel discounts offered to...

48 CFR 245.608 - Screening of contractor inventory.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 3 2010-10-01 2010-10-01 false Screening of contractor inventory. 245.608 Section 245.608 Federal Acquisition Regulations System DEFENSE ACQUISITION REGULATIONS... Disposal of Contractor Inventory 245.608 Screening of contractor inventory. ...

48 CFR 1553.209 - Contractor qualifications.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor qualifications. 1553.209 Section 1553.209 Federal Acquisition Regulations System ENVIRONMENTAL PROTECTION AGENCY CLAUSES AND FORMS FORMS Prescription of Forms 1553.209 Contractor qualifications. ...

48 CFR 45.501 - Prime contractor alternate locations.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Prime contractor alternate... CONTRACT MANAGEMENT GOVERNMENT PROPERTY Support Government Property Administration 45.501 Prime contractor... administration from another contract administration office, for purposes of evaluating prime contractor...

48 CFR 1852.209-72 - Composition of the contractor.

Science.gov (United States)

2010-10-01

... contractor. 1852.209-72 Section 1852.209-72 Federal Acquisition Regulations System NATIONAL AERONAUTICS AND... and Clauses 1852.209-72 Composition of the contractor. As prescribed in 1809.670, insert the following clause: Composition of the Contractor (DEC 1988) If the Contractor is comprised of more than one legal...

Setting the Record Straight: Strong Positive Impacts Found from the National Evaluation of Upward Bound. Re-Analysis Documents Significant Positive Impacts Masked by Errors in Flawed Contractor Reports

Science.gov (United States)

Cahalan, Margaret; Goodwin, David

2014-01-01

In January 2009, in the last week of the Bush Administration, the U.S. Department of Education (ED), upon orders from the departing political appointee staff, published the final report in a long running National Evaluation of Upward Bound (UB). The study was conducted by the contractor, Mathematica Policy Research. After more than a year in…

48 CFR 53.209 - Contractor qualifications.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Contractor qualifications. 53.209 Section 53.209 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION (CONTINUED) CLAUSES AND FORMS FORMS Prescription of Forms 53.209 Contractor qualifications. ...

48 CFR 2936.201 - Evaluation of contractor performance.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 7 2010-10-01 2010-10-01 false Evaluation of contractor... Construction 2936.201 Evaluation of contractor performance. The HCA must establish procedures to evaluate construction contractor performance and prepare performance reports as required by FAR 36.201. ...

48 CFR 1552.209-76 - Contractor performance evaluations.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor performance... 1552.209-76 Contractor performance evaluations. As prescribed in section 1509.170-1, insert the following clause in all applicable solicitations and contracts. Contractor Performance Evaluations (OCT 2002...

48 CFR 8.406-7 - Contractor Performance Evaluation.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor Performance... ACQUISITION PLANNING REQUIRED SOURCES OF SUPPLIES AND SERVICES Federal Supply Schedules 8.406-7 Contractor Performance Evaluation. Ordering activities must prepare an evaluation of contractor performance for each...

48 CFR 32.909 - Contractor inquiries.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor inquiries. 32.909 Section 32.909 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION GENERAL CONTRACTING REQUIREMENTS CONTRACT FINANCING Prompt Payment 32.909 Contractor inquiries. (a) Direct questions...

National Radon Contractor Proficiency Program. Proficiency report: Supplement

International Nuclear Information System (INIS)

1991-02-01

The report, a supplement to the RCP Proficiency Report, will further assist governmental officials in providing advice to the public on the selection of proficient radon mitigation contractors. These reports list 1,123 contractors who have met the requirements of the RCP Program as of December 15, 1990. The Proficiency Report provides information on each contractor's name, RCP identification number, company name, address, phone number, and geographic service area. The report provides two additional tables, indexed by company name and by RCP identification number. The report is intended to help users quickly identify a proficient contractor if only the company name is known, or to verify which contractor is associated with a particular ID number

Contractor Software Charges

National Research Council Canada - National Science Library

Granetto, Paul

1994-01-01

.... Examples of computer software costs that contractors charge through indirect rates are material management systems, security systems, labor accounting systems, and computer-aided design and manufacturing...

48 CFR 2452.251-70 - Contractor employee travel.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor employee travel... 2452.251-70 Contractor employee travel. As prescribed in 2451.7001, insert the following clause in all cost-reimbursement solicitations and contracts involving travel: Contractor Employee Travel (OCT 1999...

48 CFR 3036.201 - Evaluation of contractor performance.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 7 2010-10-01 2010-10-01 false Evaluation of contractor performance. 3036.201 Section 3036.201 Federal Acquisition Regulations System DEPARTMENT OF HOMELAND SECURITY... contractor performance. (a)(2) Performance reports shall be prepared and entered into the Contractor...

48 CFR 2152.215-70 - Contractor records retention.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor records... PRECONTRACT PROVISIONS AND CONTRACT CLAUSES Text of Provisions and Clauses 2152.215-70 Contractor records retention. As prescribed in 2115.071, insert the following clause: Contractor Records Retention (OCT 2005...

48 CFR 36.506 - Superintendence by the contractor.

Science.gov (United States)

2010-10-01

... contractor. 36.506 Section 36.506 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION... Superintendence by the contractor. The contracting officer shall insert the clause at 52.236-6, Superintendence by the Contractor, in solicitations and contracts when a fixed-price construction contract or a fixed...

48 CFR 1652.204-70 - Contractor records retention.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor records... of FEHBP Clauses 1652.204-70 Contractor records retention. As prescribed in 1604.705 the following clause will be inserted in all FEHB Program contracts. Contractor Records Retention (JUL 2005...

48 CFR 4.102 - Contractor's signature.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor's signature. 4.102 Section 4.102 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION GENERAL ADMINISTRATIVE MATTERS Contract Execution 4.102 Contractor's signature. (a) Individuals. A contract with an...

48 CFR 253.209 - Contractor qualifications.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 3 2010-10-01 2010-10-01 false Contractor qualifications. 253.209 Section 253.209 Federal Acquisition Regulations System DEFENSE ACQUISITION REGULATIONS SYSTEM, DEPARTMENT OF DEFENSE CLAUSES AND FORMS FORMS Prescription of Forms 253.209 Contractor qualifications. ...

Chronic beryllium disease prevention program; worker safety and health program. Final rule.

Science.gov (United States)

2006-02-09

The Department of Energy (DOE) is today publishing a final rule to implement the statutory mandate of section 3173 of the Bob Stump National Defense Authorization Act (NDAA) for Fiscal Year 2003 to establish worker safety and health regulations to govern contractor activities at DOE sites. This program codifies and enhances the worker protection program in operation when the NDAA was enacted.

Strategic Change in a Construction Contractor's Purchasing Organisation and Supplier Relations

DEFF Research Database (Denmark)

Koch, Christian; Tambo, Torben

2010-01-01

The paper adopts a combined supply chain management and purchasing theory approach to changes in a contractor's purchasing organization and suppliers relations. This is seen to be a complex prolonged change process emerging over long time. The method is qualitative and longitudinal combining ex...... ante studies with ex post elements. As the time frame is ten years a necessary combination of studies with different aims has been done. The case of a major contractor's efforts within supply chain and purchasing exhibits a number of change elements in interaction; new business concepts, processes...

The status of contractors workers operating in US nuclear power plants

International Nuclear Information System (INIS)

Lochard, J.

1985-01-01

The status of contractors operating in PWRs in the United States is described. The statistics concerning the trends of both the individual and collective exposures of these workers were analysed as well as their main demographic and sociological features. The data relative to the particular group of ''transient'' workers, i.e. those operating in several different power plants during the same year were also examined. The results presented show that the dosimetric and sociological profiles of contractors' workers, in US power plants, do not differ fundamentally from that of permanent workers [fr

30 CFR 875.20 - Contractor eligibility.

Science.gov (United States)

2010-07-01

... 30 Mineral Resources 3 2010-07-01 2010-07-01 false Contractor eligibility. 875.20 Section 875.20 Mineral Resources OFFICE OF SURFACE MINING RECLAMATION AND ENFORCEMENT, DEPARTMENT OF THE INTERIOR ABANDONED MINE LAND RECLAMATION CERTIFICATION AND NONCOAL RECLAMATION § 875.20 Contractor eligibility. Every...

30 CFR 874.16 - Contractor eligibility.

Science.gov (United States)

2010-07-01

... 30 Mineral Resources 3 2010-07-01 2010-07-01 false Contractor eligibility. 874.16 Section 874.16 Mineral Resources OFFICE OF SURFACE MINING RECLAMATION AND ENFORCEMENT, DEPARTMENT OF THE INTERIOR ABANDONED MINE LAND RECLAMATION GENERAL RECLAMATION REQUIREMENTS § 874.16 Contractor eligibility. To receive...

7 CFR 3015.183 - Access to contractor records.

Science.gov (United States)

2010-01-01

... 7 Agriculture 15 2010-01-01 2010-01-01 false Access to contractor records. 3015.183 Section 3015... contractor records. The Attachment 0 requires recipients to include in specified kinds of contracts a provision for access to the contractor's records by the recipient and the Federal government. The following...

48 CFR 3052.204-71 - Contractor employee access.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 7 2010-10-01 2010-10-01 false Contractor employee access... CLAUSES Text of Provisions and Clauses 3052.204-71 Contractor employee access. As prescribed in (HSAR) 48...: Contractor Employee Access (JUN 2006) (a) “Sensitive Information,” as used in this Chapter, means any...

Financial Analysis for Phase 1 Privatization for the Tank Farm Contractor

International Nuclear Information System (INIS)

BASCHE, A.D.

2000-01-01

The purpose of the Financial Analysis for Phase 1 Privatization for the Tank Farm Contractor is to provide a third-party quantitative and qualitative cost and schedule risk analysis of HNF-1946. The purpose of this Financial Analysis for Phase 1 Privatization for the Tank Farm Contractor (TFC) is to document the results of the risk-based financial analysis of HNF-1946, Programmatic Baseline Summary for Phase 1 Privatization f o r the Tank Farm Contractor (Diediker 2000). This analysis was performed to evaluate how well the proposed baseline meets the U. S. Department of Energy, Office of River Protection (ORP) Letter OO-MSO-009, ''Contract NO. DE-AC06-99RL14047--The US Department of Energy, Office of River Protection (ORP) Mission Planning Guidance for Fiscal Year (FY) 2002--Revision 1'' (Short 2000). The letter requires a confidence level in the baseline schedule that is consistent with the Phase 1A readiness-to-proceed (RTP) assessment conducted in fiscal year (FY) 1998. Because the success of the project depends not only on the budget but also on the schedule, this risk analysis addresses both components of the baseline

Contingency Contractor Optimization Phase 3 Sustainment Platform Requirements - Contingency Contractor Optimization Tool - Prototype

Energy Technology Data Exchange (ETDEWEB)

Durfee, Justin David [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States); Frazier, Christopher Rawls [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States); Bandlow, Alisa [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States); Gearhart, Jared Lee [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States); Jones, Katherine A. [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States)

2016-06-01

Sandia National Laboratories (Sandia) is in Phase 3 Sustainment of development of a prototype tool, currently referred to as the Contingency Contractor Optimization Tool - Prototype (CCOTP), under the direction of OSD Program Support. CCOT-P is intended to help provide senior Department of Defense (DoD) leaders with comprehensive insight into the global availability, readiness and capabilities of the Total Force Mix. The CCOT-P will allow senior decision makers to quickly and accurately assess the impacts, risks and mitigating strategies for proposed changes to force/capabilities assignments, apportionments and allocations options, focusing specifically on contingency contractor planning. During Phase 2 of the program, conducted during fiscal year 2012, Sandia developed an electronic storyboard prototype of the Contingency Contractor Optimization Tool that can be used for communication with senior decision makers and other Operational Contract Support (OCS) stakeholders. Phase 3 used feedback from demonstrations of the electronic storyboard prototype to develop an engineering prototype for planners to evaluate. Sandia worked with the DoD and Joint Chiefs of Staff strategic planning community to get feedback and input to ensure that the engineering prototype was developed to closely align with future planning needs. The intended deployment environment was also a key consideration as this prototype was developed. Initial release of the engineering prototype was done on servers at Sandia in the middle of Phase 3. In 2013, the tool was installed on a production pilot server managed by the OUSD(AT&L) eBusiness Center. The purpose of this document is to specify the CCOT-P engineering prototype platform requirements as of May 2016. Sandia developed the CCOT-P engineering prototype using common technologies to minimize the likelihood of deployment issues. CCOT-P engineering prototype was architected and designed to be as independent as possible of the major deployment

Determinants of contractor pricing strategy

OpenAIRE

Moses, O. Douglas

1988-01-01

This paper investigates pricing strategies used by major defense contractors. Two pricing strategies are identified and discussed: penetration, which calls for a relatively low initial price followed by little reduction in price over time, and skimming, which calls for a relatively high initial price coupled with greater reduction in price over time. It is argued that contractor pricing strategy will depend on features of the defense program under consideration and featur...

DOE contractor trade network: a decade of experience in training resource exchange

International Nuclear Information System (INIS)

Croll, P.; Weseman, M.

1989-01-01

Training Resources and Data Exchange (TRADE) refers to a series of activities designed to increase communication and exchanges of ideas, information, and resources among US Department of Energy contractor operated facilities in the field of training and human resource development. TRADE activities are planned and implemented by the DOE Contractor TRADE Executive Committee. TRADE objectives are accomplished through conference workshops, publications, and special interest groups. TRADE special interest groups include the following: computer-based training, emergency preparedness, industrial hygiene training, human resource issues, radiation protection training, safeguards and security training. The authors discuss how TRADE has evolved to meet changing contractor needs to improve human performance over the last 10 years. TRADE currently has working agreements to share training information with INPO, the Federal Laboratories Consortium, and the National Registry of Radiation Protection Technologists

A practical due diligence strategy for managing the safety of contractors

International Nuclear Information System (INIS)

Catton, C.

1998-01-01

Ontario Hydro's Fossil Business has developed and implemented a practical program to ensure that the due diligence requirements for contractors are met, particularly in the health and safety area. Companies in the power generation business are hiring contractors to protect their competitive potential by having them perform specialty work outside the core business of generating electricity. The reasons behind this trend, and the need for companies to develop comprehensive contractor safety management systems to avoid legislative liability and cost overruns, and to have contractors work safely, are examined. The main elements of Ontario Hydro's Fossil Business Contractor Safety Management Program (contractor safety policy, contractor safety manual, contractor safety training, and a contractor safety performance database) are discussed. 2 figs., 2 appendices

Key drivers for informal project coordination among sub-contractors

DEFF Research Database (Denmark)

Aagaard, Annabeth; Eskerod, Pernille; Madsen, Erik Skov

2015-01-01

understandings. Still though, many sub-contractors choose not to coordinate informally. The purpose of this paper is to identify drivers that enhance or inhibits informal coordination in projects. A qualitative, explorative case study approach was applied. Fifteen SME sub-contractors within the offshore wind...... are massive. Six drivers which enhance informal coordination and three drivers which inhibit informal coordination among sub-contractors in projects were identified. The findings imply that management in project-oriented organizations can enhance informal coordination across project sub-contractors...... and by facilitating trust building, by emphasizing previous collaboration successes with the sub-contractors and the possibility of future common projects, by being explicit about expectations on informal coordination, and by developing sub-contractor contracts that are not as tight in economic terms, but instead...

48 CFR 1852.242-73 - NASA contractor financial management reporting.

Science.gov (United States)

2010-10-01

... Provisions and Clauses 1852.242-73 NASA contractor financial management reporting. As prescribed in 1842.7202, insert the following clause: NASA Contractor Financial Management Reporting (NOV 2004) (a) The Contractor... instructions in NASA Procedures and Guidelines (NPR) 9501.2, NASA Contractor Financial Management Reporting...

78 FR 46783 - Federal Acquisition Regulation; Documenting Contractor Performance

Science.gov (United States)

2013-08-01

..., Sequence 1] RIN 9000-AM09 Federal Acquisition Regulation; Documenting Contractor Performance AGENCY... the Contractor Performance Assessment Reporting System (CPARS), the single Governmentwide past... Procurement Policy (OFPP) memorandum entitled ``Improving the Use of Contractor Performance Information...

Private Security Contractors in Darfur

DEFF Research Database (Denmark)

Leander, Anna

2006-01-01

This article argues that the role of Private Security Contractors in Darfur reflects and reinforces neo-liberal governmentality in contemporary security governance. It is an argument (in line with other articles in this special issue) which is more interested in discussing how the privatization....... It underlines that governance is increasingly taking place through a set of (quasi-) markets, it is marked by entrepreneurial values, and a hands off approach to governance. We then discuss the way this overall change is reflected in and reinforced by the role of private security contractors in Darfur. Drawing...... at these processes is necessary to understand the role of private security contractors in Darfur. But more than this, practices in Darfur entrench neo-liberal governmentality in security more generally. The managerial and `de-politicizing' approach to security in Darfur displaces alternative views not only...

76 FR 37704 - Federal Acquisition Regulation; Documenting Contractor Performance

Science.gov (United States)

2011-06-28

... Federal Acquisition Regulation; Documenting Contractor Performance AGENCY: Department of Defense (DoD..., and to require all past performance information be entered into the Contractor Performance Assessment... Contractor Performance Information. These changes provide Governmentwide standardized evaluation factors and...

Financial management of construction contractors.

OpenAIRE

Lacaria, Chris J.

1994-01-01

The scope of this paper is to discuss the financial management of a construction contractor. This paper attempts to approach this subject in a logical and systematic way. It communicates the importance of financial analysis and planning along with cash planning and profit planning. This report is not intended to be an all inclusive discussion of financial management in construction. Contractor's Financial Management is an extremely important subject. It has been told ...

A guide for heating contractor; Opas laempoeyrittaejaelle

Energy Technology Data Exchange (ETDEWEB)

Solmio, H; Tuomi, S; Valkonen, J

1996-12-31

Heating contractor is eg. a forest owner, who is responsible for the heating of a commune owned school using firewood purchased from the contractor`s own forests. This is a new alternative for entrepreneurship in the countryside. This guide has been meant as an aid for persons starting heating contraction. It is supposed to be of importance for the designers of the communal energy supply, for advisors and instructors, as well as for those already started the heating contraction. The guide discusses the following topics: Why to became a heating contractor; The ways of heating contraction; operational requirements; Contracts; Conversion of a boiler plant to wood fuels; Fuel purchase; Heating work; Profitably estimation; Examples of operational solutions. The guide also includes as an example a draft contract for heating contraction

National Radon Contractor Proficiency Program. Proficiency report, October 1990

International Nuclear Information System (INIS)

1990-10-01

The report lists those individual contractors in the United States who have met the requirements of the Radon Contractor Proficiency (RCP) Program as of August 18, 1990. These requirements are designed to provide minimum proficiency criteria for individuals who design and supervise the installation of radon mitigation systems in buildings. (Some States have more stringent requirements as part of their radon certification programs. The States should be consulted directly for details on their programs; see Section 5 for a list of State radon contacts). The RCP Program measures the proficiency of an individual contractor, not their company. Therefore, users of the report who select a mitigation firm should ensure that the services are provided by the listed contractor. The National RCP Program does not accredit mitigation contractors, nor does it certify, recommend, or endorse participating companies. Only the listed contractor, not their company of affilation, are deemed proficient. The inclusion of a contractor in the report should not be interpreted as a certification or accreditation of the individual or affiliated company

Final Report: Contractor Readiness Assessment (CRA) for TREAT Fuel Movement and Control Rod Drives Isolation

Energy Technology Data Exchange (ETDEWEB)

Rowsell, David Leon [Idaho National Laboratory (INL), Idaho Falls, ID (United States)

2015-06-01

This report documents the Contractor Readiness Assessment (CRA) for TREAT Fuel Movement and Control Rod Drives Isolation. The review followed the approved Plan of Action (POA) and Implementation Plan (IP) using the identified core requirements. The activity was limited scope focusing on the control rod drives functional isolation and fuel element movement. The purpose of this review is to ensure the facility's readiness to move fuel elements thus supporting inspection and functionally isolate the control rod drives to maintain the required shutdown margin.

Assuring the competence of nuclear power plant contractor personnel

International Nuclear Information System (INIS)

2001-07-01

This report was prepared in response to a recommendation by the IAEA International Working Group on Training and Qualification of NPP Personnel (JWG-T and Q) and supported by a number of IAEA meetings on NPP personnel training. IAEA publications on NPP training are the only international documents available to all Member States with nuclear programmes. This report complements the following IAEA publications on NPP personnel training: Technical Reports Series No. 380, Nuclear Power Plant Personnel Training and its Evaluation, A Guidebook; IAEA-TECDOC-1057, Experience in the Use of Systematic Approach to Training (SAT) for Nuclear Power Plant Personnel and IAEA-TECDOC-1063, IAEA World Survey on Nuclear Power Plant Personnel Training. This TECDOC also supplements the IAEA Safety Guide 50-SG-O1 (Rev. 1), Staffing of Nuclear Power Plants and the Recruitment Training and Authorization of Operating Personnel and Safety Standards Series No. NS-R-2, Safety of Nuclear Power Plants. Operation. Within the context of this report NPP contractors are defined as any personnel working for a nuclear power plant who are not directly employed by the nuclear power plant. Competence is the ability to perform to identified standards; it comprises skills, knowledge and attitudes and may be developed through education, experience and training. Qualification is a formal statement of achievement, resulting from an auditable assessment; if competence is assessed, the qualification becomes a formal statement of competence and may be shown on a certificate, diploma, etc. It is recognized that personnel are used to perform tasks that are of a specialised or temporary nature where it is not feasible to hire or maintain a full-time NPP employee. Accordingly, contractors may be used in a variety of situations to support NPPs. Typical situations include: supplies and services being delivered by the contractors that are subject to different quality standards based on a graded approach to assuring

Assuring the competence of nuclear power plant contractor personnel

Energy Technology Data Exchange (ETDEWEB)

NONE

2001-07-01

This report was prepared in response to a recommendation by the IAEA International Working Group on Training and Qualification of NPP Personnel (JWG-T and Q) and supported by a number of IAEA meetings on NPP personnel training. IAEA publications on NPP training are the only international documents available to all Member States with nuclear programmes. This report complements the following IAEA publications on NPP personnel training: Technical Reports Series No. 380, Nuclear Power Plant Personnel Training and its Evaluation, A Guidebook; IAEA-TECDOC-1057, Experience in the Use of Systematic Approach to Training (SAT) for Nuclear Power Plant Personnel and IAEA-TECDOC-1063, IAEA World Survey on Nuclear Power Plant Personnel Training. This TECDOC also supplements the IAEA Safety Guide 50-SG-O1 (Rev. 1), Staffing of Nuclear Power Plants and the Recruitment Training and Authorization of Operating Personnel and Safety Standards Series No. NS-R-2, Safety of Nuclear Power Plants. Operation. Within the context of this report NPP contractors are defined as any personnel working for a nuclear power plant who are not directly employed by the nuclear power plant. Competence is the ability to perform to identified standards; it comprises skills, knowledge and attitudes and may be developed through education, experience and training. Qualification is a formal statement of achievement, resulting from an auditable assessment; if competence is assessed, the qualification becomes a formal statement of competence and may be shown on a certificate, diploma, etc. It is recognized that personnel are used to perform tasks that are of a specialised or temporary nature where it is not feasible to hire or maintain a full-time NPP employee. Accordingly, contractors may be used in a variety of situations to support NPPs. Typical situations include: supplies and services being delivered by the contractors that are subject to different quality standards based on a graded approach to assuring

Modelling Client Satisfaction Levels: The Impact of Contractor Performance

Directory of Open Access Journals (Sweden)

Robby Soetanto

2012-11-01

Full Text Available The performance of contractors is known to be a key determinant of client satisfaction.Here, using factor analysis, clients’ satisfaction is defined in several dimensions. Based onclients’ assessment of contractor performance, a number of satisfaction models developedusing the multiple regression (MR technique are presented. The models identify arange of variables encompassing contractor performance, project performance and respondent(i.e. client attributes as useful predictors of satisfaction levels. Contractor performanceattributes were found to be of utmost importance indicating that clientsatisfaction levels are mainly dependent on the performance of the contractor. Furthermore,findings suggest that subjectivity is to some extent prevalent in clients’ performanceassessment. The models demonstrate accurate and reliable predictive power as confirmedby validation tests. Contractors could use the models to help improve their performanceleading to more satisfied clients. This would also promote the development ofharmonious working relationships within the construction project coalition.

77 FR 6676 - Office of Inspector General; Contractor Requirements

Science.gov (United States)

2012-02-09

... POSTAL SERVICE 39 CFR Part 230 Office of Inspector General; Contractor Requirements AGENCY: Postal... for contractors employed by the Office of Inspector General. The rule also emphasizes consistency in contractor selection, and clarifies the OIG's exclusive authority to set qualifications and standards for its...

48 CFR 970.0407 - Contractor records retention.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor records retention. 970.0407 Section 970.0407 Federal Acquisition Regulations System DEPARTMENT OF ENERGY AGENCY SUPPLEMENTARY REGULATIONS DOE MANAGEMENT AND OPERATING CONTRACTS Administrative Matters 970.0407 Contractor...

48 CFR 227.7108 - Contractor data repositories.

Science.gov (United States)

2010-10-01

... repositories. 227.7108 Section 227.7108 Federal Acquisition Regulations System DEFENSE ACQUISITION REGULATIONS... Technical Data 227.7108 Contractor data repositories. (a) Contractor data repositories may be established when permitted by agency procedures. The contractual instrument establishing the data repository must...

77 FR 12754 - Contractor Legal Management Requirements; Acquisition Regulations

Science.gov (United States)

2012-03-02

... DEPARTMENT OF ENERGY 10 CFR Part 719 48 Parts 931, 952 and 970 RIN 1990-AA37 Contractor Legal... rulemaking (NOPR) to revise existing regulations covering contractor legal management requirements and make... relating to the DOE notice of proposed rulemaking to revise existing regulations covering contractor legal...

48 CFR 1252.237-70 - Qualifications of contractor employees.

Science.gov (United States)

2010-10-01

... contractor employees. 1252.237-70 Section 1252.237-70 Federal Acquisition Regulations System DEPARTMENT OF....237-70 Qualifications of contractor employees. As prescribed in (TAR) 48 CFR 1237.110(a), insert the following clause: Qualifications of Contractor Employees (APR 2005) a. Definitions. As used in this clause...

48 CFR 2452.237-75 - Clearance of contractor personnel.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Clearance of contractor... Clauses 2452.237-75 Clearance of contractor personnel. As prescribed in 2437.110(e), insert the following clause in solicitations and contracts. Clearance of Contractor Personnel (OCT 1999) (a) General. This...

76 FR 81408 - Contractor Legal Management Requirements; Acquisition Regulations

Science.gov (United States)

2011-12-28

... DEPARTMENT OF ENERGY 10 CFR Part 719 48 CFR Parts 931, 952 and 970 RIN 1990-AA37 Contractor Legal... Energy (DOE or Department) is proposing to revise existing regulations covering contractor legal... costs by certain contractors whose contracts exceed $100,000,000 as well as legal counsel retained...

48 CFR 52.236-6 - Superintendence by the Contractor.

Science.gov (United States)

2010-10-01

... Contractor. 52.236-6 Section 52.236-6 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION....236-6 Superintendence by the Contractor. As prescribed in 36.506, insert the following clause: Superintendence by the Contractor (APR 1984) At all times during performance of this contract and until the work...

76 FR 31416 - Federal Acquisition Regulation; Oversight of Contractor Ethics Programs

Science.gov (United States)

2011-05-31

...-AL92 Federal Acquisition Regulation; Oversight of Contractor Ethics Programs AGENCY: Department of... that contractors have implemented the mandatory contractor business ethics program requirements. DATES... to Improve DoD's Oversight of Contractor Ethics Programs. The ethics program requirement flows from...

48 CFR 1437.7001 - Contractor qualification requirements.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor qualification requirements. 1437.7001 Section 1437.7001 Federal Acquisition Regulations System DEPARTMENT OF THE INTERIOR... Contractor qualification requirements. (a) Prior to award of a contract for real property appraisal services...

14 CFR 1274.402 - Contractor acquired property.

Science.gov (United States)

2010-01-01

... 14 Aeronautics and Space 5 2010-01-01 2010-01-01 false Contractor acquired property. 1274.402 Section 1274.402 Aeronautics and Space NATIONAL AERONAUTICS AND SPACE ADMINISTRATION COOPERATIVE AGREEMENTS WITH COMMERCIAL FIRMS Property § 1274.402 Contractor acquired property. As provided in § 1274.923...

48 CFR 1646.301 - Contractor inspection requirements.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor inspection requirements. 1646.301 Section 1646.301 Federal Acquisition Regulations System OFFICE OF PERSONNEL MANAGEMENT... Clauses 1646.301 Contractor inspection requirements. The clause set forth at 1652.246-70 shall be inserted...

48 CFR 645.608 - Screening of contractor inventory.

Science.gov (United States)

2010-10-01

... inventory. 645.608 Section 645.608 Federal Acquisition Regulations System DEPARTMENT OF STATE CONTRACT MANAGEMENT GOVERNMENT PROPERTY Reporting, Redistribution, and Disposal of Contractor Inventory 645.608 Screening of contractor inventory. ...

Contractors on the Battlefield: Planning Considerations and Requirements

National Research Council Canada - National Science Library

2002-01-01

Contractors on the Battlefield: Planning Considerations and Requirements introduces the basics and foundation for those who want to learn about the history, terminology, and process for obtaining contractor support on the battlefield...

Tank waste remediation system (TWRS) privatization contractor samples waste envelope D material 241-C-106

Energy Technology Data Exchange (ETDEWEB)

Esch, R.A.

1997-04-14

This report represents the Final Analytical Report on Tank Waste Remediation System (TWRS) Privatization Contractor Samples for Waste Envelope D. All work was conducted in accordance with ''Addendum 1 of the Letter of Instruction (LOI) for TWRS Privatization Contractor Samples Addressing Waste Envelope D Materials - Revision 0, Revision 1, and Revision 2.'' (Jones 1996, Wiemers 1996a, Wiemers 1996b) Tank 241-C-1 06 (C-106) was selected by TWRS Privatization for the Part 1A Envelope D high-level waste demonstration. Twenty bottles of Tank C-106 material were collected by Westinghouse Hanford Company using a grab sampling technique and transferred to the 325 building for processing by the Pacific Northwest National Laboratory (PNNL). At the 325 building, the contents of the twenty bottles were combined into a single Initial Composite Material. This composite was subsampled for the laboratory-scale screening test and characterization testing, and the remainder was transferred to the 324 building for bench-scale preparation of the Privatization Contractor samples.

77 FR 3503 - Guam Military Base Realignment Contractor Recruitment Standards

Science.gov (United States)

2012-01-24

... Contractor Recruitment Standards AGENCY: Employment and Training Administration, Labor. ACTION: Notice... issuing this notice to announce the recruitment standards that construction contractors are required to... contractors engaged in construction projects related to the realignment of U.S. military forces from Okinawa...

Accounting calculations problems with suppliers and contractors

Directory of Open Access Journals (Sweden)

Tikholaz I.A.

2016-12-01

Full Text Available in the article an order of accounting reflection of payments with suppliers and contractors are researched and ways of enhancement of accounting calculations process development with the purpose of management decisions optimization for their implementation are offered. Theoretical bases of intraeconomic control of settlings with suppliers and contractors are developed.

National Radon Contractor Proficiency (RCP) Program. Proficiency report, June 1991

International Nuclear Information System (INIS)

1991-06-01

The primary objective of the U.S. Environmental Protection Agency's (EPA) efforts to address the indoor radon problem is to reduce radon levels in buildings throughout the country. Achieving the objective requires a nationwide supply of capable radon mitigation contractors. In the Indoor Radon Abatement Act of 1988, Congress authorized EPA to establish a program to evaluate radon mitigation contractors and to provide the information to the public in cooperation with the States. The Radon Contractor Proficiency (RCP) Program was developed to assist States, EPA Regions, local government officials, and the public in selecting contractors who have demonstrated their proficiency in reducing indoor radon levels. The program is managed by the EPA Office of Radiation Programs' Radon Division. Under the voluntary program, radon contractors demonstrate their proficiency by meeting specific Program requirements. Individual contractors who meet these requirements are then listed in periodic RCP Proficiency Reports

National Radon Contractor Proficiency (RCP) program. Proficiency report, September 1991

International Nuclear Information System (INIS)

1991-09-01

The primary objective of the U.S. Environmental Protection Agency's (EPA) efforts to address the indoor radon problem is to reduce radon levels in buildings throughout the country. Achieving this objective requires a nationwide supply of capable radon mitigation contractors. In the Indoor Radon Abatement Act of 1988, Congress authorized EPA to establish a program to evaluate radon mitigation contractors and to provide this information to the public in cooperation with the States. The Radon Contractor Proficiency (RCP) Program was developed to assist States, EPA Regions, local government officials, and the public in selecting contractors who have demonstrated their proficiency in reducing indoor radon levels. The program is managed by the EPA Office of Radiation Programs' Radon Division. Under this voluntary program, radon contractors demonstrate their proficiency by meeting specific Program requirements. Individual contractors who meet these requirements are then listed in the Report

National Radon Contractor Proficiency (RCP) Program. Proficiency report, January 1992

International Nuclear Information System (INIS)

1992-01-01

The primary objective of the U.S. Environmental Protection Agency's (EPA) efforts to address the indoor radon problem is to reduce radon levels in buildings throughout the country. Achieving the objective requires a nationwide supply of capable radon mitigation contractors. In the Indoor Radon Abatement Act of 1988, Congress authorized EPA to establish a program to evaluate radon mitigation contractors and to provide the information to the public in cooperation with the States. The Radon Contractor Proficiency (RCP) Program was developed to assist States, EPA Regions, local government officials, and the public in selecting contractors who have demonstrated their proficiency in reducing indoor radon levels. The program is managed by the EPA Office of Radiation Programs' Radon Division. Under the voluntary program, radon contractors demonstrate their proficiency by meeting specific Program requirements. Individual contractors who meet these requirements are then listed in the Report

48 CFR 1403.570 - Restrictions on contractor advertising.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Restrictions on contractor advertising. 1403.570 Section 1403.570 Federal Acquisition Regulations System DEPARTMENT OF THE INTERIOR... 1403.570 Restrictions on contractor advertising. ...

76 FR 48776 - Federal Acquisition Regulation; Documenting Contractor Performance; Correction

Science.gov (United States)

2011-08-09

... Regulation; Documenting Contractor Performance; Correction AGENCY: Department of Defense (DoD), General... published in the Federal Register of June 28, 2011, regarding the proposed rule for Documenting Contractor... published in the Federal Register of June 28, 2011, regarding the proposed rule for Documenting Contractor...

42 CFR 405.874 - Appeals of CMS or a CMS contractor.

Science.gov (United States)

2010-10-01

... 42 Public Health 2 2010-10-01 2010-10-01 false Appeals of CMS or a CMS contractor. 405.874 Section... Part B Program § 405.874 Appeals of CMS or a CMS contractor. A CMS contractor's (that is, a carrier... supplier enrollment application. If CMS or a CMS contractor denies a provider's or supplier's enrollment...

Radiation exposures for DOE and DOE contractor employees Eighteenth annual report, 1985

International Nuclear Information System (INIS)

1986-12-01

All US Department of Energy (DOE) and DOE contractors are required to submit occupational radiation exposure records to a central repository. The data required include a summary of whole-body exposures to ionizing radiation, a summary of internal depositions of radioactive materials above specified limits, and occupational exposure reports for terminating employees. This report is a summary of the data submitted by DOE and DOE contractors for 1985. A total of 95,806 DOE and DOE contractor employees were monitored for whole-body ionizing radiation exposures in 1985. In addition to the employees, 96,665 visitors were monitored. Of all employees monitored, 58.4% received a dose equivalent that was less than measurable, 39.8% a measurable exposure less than 1 rem, and 1.9% an exposure greater than 1 rem. One employee received a dose equivalent greater than 5 rem (8.66 rem). The exposure received by 91.9% of the visitors to DOE facilities was less than measurable. No visitors received a dose equivalent greater than 2 rem. The collective dose equivalent for DOE and DOE contractor employees was 8223 person-rem. The collective dose equivalent for visitors was 461 person-rem. These averages are significantly less than the DOE 5-rem/year radiation protection standard for whole-body exposures. Ten new cases of internal depositions were reported in 1985 that exceeded 50% of the pertinent annual dose-equivalent standard. Of these ten cases, eight occurred in a previous year and are reported now because recent revisions in the dose calculations established these cases as reportable depositions. Twenty-six cases reported during 1985 were considered to be the continued tracking of previous depositions. 5 figs., 32 tabs

48 CFR 2804.470 - Contractor Personnel Security Program.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor Personnel Security Program. 2804.470 Section 2804.470 Federal Acquisition Regulations System DEPARTMENT OF JUSTICE General ADMINISTRATIVE MATTERS Safeguarding Classified Information Within Industry 2804.470 Contractor...

Influence of year-on-year performance on final degree classification in a chiropractic master's degree program.

Science.gov (United States)

Dewhurst, Philip; Rix, Jacqueline; Newell, David

2016-03-01

We explored if any predictors of success could be identified from end-of-year grades in a chiropractic master's program and whether these grades could predict final-year grade performance and year-on-year performance. End-of-year average grades and module grades for a single cohort of students covering all academic results for years 1-4 of the 2013 graduating class were used for this analysis. Analysis consisted of within-year correlations of module grades with end-of-year average grades, linear regression models for continuous data, and logistic regression models for predicting final degree classifications. In year 1, 140 students were enrolled; 85.7% of students completed the program 4 years later. End-of-year average grades for years 1-3 were correlated (Pearson r values ranging from .75 to .87), but the end-of-year grades for years 1-3 were poorly correlated with clinic internship performance. In linear regression, several modules were predictive of end-of-year average grades for each year. For year 1, logistic regression showed that the modules Physiology and Pharmacology and Investigative Imaging were predictive of year 1 performance (odds ratio [OR] = 1.15 and 0.9, respectively). In year 3, the modules Anatomy and Histopathology 3 and Problem Solving were predictors of the difference between a pass/merit or distinction final degree classification (OR = 1.06 and 1.12, respectively). Early academic performance is weakly correlated with final-year clinic internship performance. The modules of Anatomy and Histopathology year 3 and Problem Solving year 3 emerged more consistently than other modules as being associated with final-year classifications.

29 CFR 500.60 - Farm labor contractors' recruitment, contractual and general obligations.

Science.gov (United States)

2010-07-01

... labor contractors' recruitment, contractual and general obligations. The Act imposes certain specific recruitment, contractual and general obligations on farm labor contractors and farm labor contractor employees... 29 Labor 3 2010-07-01 2010-07-01 false Farm labor contractors' recruitment, contractual and...

Selection and assessment of contractors; Auswahl und Beurteilung von Auftragnehmerfirmen

Energy Technology Data Exchange (ETDEWEB)

Lier, K.H. [ExxonMobil Production Deutschland GmbH, Hannover (Germany)

2007-09-13

Reliable and efficient contractors are important for the activities of ExxonMobil. Qualification of contractors is to ensure that contractors provide technical services in accordance with the specifications of ExxonMobil. Apart from the financial, oranisational and legal qualification this covers technical qualification, i.e. industrial safety, health protection and environmental protection, as well as technical efficiency and quality. The ultimate intention is to find out if contractors have the processes and systems at their disposal that are required for the services. The qualification process is described. (orig.)

Information technology boosts contractor's economic success

International Nuclear Information System (INIS)

Penny, M.; Vasey, G.M.

1995-01-01

This article will discuss the advantages of Information Technology (IT) and how one drilling contractor, Global Marine, has applied this technology. The company has applied it in an efficient manner which has provided business benefits and cost reductions that have helped its operations be more successful. The following are the different aspects of information technology that led to the contractor's success: cost reduction measures; migration to a client/server IT infrastructure; IT business benefits; and keys to obtaining business benefits from IT

Contractor Selection for Enhancing the Quality of University ...

African Journals Online (AJOL)

Contractor Selection for Enhancing the Quality of University Education in Nigeria using the Hamming Distance. DEA Omorogbe, SO Aibieyi. Abstract. The need for contractor selection in our university education system cannot be over emphasized. And applying scientific techniques for appropriateness and accuracy in the ...

48 CFR 36.201 - Evaluation of contractor performance.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Evaluation of contractor performance. 36.201 Section 36.201 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION... Contracting for Construction 36.201 Evaluation of contractor performance. See 42.1502(e) for the requirements...

48 CFR 49.405 - Completion by another contractor.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Completion by another contractor. 49.405 Section 49.405 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION... contractor. If the surety does not arrange for completion of the contract, the contracting officer normally...

Fiscal Liability of State Contractors

Directory of Open Access Journals (Sweden)

Santiago Fajardo-Peña

2017-06-01

Full Text Available The State contract is one of the most important tools for public management. The formation, execution and liquidation of State contracts are also a potential cause of State patrimonial damages. Perhaps for this reason, many State contractors are prosecuted as if they were public spending managers. The question, however, is not as simple. The fiscal liability process has a qualified recipient: the fiscal manager. In this article, through a conceptual exposition and a case study, we identify the criterion for determining in which cases a State contractor acquires the function of controlling public funds and when he/she can be subjected to a fiscal liability.

77 FR 43078 - Federal Acquisition Regulation; Information Collection; Central Contractor Registration

Science.gov (United States)

2012-07-23

...; Information Collection; Central Contractor Registration AGENCY: Department of Defense (DOD), General Services... requirement concerning the Central Contractor Registration database. Public comments are particularly invited... Information Collection 9000- 0159, Central Contractor Registration, by any of the following methods...

Cassini at Saturn: The Final Two Years

Science.gov (United States)

Spilker, L.; Edgington, S.; Altobelli, N.

2015-10-01

After 11 years in orbit, the Cassini-Huygens Mission to Saturn, a collaboration of NASA, ESA, and ASI, continues to wow the imagination and reveal unprecedented findings. Every year Cassini produces answers to questions raised by the Voyager flybys, while at the same time posing new questions that can only be answered with a long duration mission using a flagship-class spacecraft. Here we sample a few of Cassini's discoveries from the past year and give an overview of Cassini's final two years.

78 FR 12316 - Federal Acquisition Regulation; Information Collection; Central Contractor Registration

Science.gov (United States)

2013-02-22

...; Information Collection; Central Contractor Registration AGENCIES: Department of Defense (DOD), General... collection requirement concerning the Central Contractor Registration database. A notice was published in the... Information Collection 9000- 0159, Central Contractor Registration, by any of the following methods...

Searching for Contracting Patterns over Time: Do Prime Contractor and Subcontractor Relations Follow Similar Patterns for Professional Services Provision?

Science.gov (United States)

Ponomariov, Branco; Kingsley, Gordon; Boardman, Craig

2011-01-01

This paper compares over a 12-year period (1) patterns of contracting between a state transportation agency and its prime contractors providing engineering design services with (2) patterns between these prime contractors and their subcontractors. We find evidence of different contracting patterns at each level that emerge over time and coexist in…

Configuration Management Plan for the Tank Farm Contractor

International Nuclear Information System (INIS)

WEIR, W.R.

2000-01-01

The Configuration Management Plan for the Tank Farm Contractor describes configuration management the contractor uses to manage and integrate its technical baseline with the programmatic and functional operations to perform work. The Configuration Management Plan for the Tank Farm Contractor supports the management of the project baseline by providing the mechanisms to identify, document, and control the technical characteristics of the products, processes, and structures, systems, and components (SSC). This plan is one of the tools used to identify and provide controls for the technical baseline of the Tank Farm Contractor (TFC). The configuration management plan is listed in the management process documents for TFC as depicted in Attachment 1, TFC Document Structure. The configuration management plan is an integrated approach for control of technical, schedule, cost, and administrative processes necessary to manage the mission of the TFC. Configuration management encompasses the five functional elements of: (1) configuration management administration, (2) configuration identification, (3) configuration status accounting, (4) change control, and (5 ) configuration management assessments

Configuration Management Plan for the Tank Farm Contractor

Energy Technology Data Exchange (ETDEWEB)

WEIR, W.R.

2000-04-21

The Configuration Management Plan for the Tank Farm Contractor describes configuration management the contractor uses to manage and integrate its technical baseline with the programmatic and functional operations to perform work. The Configuration Management Plan for the Tank Farm Contractor supports the management of the project baseline by providing the mechanisms to identify, document, and control the technical characteristics of the products, processes, and structures, systems, and components (SSC). This plan is one of the tools used to identify and provide controls for the technical baseline of the Tank Farm Contractor (TFC). The configuration management plan is listed in the management process documents for TFC as depicted in Attachment 1, TFC Document Structure. The configuration management plan is an integrated approach for control of technical, schedule, cost, and administrative processes necessary to manage the mission of the TFC. Configuration management encompasses the five functional elements of: (1) configuration management administration, (2) configuration identification, (3) configuration status accounting, (4) change control, and (5 ) configuration management assessments.

Eleventh annual report of radiation exposures for DOE and DOE contractor employees

International Nuclear Information System (INIS)

1978-01-01

In 1968, the US Atomic Energy Commission (AEC) established a program for reporting certain occupationa radiation exposure information to a central radiation records repository maintained at the Union Carbide Computing Technology Center, Oak Ridge, Tennessee. Annual summaries (WASH-1350-R1 through WASH-1350-R6) were reported for the years 1968-1973 and included data on AEC contracter employees as well as employees of companies in the private sector licensed by the AEC. In January 1975, the operational functions of the AEC, including the maintenance of records on the occupational radiation exposure on contractor employees, were transferred to the Energy Research and Development Administration (ERDA) and the AEC's regulatory functions, including the reporting of information on the occupational radiation exposure of licenses, were transferred to the Nuclear Regulatory Commission (NRC). Previous AEC licenses then reported to NRC while the contractors reported to ERDA. On October 1, 1977, the Department of Energy (DOE) was formed and assumed the responsibilities of ERDA. This report contains the 1978 radiation exposure data for DOE and DOE contractors

Operator and contractor benefit from incentive contracts

International Nuclear Information System (INIS)

Brandon, B.

1991-01-01

This book reports that with incentive contracts, drilling and service contractors assume greater responsibility for operations. That helps them to align their goals more closely with those of the operator. This achieves a more equitable division of the risks. Many operators and contractors believe this is a more appropriate approach to contracting drilling services. As they assume manageable responsibility, each party also has opportunities for greater reward. Innovations in cooperation can create a win-win situation. In a win-win contract all parties benefit from the new relationships between operator, contractor, and service company. The win-win situation can only be achieved by allowing the contracting parties to become much more closely involved in drilling operations. This is the primary motivation behind development of more productive contracting strategies

48 CFR 252.235-7011 - Final scientific or technical report.

Science.gov (United States)

2010-10-01

... technical report. 252.235-7011 Section 252.235-7011 Federal Acquisition Regulations System DEFENSE... CLAUSES Text of Provisions And Clauses 252.235-7011 Final scientific or technical report. As prescribed in 235.072(d), use the following clause: Final Scientific or Technical Report (NOV 2004) The Contractor...

77 FR 69715 - Federal Acquisition Regulation; Updates to Contract Reporting and Central Contractor Registration

Science.gov (United States)

2012-11-20

... Contractor Registration AGENCY: Department of Defense (DoD), General Services Administration (GSA), and... changes the clauses requiring contractor registration in the Central Contractor Registration (CCR... unique identifier for contractors. It is used (1) to uniquely identify a contractor entity, and (2) to...

Exposing government response action contractors to environmental tort liability

International Nuclear Information System (INIS)

Roy, M.J.

1991-01-01

Government contractors, particularly those involved with hazardous waste response action activities, are encountering increased risks for environmental tort liabilities. Contracts often include tasks and work assignments requiring the management of industrial, chemical, nuclear or mining wastes, spent fuels, munitions or other toxic substances. Contractors exposure to liability for damages results directly from the environmental laws and regulations pursuant to which the Government has contracted them to respond. Additionally, contractors may be exposed to common law liability under such dogmas as nuisance, trespass and strict liability in tort

75 FR 66680 - Defense Federal Acquisition Regulation Supplement (DFARS); Continuation of Essential Contractor...

Science.gov (United States)

2010-10-29

...-AG52 Defense Federal Acquisition Regulation Supplement (DFARS); Continuation of Essential Contractor... that contractors providing essential contractor services, as determined by the requiring activity..., implementing the requirements of DoDI 3020.37, Continuation of Essential DoD Contractor Services During Crises...

48 CFR 52.236-23 - Responsibility of the Architect-Engineer Contractor.

Science.gov (United States)

2010-10-01

... Architect-Engineer Contractor. 52.236-23 Section 52.236-23 Federal Acquisition Regulations System FEDERAL... Provisions and Clauses 52.236-23 Responsibility of the Architect-Engineer Contractor. As prescribed in 36.609-2(b), insert the following clause: Responsibility of the Architect-Engineer Contractor (APR 1984) (a...

78 FR 30233 - Defense Federal Acquisition Regulation Supplement; Government Support Contractor Access to...

Science.gov (United States)

2013-05-22

... Number 0750-AG38 Defense Federal Acquisition Regulation Supplement; Government Support Contractor Access... Government support contractors to have access to proprietary technical data belonging to prime contractors and other third parties, provided that the technical data owner may require the support contractor to...

Analysis of Criteria Influencing Contractor Selection Using TOPSIS Method

Science.gov (United States)

Alptekin, Orkun; Alptekin, Nesrin

2017-10-01

Selection of the most suitable contractor is an important process in public construction projects. This process is a major decision which may influence the progress and success of a construction project. Improper selection of contractors may lead to problems such as bad quality of work and delay in project duration. Especially in the construction projects of public buildings, the proper choice of contractor is beneficial to the public institution. Public procurement processes have different characteristics in respect to dissimilarities in political, social and economic features of every country. In Turkey, Turkish Public Procurement Law PPL 4734 is the main regulatory law for the procurement of the public buildings. According to the PPL 4734, public construction administrators have to contract with the lowest bidder who has the minimum requirements according to the criteria in prequalification process. Public administrators are not sufficient for selection of the proper contractor because of the restrictive provisions of the PPL 4734. The lowest bid method does not enable public construction administrators to select the most qualified contractor and they have realised the fact that the selection of a contractor based on lowest bid alone is inadequate and may lead to the failure of the project in terms of time delay Eand poor quality standards. In order to evaluate the overall efficiency of a project, it is necessary to identify selection criteria. This study aims to focus on identify importance of other criteria besides lowest bid criterion in contractor selection process of PPL 4734. In this study, a survey was conducted to staff of Department of Construction Works of Eskisehir Osmangazi University. According to TOPSIS (Technique for Order Preference by Similarity to the Ideal Solution) for analysis results, termination of construction work in previous tenders is the most important criterion of 12 determined criteria. The lowest bid criterion is ranked in rank 5.

Project Finance Model for Small Contractors in USA

Directory of Open Access Journals (Sweden)

Jawahar Nesan

2012-11-01

Full Text Available Construction projects do not require a large capital outlay but a large working capital to start up the project. Unfortunately, for small contractors there are very limited options available from the banks or other lending institutions to cover this large working capital requirement in the absence of sufficient collateral. The “Project Finance” method presented in this paper is recommended as the most effective method for small contractors in the United States. The problems of small and start up contractors in funding their projects have been little addressed in the literature. The current financing practices were observed through both the literature review and interviews with contractors and bankers in the western Michigan area and subsequently a system has been proposed which could help a small start-up company seeking higher growth. The growth rates that can be achieved using the project finance system in contrast to the traditional “line of credit” arrangements as illustrated in this paper show that the project finance model is beneficial.

Building America Expert Meeting Report. Transitioning Traditional HVAC Contractors to Whole House Performance Contractors

Energy Technology Data Exchange (ETDEWEB)

Burdick, Arlan [IBACOS Inc., Pittsburgh, PA (United States)

2011-10-01

This expert meeting was hosted by the IBACOS Building America research team to determine how HVAC companies can transition from a traditional contractor status to a service provider for whole house energy upgrade contracting.

76 FR 50714 - Federal Acquisition Regulation; Documenting Contractor Performance; Correction

Science.gov (United States)

2011-08-16

... Regulation; Documenting Contractor Performance; Correction AGENCY: Department of Defense (DoD), General... August 9, 2011, regarding the proposed rule for Documenting Contractor Performance. DATES: The comment...

Highlights of contractor initiatives in quality enhancement and productivity improvement

Science.gov (United States)

1986-01-01

The NASA/Contractor Team efforts are presented as part of NASA's continuing effort to facilitate the sharing of quality and productivity improvement ideas among its contractors. This complilation is not meant to be a comprehensive review of contractor initiative nor does it necessarily express NASA's views. The submissions represent samples from a general survey, and were not edited by NASA. The efforts are examples of quality and productivity programs in private industry, and as such, highlight company efforts in individual areas. Topics range from modernization of equipment, hardware, and technology to management of human resources. Of particular interest are contractor initiatives which deal with measurement and evaluation data pertaining to quality and productivity performance.

Medicare Administrative Contractor Performance Evaluation

Data.gov (United States)

U.S. Department of Health & Human Services — The Centers for Medicare and Medicaid Services (CMS) has compiled a summary of overall Medicare Administrative Contractor (MAC) performance information as measured...

48 CFR 852.236-72 - Performance of work by the contractor.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Performance of work by the....236-72 Performance of work by the contractor. As prescribed in 836.501, insert the following clause: Performance of Work by the Contractor (JUL 2002) The clause entitled “Performance of Work by the Contractor...

Emerging Trends of the Owner-Contractor Relationship for Capital Facility Projects: From the Contractor Perspective

National Research Council Canada - National Science Library

Geertsema, Cameron

2003-01-01

.... Specifically, this document will focus on how the outcome of capital facility projects are affected by human resources practices, and the management principles and practices of the contractor-owner...

77 FR 51783 - Federal Acquisition Regulation; Information Collection; Contractors' Purchasing Systems Reviews

Science.gov (United States)

2012-08-27

...; Information Collection; Contractors' Purchasing Systems Reviews AGENCY: Department of Defense (DOD), General... collection requirement concerning contractors' purchasing systems reviews. Public comments are particularly... Information Collection 9000- 0132, Contractors' Purchasing Systems Reviews, by any of the following methods...

76 FR 60837 - Federal Acquisition Regulation; Information Collection; Contractor Business Ethics Compliance...

Science.gov (United States)

2011-09-30

...; Information Collection; Contractor Business Ethics Compliance Program and Disclosure Requirements AGENCIES... concerning contractor business ethics compliance program and disclosure requirements. Public comments are... Collection 9000- 0164, Contractor Business Ethics Compliance Program and Disclosure Requirements, by any of...

Contractor firm strategies in delivering green project: A review

Science.gov (United States)

Powmya, Ayisha; Abidin, Nazirah Zainul; Azizi, Nurul Sakina Mokhtar

2017-10-01

Building green requires effort from various parties, from those who plan, design, manage and construct the building. Contractors are responsible for converting the design on paper into a real building and their role at the construction site support environmental sustainability by implementing responsible construction practices. Inefficient or inexperienced contractor in green construction project may find that delivering this type of project is not an easy task due to added requirement in design, stringent practices at site and the use of green technology and materials. Adopting suitable strategies at firm level will assist in preparatory process and readiness of delivering the green project. This paper reviews the strategies at firm level to deliver green construction project. From extensive literature review, it was discovered that there are six strategies to be adopted by the contractor. Understanding these strategies is expected to promote more contractors to be proactive in delivering green projects.

78 FR 59851 - Defense Federal Acquisition Regulation Supplement: Enhancement of Contractor Employee...

Science.gov (United States)

2013-09-30

...-AH97 Defense Federal Acquisition Regulation Supplement: Enhancement of Contractor Employee... contractor and subcontractor employees. DATES: Effective date: September 30, 2013. In accordance with FAR 1... Whistleblower Protections for Contractor Employees) made extensive changes to 10 U.S.C. 2409, entitled...

Contractors on the Battlefield: What Have We Signed Up For?

National Research Council Canada - National Science Library

Zamparelli, Steven

1999-01-01

The role of contractors in warfare has changed dramatically. As the Services have drawn down, more and more of the duties formerly accomplished by military members are being performed by contractors...

Comment Response on the Final Report: Peer Review of the Total System Performance Assessment-Viability Assessment (TSPA-VA)

International Nuclear Information System (INIS)

Pendleton, M. W.

1999-01-01

The Management and Operating Contractor established a Performance Assessment Peer Review Panel (hereinafter ''the Panel'') at the request of the U.S. Department of Energy Yucca Mountain Site Characterization Office. The objectives of the peer review were to provide: (1) A formal, independent evaluation and critique of Viability Assessment of a Repository at Yucca Mountain: Total System Performance Assessment, Volume 3 (DOE 1998a; hereinafter ''Total System Performance Assessment-Viability Assessment'') that was conducted in support of the Viability Assessment of a Repository at Yucca Mountain (DOE 1998b). (2) Suggestions for improvements as the U.S. Department of Energy prepares to develop the documentation for a Total System Performance Assessment to support a potential License Application. The Panel conducted a phased review over a two-year period to observe the development and, ultimately, to review the Total System Performance Assessment-Viability Assessment (DOE 1998a). During the development of the Total System Performance Assessment-Viability Assessment (DOE 1998a), the Panel submitted three Interim Reports (Whipple et al., 1997a, 1997b, and 1998) to the Management and Operating Contractor with recommendations and comments on the process models, model abstractions, and draft documentation for the Total System Performance Assessment-Viability Assessment (DOE 1998a). The Panel's Final Report Total System Performance Assessment Peer Review Panel (Whipple et al. 1999; hereinafter ''Final Report'') on the Total System Performance Assessment-Viability Assessment (DOE 1998a) is based primarily on the completed Total System Performance Assessment-Viability Assessment (DOE 1998a), the Total System Performance Assessment-Viability Assessment (TSPA-VA) Analyses Technical Basis Document (CRWMS M and O 1998), and the cited references. The Final Report (Whipple et al. 1999) includes the major points from the three Interim Reports (Whipple et al. 1997a, 1997b, and 1998

75 FR 55577 - Clean Water Act; Contractor Access to Confidential Business Information

Science.gov (United States)

2010-09-13

... ENVIRONMENTAL PROTECTION AGENCY [FRL-9200-8] Clean Water Act; Contractor Access to Confidential... Recovery Act (RCRA). Transfer of the information will allow the contractor and subcontractors to access... contractors and subcontractors over the history of the effluent guidelines program. EPA determined that this...

75 FR 82575 - Federal Acquisition Regulation; Personal Identity Verification of Contractor Personnel

Science.gov (United States)

2010-12-30

... 9000-AL60 Federal Acquisition Regulation; Personal Identity Verification of Contractor Personnel AGENCY... requirement of collecting from contractors all forms of Government-provided identification once they are no...D Inspector General Audit Report No. D-2009-005, entitled ``Controls Over the Contractor Common...

77 FR 60962 - Clean Water Act; Contractor Access to Confidential Business Information

Science.gov (United States)

2012-10-05

... ENVIRONMENTAL PROTECTION AGENCY 40 CFR Part 2 [FRL-9733-8] Clean Water Act; Contractor Access to... transfer of confidential business information to contractor, subcontractors, and consultants. SUMMARY: The... certain industries. We have determined that the contractors listed below require access [[Page 60963

77 FR 51496 - Federal Acquisition Regulation; Basic Safeguarding of Contractor Information Systems

Science.gov (United States)

2012-08-24

... Federal Acquisition Regulation; Basic Safeguarding of Contractor Information Systems AGENCY: Department of... Acquisition Regulation (FAR) to add a new subpart and contract clause for the basic safeguarding of contractor... information) that will be resident on or transiting through contractor information systems. DATES: Interested...

75 FR 60452 - Clean Water Act; Contractor Access to Confidential Business Information

Science.gov (United States)

2010-09-30

... ENVIRONMENTAL PROTECTION AGENCY [FRL-9208-9] Clean Water Act; Contractor Access to Confidential... electric industry to a new subcontractor of a contractor, Eastern Research Group (ERG). EPA previously... contractors and subcontractors to access information necessary to support EPA in the planning, development...

76 FR 4343 - Agency Information Collection Activities; Proposed Collection; Comment Request; Contractor...

Science.gov (United States)

2011-01-25

...; Contractor Conflicts of Interest AGENCY: Environmental Protection Agency. ACTION: Notice. SUMMARY: In... control numbers in certain EPA regulations is consolidated in 40 CFR part 9. Abstract: EPA contractors... cleanup and enforcement and because its contractors are often involved in both activities, it is...

76 FR 81490 - Agency Information Collection Activities; Proposed Collection; Comment Request; Contractor...

Science.gov (United States)

2011-12-28

... Activities; Proposed Collection; Comment Request; Contractor Cumulative Claim and Reconciliation (Renewal... identify the Docket ID Number EPA-HQ-OARM-2011-0997, Contractor Cumulative Claim and Reconciliation. Hand... information collection activity or ICR does this apply to? Affected entities: All contractors who have...

The main factor affecting the competitiveness of Contractor Company

Science.gov (United States)

Nurisra; Malahayati, Nurul; Mahmuddin

2018-05-01

Contractor companies must have the competitive advantage to compete in maintaining the survival of the company. Problems arise because quite a lot of advantages can be used and these advantages must be used appropriately to produce competitiveness for the company to continue to compete and to win the competition. This study aims to determine the main factors affecting the competitiveness of medium-class contractors in Banda Aceh. Data collection was obtained through questionnaires distributed to 31 middle-class contractors in Banda Aceh. Data processing and analysis is done by using descriptive analysis. Based on the result of descriptive analysis, it can be concluded that the most important competitiveness factor with a mean score value 4.52 is the relationship, and the factor that has the highest mean score value is the relationship with the government of 4.97, while the result of the ranking analysis is obtained 25 factor that is critical to the competitiveness of medium-class contractors in Banda Aceh.

ACED Federal Grant Contractor Tracking

Data.gov (United States)

Allegheny County / City of Pittsburgh / Western PA Regional Data Center — Dataset includes grant, project, and contractor awarded which are tracked for ensuring Davis-Bacon Act compliance where applicable. The 1931 Davis-Bacon Act...

Construction Manager or General Contractor?

Science.gov (United States)

McKinley, John

1991-01-01

Unlike the general contractor approach, the construction management firm acts on behalf of the school district in school construction. Examines the development and nature of construction management, and cites its advantages and disadvantages. (MLF)

Final Report for the Restart of the Waste Characterization, Reduction and Repackaging Facility (WCRRF) Contractor Readiness Assessment (CRA)

Energy Technology Data Exchange (ETDEWEB)

Stephens, Gregory Mark [Los Alamos National Lab. (LANL), Los Alamos, NM (United States)

2017-02-22

The Los Alamos National Laboratory (LANL or Laboratory) Contractor Readiness Assessment (CRA) required for restart of the Technical Area (TA) 50 Waste Characterization, Reduction, and Repackaging Facility (WCRRF) for remediated nitrate salt (RNS) waste operations was performed in compliance with the requirements of Department of Energy (DOE) Order (O) 425.1D, Verification of Readiness to Start Up or Restart Nuclear Facilities, and LANL procedure FSD-115-001, Verification of Readiness to Start Up or Restart LANL Nuclear Facilities, Activities, and Operations.

Drawing the critical distinction between independent contractors and permanent employees : the tax implications

Energy Technology Data Exchange (ETDEWEB)

Bodie, J.S.; Haymour, J. [Fraser Milner, Calgary, AB (Canada)

1999-10-01

The many factors that should be considered when distinguishing between an independent contractor and an employee from the perspective of tax laws were discussed. Some of the major areas where disputes regarding relationships between the employee and the independent contractor arise were reviewed with particular emphasis on some of the dangers associated with a change in characterization of these types of relationships. Ways in which to guard against these dangers were also presented. The courts have established the following four tests to determine a contractor`s status: (1) the control test, (2) the economic reality test, (3) the business integration test, and (4) the ownership of tools test. The control tests looks to the degree of control that an employer/recipient of services possesses over the work that is to be performed. The economic reality test looks to whether the contractor is actually in business for himself and is risking a loss. The business integration test examines the relationship between employer and contractor in terms of how economically dependent the contractor is on the employer and whether the task the contractor carries on forms an integral part of the business of the employer. The last test examines who owns the tools used by the contractor to carry out his duties. This presentation also reviewed how employers and contractors are responsible for adhering to Revenue Canada tax laws and certain liabilities regarding income taxes, Employment Insurance (EI) premiums, Canada Pension Plan (CPP) contributions and other amounts.

76 FR 20661 - Agency Information Collection Activities; Proposed Collection; Comment Request; Contractor...

Science.gov (United States)

2011-04-13

... Activities; Proposed Collection; Comment Request; Contractor Conflicts of Interest AGENCY: Environmental....regulations.gov . Title: Contractor Conflicts of Interest. ICR numbers: EPA ICR No. 1550.09, OMB Control No... control numbers in certain EPA regulations is consolidated in 40 CFR part 9. Abstract: EPA contractors...

78 FR 79692 - Clean Water Act; Contractor Access to Confidential Business Information

Science.gov (United States)

2013-12-31

... ENVIRONMENTAL PROTECTION AGENCY [FRL-9904-94-OW] Clean Water Act; Contractor Access to... Transfer of Confidential Business Information to Contractor, Subcontractors, and Consultants. SUMMARY: The... contractors listed below require access to CBI submitted to EPA under Section 308 of the Clean Water Act (CWA...

Contingency Contractor Optimization Phase 3 Sustainment Database Design Document - Contingency Contractor Optimization Tool - Prototype

Energy Technology Data Exchange (ETDEWEB)

Frazier, Christopher Rawls; Durfee, Justin David; Bandlow, Alisa; Gearhart, Jared Lee; Jones, Katherine A

2016-05-01

The Contingency Contractor Optimization Tool – Prototype (CCOT-P) database is used to store input and output data for the linear program model described in [1]. The database allows queries to retrieve this data and updating and inserting new input data.

Representation of a Method for Identification of the Best Safe Contractors by Fuzzy Input Efficiency Profiling and AHP

Directory of Open Access Journals (Sweden)

F. Taheri

2011-04-01

Full Text Available Background and Aims Health, Safety and Environment (HSE performance measurement of the contractors and identification of the best ones can make a perception of the past changes in their HSE performance. Consequently, this may motivate them and provide an opportunity to improve their quality of services. The aim of this study is to rank the contractor-companies of one of the Iranian steel manufacturing companies considering their safety behavior and also to determine the best combination of contractors-companies.   Methods safety behavior sampling method used to determine the status of unsafe acts. The fuzzy efficiency numbers of each input were ranked by Chen & Klein method. To obtain a final ranking AHP was applied. The obtained rankings by FIEP-AHP were compared to the ranking of DEA.   Results Results indicated that the most frequent unsafe behaviors were related to not-using or miss-using the PPE, using broken tools and inappropriate working condition respectively. A significant relationship between experience, education and age with safety behaviors was obtained (p<0.05. Results showed that companies’ number 2 and 6 had respectively the best and worst ranks.   Conclusion Because FIEP increases the power of recognition especially when the number of DMUs is lower than inputs and outputs, it can be suggested as an appropriate model for determining the best contractor companies.

77 FR 13153 - Information Collection; NASA Contractor Financial Management Reports

Science.gov (United States)

2012-03-05

..., [email protected] . SUPPLEMENTARY INFORMATION: I. Abstract The NASA Contractor Financial Management... NATIONAL AERONAUTICS AND SPACE ADMINISTRATION [Notice 12-019] Information Collection; NASA Contractor Financial Management Reports AGENCY: National Aeronautics and Space Administration (NASA). ACTION...

48 CFR 307.108-70 - Telecommuting of contractor employees.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 4 2010-10-01 2010-10-01 false Telecommuting of... Telecommuting of contractor employees. (a) SOWs/PWSs shall permit offerors or contractors to specify their own... telecommuting) for any part of an SOW/PWS, after determining that the work or any portion thereof must be...

23 CFR 635.110 - Licensing and qualification of contractors.

Science.gov (United States)

2010-04-01

... licensing contractors, who may bid for, be awarded, or perform Federal-aid highway contracts, shall be... competition, to prevent submission of a bid by, or to prohibit the consideration of a bid submitted by, any...) No contractor shall be required by law, regulation, or practice to obtain a license before submission...

Prototypical Consolidation Demonstration Project: Final report

International Nuclear Information System (INIS)

Gili, J.A.; Poston, V.K.

1993-11-01

This is the final report of the Prototypical Consolidation Demonstration Project, which was funded by the US Department of Energy's Office of Civilian Radioactive Waste Management. The project had two objectives: (a) to develop and demonstrate a prototype of production-scale equipment for the dry, horizontal consolidation and packaging of spent nuclear fuel rods from commercial boiling water reactor and pressurized water reactor fuel assemblies, and (b) to report the development and demonstration results to the US Department of Energy, Idaho Operations Office. This report summarizes the activities and conclusions of the project management contractor, EG ampersand G Idaho, Inc., and the fabrication and testing contractor, NUS Corporation (NUS). The report also presents EG ampersand G Idaho's assessments of the equipment and procedures developed by NUS

Contingency Contractor Optimization Phase 3 Sustainment Third-Party Software List - Contingency Contractor Optimization Tool - Prototype

Energy Technology Data Exchange (ETDEWEB)

Durfee, Justin David; Frazier, Christopher Rawls; Bandlow, Alisa

2016-05-01

The Contingency Contractor Optimization Tool - Prototype (CCOT-P) requires several third-party software packages. These are documented below for each of the CCOT-P elements: client, web server, database server, solver, web application and polling application.

Selection of disposal contractor by multi criteria decision making methods

Directory of Open Access Journals (Sweden)

Cenker Korkmazer

2016-08-01

Full Text Available Hazardous waste is substance that threaten people and environment in case of improper storage, disposal and transport due to its concentration, physical and chemical properties. Companies producing hazardous waste as a result of several activities mostly do not have any own disposal facilities. In addition, they do not pay attention enough to determine the right contractor as a disposal facility. On the other hand, there are various qualitative and quantitative criteria affecting the selection of the contractor and conflicting with each other. The aim of the performed study is to assist one of these companies producing hazardous waste in the selection of the best contractor that eliminates hazardous waste economic and harmless way. In the study, contractor weights in percentage is calculated by using Analytic Network Process (ANP as one of the multi-criteria decision making (MCDM methods and widely used in the literature which considers both qualitative and quantitative criteria. In the next step, by the help of the mathematical model, contractors that will be given which type of hazardous waste are identified. This integrated approach can be used as a guide for similar firms.

Innovation Strategy in Slovak Forest Contractor Firms—A SWOT Analysis

Directory of Open Access Journals (Sweden)

Martina Štěrbová

2016-05-01

Full Text Available The aim of the study is to determine the innovation strategy of contractor firms in the Slovak forestry service sector in the area of further innovation activities development. The strategy identification was based on the analysis of the strengths, weaknesses, opportunities and threats in this sector. The results indicate that weaknesses of contractor firms exceed their strengths and, considering the degree and importance of their impact, opportunities exceed identified threats. Based on these findings revealing the relations in the area of innovation activities of forestry service contractors, the “Strategy of Partnership” was suggested as the most suitable type of strategy. It can be concluded that such a form of grouping cooperation brings many benefits to contractors in the form of information availability, guidance, training, and management of conflicts, risks and uncertainty, which are associated with the innovation process.

77 FR 17098 - Proposed Extension of Existing Information Collection; Independent Contractor Registration and...

Science.gov (United States)

2012-03-23

... Information Collection; Independent Contractor Registration and Identification AGENCY: Mine Safety and Health...-00040, Independent Contractor Register. OMB last approved this information collection request (ICR) on...); or 202-693-9441 (facsimile). SUPPLEMENTARY INFORMATION: I. Background Independent contractors...

75 FR 43166 - Information Collection; Central Contractor Registration Requirements for Prime Grant Recipients

Science.gov (United States)

2010-07-23

...] Information Collection; Central Contractor Registration Requirements for Prime Grant Recipients AGENCY: Office... information collection requirement regarding Central Contractor Registration Requirements for Prime Grant... for the proper performance of functions of the Central Contractor Registration Requirements for Prime...

EDRP public local inquiry, UKAEA/BNFL precognition on: Contractor accommodation

International Nuclear Information System (INIS)

Scott, W.

1986-01-01

The availability of accommodation for contractors working on the proposed EDRP at Dounreay is discussed. It is predicted that the contractors could be accommodated without the need for special arrangement and with no adverse effect on the tourist industry. (U.K.)

Drawing the critical distinction between independent contractors and permanent employees : the tax implications

International Nuclear Information System (INIS)

Bodie, J.S.; Haymour, J.

1999-01-01

The many factors that should be considered when distinguishing between an independent contractor and an employee from the perspective of tax laws were discussed. Some of the major areas where disputes regarding relationships between the employee and the independent contractor arise were reviewed with particular emphasis on some of the dangers associated with a change in characterization of these types of relationships. Ways in which to guard against these dangers were also presented. The courts have established the following four tests to determine a contractor's status: (1) the control test, (2) the economic reality test, (3) the business integration test, and (4) the ownership of tools test. The control tests looks to the degree of control that an employer/recipient of services possesses over the work that is to be performed. The economic reality test looks to whether the contractor is actually in business for himself and is risking a loss. The business integration test examines the relationship between employer and contractor in terms of how economically dependent the contractor is on the employer and whether the task the contractor carries on forms an integral part of the business of the employer. The last test examines who owns the tools used by the contractor to carry out his duties. This presentation also reviewed how employers and contractors are responsible for adhering to Revenue Canada tax laws and certain liabilities regarding income taxes, Employment Insurance (EI) premiums, Canada Pension Plan (CPP) contributions and other amounts

Drawing the critical distinction between independent contractors and permanent employees : the tax implications

Energy Technology Data Exchange (ETDEWEB)

Bodie, J.S.; Haymour, J. [Fraser Milner, Calgary, AB (Canada)

1999-07-01

The many factors that should be considered when distinguishing between an independent contractor and an employee from the perspective of tax laws were discussed. Some of the major areas where disputes regarding relationships between the employee and the independent contractor arise were reviewed with particular emphasis on some of the dangers associated with a change in characterization of these types of relationships. Ways in which to guard against these dangers were also presented. The courts have established the following four tests to determine a contractor's status: (1) the control test, (2) the economic reality test, (3) the business integration test, and (4) the ownership of tools test. The control tests looks to the degree of control that an employer/recipient of services possesses over the work that is to be performed. The economic reality test looks to whether the contractor is actually in business for himself and is risking a loss. The business integration test examines the relationship between employer and contractor in terms of how economically dependent the contractor is on the employer and whether the task the contractor carries on forms an integral part of the business of the employer. The last test examines who owns the tools used by the contractor to carry out his duties. This presentation also reviewed how employers and contractors are responsible for adhering to Revenue Canada tax laws and certain liabilities regarding income taxes, Employment Insurance (EI) premiums, Canada Pension Plan (CPP) contributions and other amounts.

32 CFR 806b.6 - Systems of records operated by a contractor.

Science.gov (United States)

2010-07-01

... 32 National Defense 6 2010-07-01 2010-07-01 false Systems of records operated by a contractor... ADMINISTRATION PRIVACY ACT PROGRAM Overview of the Privacy Act Program § 806b.6 Systems of records operated by a contractor. Contractors who are required to operate or maintain a Privacy Act system of records by contract...

Integrating Contractors into the Logistics Force

National Research Council Canada - National Science Library

Terrell, Ronald G

2006-01-01

... a panacea. For a combatant commander to effectively integrate them with his military force requires an understanding of the operational environment, contractor capabilities, acceptable levels of risk...

Private Military and Security Contractors

DEFF Research Database (Denmark)

In Private Military and Security Contractors: Controlling the Corporate Warrior a multinational team of 16 scholars and a practitioner from political science, sociology, and law address a developing phenomenon: controlling the use of privatized force by states in international politics. Robust...

78 FR 23935 - Federal Acquisition Regulation; Information Collection; Contractor Use of Interagency Fleet...

Science.gov (United States)

2013-04-23

...; Information Collection; Contractor Use of Interagency Fleet Management System Vehicles AGENCY: Department of... previously approved information collection requirement concerning contractor use of interagency fleet... Collection 9000- 0032, Contractor Use of Interagency Fleet Management System Vehicles, by any of the...

48 CFR 252.237-7023 - Continuation of Essential Contractor Services.

Science.gov (United States)

2010-10-01

... provide a written plan for continuing the performance of essential contractor services identified in...; and (v) The approach for communicating expectations to contractor employees regarding their roles and... or other designated representative as expeditiously as possible and use its best efforts to cooperate...

The Inadequacy of Existing Far Provisions to Ensure Contractor Environmental Compliance

National Research Council Canada - National Science Library

MacDonald, Edward

1997-01-01

This thesis focuses on situations where the obligation is on the contractor, and examines the existing FAR provisions and clauses to explore whether they are adequate to ensure government contractor...

78 FR 60169 - Federal Acquisition Regulation; Pilot Program for Enhancement of Contractor Employee...

Science.gov (United States)

2013-09-30

... 9000-AM56 Federal Acquisition Regulation; Pilot Program for Enhancement of Contractor Employee... program enhancing whistleblower protections for contractor employees. DATES: Effective: September 30, 2013... contractor employees at FAR subpart 3.9. The pilot program is mandated by section 828, entitled ``Pilot...

Site contractor participation in the DOE SWEIS process at Los Alamos, New Mexico

Energy Technology Data Exchange (ETDEWEB)

Pendergrass, A.; Garvey, D.

1997-12-01

The U.S. Department of Energy (DOE) prepares site-wide environmental impact statements (SWEIS) on sites that are to remain in operation in order to provide an estimate of the cumulative environmental impacts from projected future operations at the site. DOE has relied on outside contractors rather than the site management and operating (M&O) contractors to prepare EISs, in order to preclude the potential for conflict of interest. The site M&O contractors, who know the potential for conflict of interest. The site M&O contractors, who know the site best and are most familiar with existing information, are critical support for the contractor. The University of California (UC) is the site M&O contractor for Los Alamos National Laboratory (LANL) in Los Alamos, NM. The role of LANL (UC) personnel in DOE`s preparation process for the LANL SWEIS is described. 3 refs.

Beyond the design fix - New industrialisation in contractor's supplier relationships

DEFF Research Database (Denmark)

Koch, Christian; Frödell, M.; Josephson, P.E.

2010-01-01

by the Erabuild program, this paper presents 3 cases of long term transformation of contractor- supplier relations as general contractors outsource and commence professionalising purchasing moving it from project purchasing into strategic purchasing. It is suggested that “new industrialisation” is a long term...

48 CFR 509.308-1 - Testing performed by the contractor.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 4 2010-10-01 2010-10-01 false Testing performed by the... ADMINISTRATION COMPETITION AND ACQUISITION PLANNING CONTRACTOR QUALIFICATIONS First Article Testing and Approval 509.308-1 Testing performed by the contractor. In FSS solicitations and contracts that will require...

Contractor-style tunnel cost estimating

International Nuclear Information System (INIS)

Scapuzzi, D.

1990-06-01

Keeping pace with recent advances in construction technology is a challenge for the cost estimating engineer. Using an estimating style that simulates the actual construction process and is similar in style to the contractor's estimate will give a realistic view of underground construction costs. For a contractor-style estimate, a mining method is chosen; labor crews, plant and equipment are selected, and advance rates are calculated for the various phases of work which are used to determine the length of time necessary to complete each phase of work. The durations are multiplied by the cost or labor and equipment per unit of time and, along with the costs for materials and supplies, combine to complete the estimate. Variations in advance rates, ground support, labor crew size, or other areas are more easily analyzed for their overall effect on the cost and schedule of a project. 14 figs

Increasing Prediction the Original Final Year Project of Student Using Genetic Algorithm

Science.gov (United States)

Saragih, Rijois Iboy Erwin; Turnip, Mardi; Sitanggang, Delima; Aritonang, Mendarissan; Harianja, Eva

2018-04-01

Final year project is very important forgraduation study of a student. Unfortunately, many students are not seriouslydidtheir final projects. Many of studentsask for someone to do it for them. In this paper, an application of genetic algorithms to predict the original final year project of a studentis proposed. In the simulation, the data of the final project for the last 5 years is collected. The genetic algorithm has several operators namely population, selection, crossover, and mutation. The result suggest that genetic algorithm can do better prediction than other comparable model. Experimental results of predicting showed that 70% was more accurate than the previous researched.

78 FR 4425 - Notice of Proposed Information Collection: Comment Request; Multifamily Contractor's Mortgagor's...

Science.gov (United States)

2013-01-22

... Information Collection: Comment Request; Multifamily Contractor's Mortgagor's Cost Breakdowns and... comments on the subject proposal. Contractors use the form HUD-2328 to establish a schedule of values of construction items on which the monthly advances or mortgage proceeds are based. Contractors use the form HUD...

76 FR 68017 - Federal Acquisition Regulation; Preventing Personal Conflicts of Interest for Contractor...

Science.gov (United States)

2011-11-02

... Contractor Employees Performing Acquisition Functions AGENCIES: Department of Defense (DoD), General Services... personal conflicts of interest by employees of Government contractors as required by statute. DATES... clause for future orders. In the event that a contractor refuses to accept such a modification, the...

75 FR 55671 - Financial Assistance Use of Universal Identifier and Central Contractor Registration

Science.gov (United States)

2010-09-14

... of Universal Identifier and Central Contractor Registration AGENCY: Office of Federal Financial...) numbers and maintain current registrations in the Central Contractor Registration (CCR) database. An... CONTRACTOR REGISTRATION Sec. Subpart A--General 25.100 Purposes of this part. 25.105 Types of awards to which...

Contractors In The Theater: Implications For Joint Operational Planning And Execution

National Research Council Canada - National Science Library

Binder, Jeanne

2003-01-01

The use of contractors in the theater of operations is nothing new. However downsizing efforts and outsourcing as well as the increasing complexity of military equipment has increased military reliance on contractors...

Contractor Development Models for Promoting Sustainable Building – a case for developing management capabilities of contractors

CSIR Research Space (South Africa)

Dlungwana, Wilkin S

2004-11-01

Full Text Available Construction industry and indeed all small and medium-sized contractors play a significant socio-economic role in the developing countries. This paper highlights the importance of promoting sustainable building through the implementation...

48 CFR 2052.209-72 - Contractor organizational conflicts of interest.

Science.gov (United States)

2010-10-01

... conflicts of interest. 2052.209-72 Section 2052.209-72 Federal Acquisition Regulations System NUCLEAR... Clauses 2052.209-72 Contractor organizational conflicts of interest. As prescribed at 2009.570-5(a) and..., contracts, and simplified acquisitions of the types described; 2009.570-4(b): Contractor Organizational...

48 CFR 252.247-7016 - Contractor liability for loss or damage.

Science.gov (United States)

2010-10-01

... the Contractor's negligence, indemnification shall be at a rate not to exceed sixty cents per pound per article. (ii) Negligent damage. When loss or damage is caused by the negligence of the Contractor...

Military Contractors - Too Much Dependence

Science.gov (United States)

2008-03-19

promotes integrity, physical strength, health, unity, cooperation and teamwork. It combats stereotyping and sexual harassment. It fosters in its...weeklyreport108-000001337290&type= toc &num=115&; accessed 15 Jan 2008. 20 U.S. Department of the Army, Contractors on the Battlefield, Field Manual 3

Final audit report of remedial action construction at the UMTRA project site Rifle, Colorado. Rev. 1

International Nuclear Information System (INIS)

1997-01-01

This final audit report summarizes the assessments performed by the U.S. Department of Energy (DOE) Environmental Restoration Division (ERD) and its Technical Assistance Contractor (TAC) of remedial action compliance with approved plans, specifications, standards, and 40 CFR Part 192 at the Rifle, Colorado, Uranium Mill Tailings Remedial Action (UMTRA) Project site. Remedial action construction was directed by the Remedial Action Contractor (RAC)

Critical Electronic Data Loss Perceptions of United States Military Contractors

Science.gov (United States)

Singletary, Tod J.

2017-01-01

The United States Military has become increasingly dependent upon technology to meet its mission objectives with a consequence being greater dependence on civilian defense contractors to provide specialized services in support of high-tech mission requirements. Modern military defense contractors have also become dependent upon reliable and secure…

48 CFR 52.209-3 - First Article Approval-Contractor Testing.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false First Article Approval... Clauses 52.209-3 First Article Approval—Contractor Testing. As prescribed in 9.308-1 (a) and (b), insert the following clause: First Article Approval—Contractor Testing (SEP 1989) [Contracting Officer shall...

Appeals - Redetermination by a Medicare Contractor

Data.gov (United States)

U.S. Department of Health & Human Services — A redetermination is an examination of a claim by the fiscal intermediary (FI), carrier, or Medicare Administrative Contractor (MAC) personnel who are different from...

Human Resources Staffing Plan for the Tank Farm Contractor

International Nuclear Information System (INIS)

BOSLEY, J.W.

2000-01-01

The Human Resources Staffing Plan quantified the equivalent staffing needs required for the Tank Farm Contractor (TFC) and its subcontractors to execute the readiness to proceed baseline between FY 2000-2008. The TFC staffing needs were assessed along with the staffings needs of Fluor Hanford and the privatization contractor. The plan then addressed the staffing needs and recruitment strategies required to execute the baseline

Hanford Site Welding Program Successfully Providing A Single Site Function For Use By Multiple Contractors

International Nuclear Information System (INIS)

Cannell, G.R.

2009-01-01

The Department of Energy, Richland Operations (DOE-RL) recently restructured its Hanford work scope, awarding two new contracts over the past several months for a total of three contracts to manage the sites cleanup efforts. DOE-RL met with key contractor personnel prior to and during contract transition to ensure site welding activities had appropriate oversight and maintained code compliance. The transition also provided an opportunity to establish a single site-wide function that would provide welding and materials engineering services to the Hanford site contractors: CH2M HILL Plateau Remediation Company (CHPRC); Mission Support Alliance (MSA); Washington River Protection Solutions (WRPS); and Washington Closure Hanford (WCH). Over the years, multiple and separate welding programs (amongst the several contractors) existed at the Hanford site leading to inefficiencies resulting from duplication of administrative efforts, maintenance of welding procedures, welder performance certifications, etc. The new, single program eliminates these inefficiencies. The new program, co-managed by two of the sites' new contractors, the CHPRC ('owner' of the program and responsible for construction welding services) and the MSA (provides maintenance welding services), provides more than just the traditional construction and maintenance welding services. Also provided, are welding engineering, specialty welding development/qualification for the closure of radioactive materials containers and materials evaluation/failure analysis. The following describes the new Hanford site welding program.

Application of integrated fuzzy VIKOR & AHP methodology to contractor ranking

Directory of Open Access Journals (Sweden)

Mohamad Rahim Ramezaniyan

2012-08-01

Full Text Available Contractor selection is a critical activity, which plays an important role in the overall success of any construction project. The implementation of fuzzy multiple criteria decision attribute (MCDA in selecting contractors has the advantage of rendering subjective and implicit decision making more objective and transparent. An additional merit of fuzzy MCDA is the ability to accommodate quantitative and qualitative information. In this paper, an integrated VIKOR–AHP methodology is proposed to make a selection among the alternative contractors in one of Iranian construction industry projects. In the proposed methodology, the weights of the selection criteria are determined by fuzzy pairwise comparison matrices of AHP.

48 CFR 836.501 - Performance of work by the contractor.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Performance of work by the... Performance of work by the contractor. The contracting officer shall insert the clause at 852.236-72, Performance of work by the contractor, in solicitations and contracts for construction that contain the FAR...

48 CFR 9.308-1 - Testing performed by the contractor.

Science.gov (United States)

2010-10-01

... the contractor. (a)(1) The contracting officer shall insert the clause at 52.209-3, First Article... it is intended that the contract require (i) first article approval and (ii) that the contractor be... produce the first article and the production quantity at the same facility, the contracting officer shall...

76 FR 37353 - Federal Acquisition Regulation; Submission for OMB Review; Contractor Business Ethics Compliance...

Science.gov (United States)

2011-06-27

...; Submission for OMB Review; Contractor Business Ethics Compliance Program and Disclosure Requirements AGENCIES... contractor business ethics compliance program and disclosure requirements. Public comments are particularly... Information Collection 9000- 0164, Contractor Business Ethics Compliance Program and Disclosure Requirements...

48 CFR 36.501 - Performance of work by the contractor.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Performance of work by the... Performance of work by the contractor. (a) To assure adequate interest in and supervision of all work involved... contracting officer shall insert the clause at 52.236-1, Performance of Work by the Contractor, in...

76 FR 73564 - Federal Acquisition Regulation; Updates to Contract Reporting and Central Contractor Registration

Science.gov (United States)

2011-11-29

... Federal Acquisition Regulation; Updates to Contract Reporting and Central Contractor Registration AGENCIES... Procurement Data System (FPDS). Additionally, changes are proposed for the clauses requiring contractor registration in the Central Contractor Registration (CCR) database and DUNS number reporting. DATES: Interested...

Farm Building Contractors and Manufacturers: Their Role in Midwest Farm Construction

Science.gov (United States)

Lyle Solverson; David C. Baumgartner

1974-01-01

Describes and analyzes the activities of farm building contractors and manufacturers in Illinois, Indiana, Iowa, and Missouri. Contractors and manufacturers are setting the trend in the farm building market in terms of building type and size and materials used.

Fourteenth annual report radiation exposures for DOE and DOE contractor employees - 1981

International Nuclear Information System (INIS)

1983-03-01

All Department of Energy (DOE) and DOE contractors are required by DOE Order 5484.1, Chapter IV, to submit occupational exposure records to a central repository. The data required includes a summary of whole-body exposures to ionizing radiation, a summary of internal depositions of radioactive materials above specified limits, and occupational exposure reports for terminating employees. This report is a summary of the data submitted by DOE and DOE contractors for 1981. A total of 82,873 DOE and DOE contractor employees were monitored for whole-body ionizing radiation exposures in 1981. In addition to the employees, 84,343 visitors were monitored. Of all employees monitored, 54.43% received a dose equivalent that was less than measurable, 44.04% a measurable exposure less than 1 rem, and 1.53% an exposure granter than 1 rem. the exposure received by 88.14% of the visitors to DOE facilities was less than measurable. Only 11.85% of the visitors received a measurable exposure less than 1 rem, and 0.0% of the visitors received an exposure greater than 1 rem. No employees or visitors received a dose equivalent greater than 5 rem. The collective dose equivalent for DOE and DOE contractors employees was 6,902 person-rem. The collective dose equivalent for visitors was 579 person-rem. The total dose equivalent for employees and visitors combined was 7,481 person-rem. The average dose equivalent for all individuals (employees and visitors) monitored was 45 mrem and the average dose equivalent for all individuals who received a measurable exposure was 157 mrem. The highest average dose equivalent was observed for employees monitored at fuel processing facilities (342 mrem) and the lowest among visitors (7 mrem) to DOE facilities. These averages are significantly less than the DOE 5-rem/year radiation protection standard for whole-body exposures

Short communication: final year students' deficits in physical examination skills performance in Germany.

Science.gov (United States)

Krautter, Markus; Diefenbacher, Katja; Koehl-Hackert, Nadja; Buss, Beate; Nagelmann, Lars; Herzog, Wolfgang; Jünger, Jana; Nikendei, Christoph

2015-01-01

The physical examination of patients is an important diagnostic competence, but little is known about the examination skills of final-year medical students. To investigate physical examination skills of final-year medical students. In a cross-sectional study, 40 final-year students were asked to perform a detailed physical examination on standardized patients. Their performances were video-recorded and rated by independent video assessors. Video ratings showed a mean success rate of 40.1 % (SD 8.2). As regards accompanying doctor-patient communication, final-year students achieved a mean of no more than 36.7 % (SD 8.9) in the appropriate use of the corresponding communication items. Our study revealed severe deficits among final-year medical students in performing a detailed physical examination on a standardized patient. Thus, physical examination skills training should aim to improve these deficits while also paying attention to communicative aspects. Copyright © 2015. Published by Elsevier GmbH.

77 FR 14490 - Defense Federal Acquisition Regulation Supplement: Alleged Crimes By or Against Contractor...

Science.gov (United States)

2012-03-12

... Federal Acquisition Regulation Supplement: Alleged Crimes By or Against Contractor Personnel (DFARS Case... (DFARS) to expand coverage on contractor requirements and responsibilities relating to alleged crimes by or against contractor personnel. DATES: Comment Date: Comments on the proposed rule should be...

77 FR 59339 - Contractor Qualifications

Science.gov (United States)

2012-09-27

... DEPARTMENT OF DEFENSE Defense Acquisition Regulations System 48 CFR Part 209 Contractor Qualifications CFR Correction In Title 48 of the Code of Federal Regulations, Chapter 2 (Parts 201-299), revised as of October 1, 2011, on page 55, in section 209.104-70, paragraph (a) is amended by revising the...

Final-year student nurses??? perceptions of role transition

OpenAIRE

Doody, Owen; Tuohy, Dympna; Deasy, Christine

2012-01-01

peer-reviewed Role transition can be both challenging and exciting. This study presents the findings of phase one of a two-part study conducted by Deasy et al (2011), which explored final-year student nurses??? (n=116) perceptions and expectations of role transition. The students were registered on four-year BSc nursing programmes at an Irish university. Data was analyzed using SPSS (version 16). A response rate of 84% was achieved. Over half of respondents said they were adequately ...

Defense Primer: DOD Contractors

Science.gov (United States)

2017-02-10

functions, from intelligence analysis or software development to landscaping or food service. Why does DOD use individual contractors? Going back to...that provide professional services, from research to management support. The bulk of contractors—more than 70%—provide products, and these include...10 U.S.C. Part IV: Service, Supply, and Procurement. CRS Products CRS In Focus IF10548, Defense Primer: U.S. Defense Industrial Base, by Daniel

Fiscal year 1999 Battelle performance evaluation and fee agreement

Energy Technology Data Exchange (ETDEWEB)

DAVIS, T.L.

1998-10-22

Fiscal Year 1999 represents the third fill year utilizing a results-oriented, performance-based evaluation for the Contractor's operations and management of the DOE Pacific Northwest National Laboratory (here after referred to as the Laboratory). However, this is the first year that the Contractor's fee is totally performance-based utilizing the same Critical Outcomes. This document describes the critical outcomes, objectives, performance indicators, expected levels of performance, and the basis for the evaluation of the Contractor's performance for the period October 1, 1998 through September 30, 1999, as required by Clauses entitled ''Use of Objective Standards of Performance, Self Assessment and Performance Evaluation'' and ''Performance Measures Review'' of the Contract DE-ACO6-76RL01830. Furthermore, it documents the distribution of the total available performance-based fee and the methodology set for determining the amount of fee earned by the Contractor as stipulated within the causes entitled ''Estimated Cost and Annual Fee,'' ''Total Available Fee'' and ''Allowable Costs and Fee.'' In partnership with the Contractor and other key customers, the Department of Energy (DOE) Headquarters (HQ) and Richland Operations Office (RL) has defined four critical outcomes that serve as the core for the Contractor's performance-based evaluation and fee determination. The Contractor also utilizes these outcomes as a basis for overall management of the Laboratory.

Structured Transition of Wind Tunnel Operations Skills from Government-to Contractor-Managed

Science.gov (United States)

Dunn, Steven C.; Schlank, John J.

2010-01-01

In 2004, NASA awarded the Research, Operations, Maintenance, and Engineering (ROME) contract at NASA Langley Research Center to a team led by Jacobs Technology, Inc. A key component of the contract was the transitioning of the five large wind tunnel facilities from NASA managed and NASA or NASA/contractor workforces to fully contractor operated. The contractor would manage daily operations while NASA would continue to develop long-term strategies, make decisions regarding commitment of funds and commitment of facilities, and provide oversight of the contractor's performance. A major challenge would be the transition of knowledge of facility operations and maintenance from the incumbent civil servant workforce to the contractor workforce. While the contract has since been modified multiple times, resulting in a blended NASA/ROME workforce across the facilities, the processes developed and implemented to capture and document facility knowledge from the incumbent subject matter experts, build training and certification programs, and grow individual skills across subject areas and across facilities, are worthy of documentation. This is the purpose of this paper.

48 CFR 1845.7101-5 - Contractor's privileged financial and business information.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor's privileged financial and business information. 1845.7101-5 Section 1845.7101-5 Federal Acquisition Regulations System... 1845.7101-5 Contractor's privileged financial and business information. If a transfer of property...

Fiscal year 1999 Battelle performance evaluation and fee agreement; TOPICAL

International Nuclear Information System (INIS)

DAVIS, T.L.

1998-01-01

Fiscal Year 1999 represents the third fill year utilizing a results-oriented, performance-based evaluation for the Contractor's operations and management of the DOE Pacific Northwest National Laboratory (here after referred to as the Laboratory). However, this is the first year that the Contractor's fee is totally performance-based utilizing the same Critical Outcomes. This document describes the critical outcomes, objectives, performance indicators, expected levels of performance, and the basis for the evaluation of the Contractor's performance for the period October 1, 1998 through September 30, 1999, as required by Clauses entitled ''Use of Objective Standards of Performance, Self Assessment and Performance Evaluation'' and ''Performance Measures Review'' of the Contract DE-ACO6-76RL01830. Furthermore, it documents the distribution of the total available performance-based fee and the methodology set for determining the amount of fee earned by the Contractor as stipulated within the causes entitled ''Estimated Cost and Annual Fee,'' ''Total Available Fee'' and ''Allowable Costs and Fee.'' In partnership with the Contractor and other key customers, the Department of Energy (DOE) Headquarters (HQ) and Richland Operations Office (RL) has defined four critical outcomes that serve as the core for the Contractor's performance-based evaluation and fee determination. The Contractor also utilizes these outcomes as a basis for overall management of the Laboratory

77 FR 10461 - Federal Acquisition Regulation; Unallowability of Costs Associated With Foreign Contractor Excise...

Science.gov (United States)

2012-02-22

... Acquisition Regulation; Unallowability of Costs Associated With Foreign Contractor Excise Tax AGENCIES.... Additionally, the law stipulates that no funds are to be disbursed to any foreign contractor in order to... payment. Additionally, the law stipulates that no funds are to be disbursed to any foreign contractor in...

76 FR 52378 - Privacy Act; System of Records: State-76, Personal Services Contractor Records

Science.gov (United States)

2011-08-22

... Services Contractor Records SUMMARY: Notice is hereby given that the Department of State proposes to create a new system of records, Personal Services Contractor Records, State-76, pursuant to the provisions... July 20, 2011. It is proposed that the new system be named ``Personal Services Contractor Records.'' It...

48 CFR 225.7303-1 - Contractor sales to other foreign customers.

Science.gov (United States)

2010-10-01

... foreign customers. 225.7303-1 Section 225.7303-1 Federal Acquisition Regulations System DEFENSE... for Foreign Military Sales 225.7303-1 Contractor sales to other foreign customers. If the contractor has made sales of the item required for the foreign military sale to foreign customers under...

Development and validation of a strategic repositioning model for defense and aerospace contractors

Science.gov (United States)

Bers, John A.

Strategic repositioning refers to the organized efforts of defense contractors to "reposition" a technology that they have developed for a defense sector customer into a civilian or commercial market. The strategic repositioning model developed here is a structural model: it seeks to isolate the factors that influence choice of strategy, which in turn influences the organization's performance. The model draws from the prior experience of contractors (through interviews and surveys) and companies in other sectors (through a review of the relevant published research). (1) Over all, the model accounted for 55% of the variance in financial performance of the sample and 35% for the underlying population. (2) Key success factors include a rigorous planning process, a target market in the growth (vs. incubation) stage, a priority on market leadership as well as financial return, the ability to operate in an ambiguous business environment, and a relatively short time horizon but strong corporate support. (3) The greatest challenges that a contractor is likely to encounter are understanding his new customers' buying practices, strong competition, and adapting his technology to their needs and price expectations. (4) To address these issues contractors often involve partners in their entry strategy, but partnerships of equals tend to be more difficult to bring off than direct entry strategies. (5) The two major target market categories--government and commercial--present different challenges. Commercial customers are more likely to resist doing business with the contractor, while contractors entering government and other noncommercial markets are more likely to encounter price resistance, low technical sophistication among customers, and difficulties reaching their customer base. (6) Despite these differences across markets, performance is not influenced by the target market category, nor by the type of product or service or the contractor's functional orientation (marketing

76 FR 13423 - Notice of Submission of Proposed Information Collection to OMB; Contractor's Requisition-Project...

Science.gov (United States)

2011-03-11

... Proposed Information Collection to OMB; Contractor's Requisition--Project Mortgages AGENCY: Office of the.... Contractor's monthly application for distribution of insured mortgage proceeds for construction costs... Following Information Title of Proposal: Contractor's Requisition--Project Mortgages. OMB Approval Number...

Private security and military contractors: A troubling oversight

DEFF Research Database (Denmark)

Swed, Ori; Crosbie, Thomas Alexander

2017-01-01

Though private military and security companies (PMSCs) have been addressed extensively in the literature, little research has been done on the contractors themselves, leaving us in the dark as to who these individuals are. In this article, we focus on the critical case of the United States armed...... and concomitant evolution of the security sector, while noting a new trend that points to the need for moving from the macrosocial to the microsocial level of inquiry. Second, we indicate the challenges contractors pose to the sociological paradigm of military professionalism: These suggest a need to move from...

Contractor Past Performance - Are We There Yet?

National Research Council Canada - National Science Library

Guerrero, Juan

2001-01-01

During the United States federal government acquisition reform movement of the 1990s, the government strongly emphasized the use of past performance information to select contractors in federal procurements...

78 FR 64499 - Federal Acquisition Regulation; Submission for OMB Review; Contractor Use of Interagency Fleet...

Science.gov (United States)

2013-10-29

...; Submission for OMB Review; Contractor Use of Interagency Fleet Management System Vehicles AGENCY: Department... previously approved information collection requirement concerning contractor use of interagency fleet... comments identified by Information Collection 9000- 0032, Contractor Use of Interagency Fleet Management...

Improving UK client-contractor relations

International Nuclear Information System (INIS)

Brant, A.W.

1996-01-01

The client's aim in any decommissioning project is that the originally intended end point is achieved, within budget and on time. The contractor's aim is to have a satisfied client, so that both are happy to work together again, and to have a reasonable return for his efforts. How can these - not incompatible - aims best be achieved? (UK)

Proceedings of the advanced research and technology development direct utilization, instrumentation and diagnostics contractors' review meeting

Energy Technology Data Exchange (ETDEWEB)

Geiling, D.W. (USDOE Morgantown Energy Technology Center, WV (USA)); Goldberg, P.M. (eds.) (USDOE Pittsburgh Energy Technology Center, PA (USA))

1990-01-01

The 1990 Advanced Research and Technology Development (AR TD) Direct Utilization, and Instrumentation and Diagnostics Contractors Review Meeting was held September 16--18, 1990, at the Hyatt at Chatham Center in Pittsburgh, PA. The meeting was sponsored by the US Department of Energy (DOE), Office of Fossil Energy, and the Pittsburgh and Morgantown Energy Technology Centers. Each year the meeting provides a forum for the exchange of information among the DOE AR TD contractors and interested parties. This year's meeting was hosted by the Pittsburgh Energy Technology Center and was attended by 120 individuals from industry, academia, national laboratories, and other governmental agencies. Papers were presented on research addressing coal surface, science, devolatilization and combustion, ash behavior, emission controls for gases particulates, fluid bed combustion and utilization in diesels and turbines. Individual reports are processed separately for the data bases.

75 FR 10267 - Federal Acquisition Regulation; Submission for OMB Review; Contractor Use of Interagency Motor...

Science.gov (United States)

2010-03-05

... ADMINISTRATION [OMB Control No. 9000-0032] Federal Acquisition Regulation; Submission for OMB Review; Contractor... previously approved information collection requirement concerning contractor use of interagency motor pool... contracting officer may authorize cost-reimbursement contractors to obtain, for official purposes only...

77 FR 63835 - Office of the Chief Information Officer; Submission for OMB Review; Temporary Contractor...

Science.gov (United States)

2012-10-17

... of the Chief Information Officer; Submission for OMB Review; Temporary Contractor Information... information collection requirement regarding temporary contractor information worksheet. A notice was... for temporary contractors as a result of the American Recovery and Reinvestment Act of 2009 (Public...

institutional and resource constraints that inhibit contractor ...

African Journals Online (AJOL)

p2333147

Keywords: Institutions; small-scale contractor performance; sugar industry. ABSTRACT ..... diverse cultural settings, women, specifically widowed or single women, have a .... constraints on business growth, such as the work limitations placed.

CONTRACTORS OF SOCIALIZATION AND THEIR INFLUENCE ON SOCIAL PROCESSES

OpenAIRE

Mikhail Yu. POPOV

2016-01-01

This article is devoted to the analysis of an essence of the concept "contractors of socialization" and attempt of definition of its place in structure of sociological knowledge. During the solution of this task the author seeks to define destructive nature of influence of contractors of socialization on formation of the personality both at a stage of primary socialization, and in the course of the entire period of its activity. Inclusion of this term in structure of sociological knowledge, a...

78 FR 13547 - Defense Federal Acquisition Regulation Supplement: Alleged Crimes By or Against Contractor Personnel

Science.gov (United States)

2013-02-28

... Contractor Personnel AGENCY: Defense Acquisition Regulations System, Department of Defense (DoD). ACTION... (FY) 2009 and expand coverage on contractor requirements and responsibilities relating to alleged crimes by or against contractor personnel. DATES: Effective February 28, 2013. FOR FURTHER INFORMATION...

Licensee contractor and vendor inspection status report

International Nuclear Information System (INIS)

1990-10-01

A fundamental premise of the Nuclear Regulatory Commission's (NRC) licensing and inspection program is that licensees are responsible for the proper construction and safe and efficient operation of their nuclear power plants. The total government-industry system for the inspection of commercial nuclear facilities has been designed to provide for multiple levels of inspection and verification. Licensees, contractors, and vendors each participate in a quality verification process in compliance with requirements prescribed by the NRC's rules and regulations (Title 10 Code of Federal Regulations). The NRC performs an overview of the commercial nuclear industry by inspection to determine whether its requirements are being met by licensees and their contractors, while the major inspection effort is performed by the industry within the framework of ongoing quality verification programs

78 FR 6189 - Federal Acquisition Regulation; Unallowability of Costs Associated With Foreign Contractor Excise...

Science.gov (United States)

2013-01-29

... 9000-AM13 Federal Acquisition Regulation; Unallowability of Costs Associated With Foreign Contractor... contractor in order to reimburse the tax imposed (26 U.S.C. 5000C Note). On February 22, 2012, DoD, GSA, and... with the statute, FAR 31.205-41 is amended to inform the Government and contractors that the costs of...

International Markets: Malaysian Construction Contractors and the Stage Theory

Directory of Open Access Journals (Sweden)

Ahmed Awil

2012-11-01

Full Text Available Reduced demand for services, lack of finances for projects and idle resources at homehave resulted in loss of business for Malaysian construction contractors. Among the optionsthat are explored in this paper is internationalisation of services to help the contractorsgainfully employ their resources and diversify their markets. Integration of worldmarkets, faster transportation and improved means of communication have made it possiblefor contractors to undertake work in international markets. It was found that contractorswere motivated to internationalise by need to make the firm a viable one byconsidering the long-term profitability. Reputation and size of the firm were found to befactors that help contractors in winning contracts overseas. Most non-exporters were concernedwith provision of market intelligence and export credit finance. It was found thatproviding relevant market information, accessible to both exporter and non-exporters, canhelp firms make informed decisions. Any assistance provided should match the firm to thestage the firm has reached in exporting

Government/contractor partnerships for continuous improvement. A Goddard Space Flight Center example

Science.gov (United States)

Tagler, Richard C.

1992-01-01

The efforts of a government organization and its major contractors to foster a continuous improvement environment which transcends the traditional government/contractor relationship is discussed. This relationship is aimed at communication, partnership, and trust - creating benefits for all involved.

75 FR 28771 - Federal Acquisition Regulation; FAR Case 2009-027, Personal Identity Verification of Contractor...

Science.gov (United States)

2010-05-24

... Acquisition Regulation; FAR Case 2009-027, Personal Identity Verification of Contractor Personnel AGENCIES... of collecting from contractors all forms of Government provided identification once they are no..., titled Controls Over the Contractor Common Access Card (CAC) Life Cycle, was performed to determine...

77 FR 65927 - 60-Day Notice of Proposed Information Collection: Office of Language Services Contractor...

Science.gov (United States)

2012-10-31

... of Language Services Contractor Application Form ACTION: Notice of request for public comment... Collection: Office of Language Services Contractor Application Form. OMB Control Number: 1405-0191. Type of... become contractors for the U.S. Department of State, Office of Language Services, the information...

78 FR 13394 - 30-Day Notice of Proposed Information Collection: Office of Language Services Contractor...

Science.gov (United States)

2013-02-27

... of Language Services Contractor Application Form ACTION: Notice of request for public comment and...: Title of Information Collection: Office of Language Services Contractor Application Form. OMB Control... States. If candidates successfully become contractors for the U.S. Department of State, Office of...

42 CFR 405.1012 - When CMS or its contractors may be a party to a hearing.

Science.gov (United States)

2010-10-01

... 42 Public Health 2 2010-10-01 2010-10-01 false When CMS or its contractors may be a party to a... Hearings § 405.1012 When CMS or its contractors may be a party to a hearing. (a) CMS and/or one or more of... unrepresented beneficiary. (b) CMS and/or the contractor(s) advises the ALJ, appellant, and all other parties...

Assessing Contractor Capabilities for Streamlined Site Investigations

Science.gov (United States)

The purpose of this document is to familiarize and encourage brownfields decision makers to investigate and employ innovative methods for characterizing their sites, to assist brownfields decision makers in assessing contractors' capabilities.

Safety-Related Contractor Activities at Nuclear Power Plants. New Challenges for Regulatory Oversight

International Nuclear Information System (INIS)

Chockie, Alan

2005-09-01

The use of contractors has been an integral and important part of the design, construction, operation, and maintenance of nuclear power plants. To ensure the safe and efficient completion of contracted tasks, each nuclear plant licensee has developed and refined formal contract management processes to meet their specific needs and plant requirements. Although these contract management processes have proven to be effective tools for the procurement of support and components tailored to the needs of nuclear power plants, contractor-related incidents and accidents have revealed some serious weaknesses with the implementation of these processes. Identifying and addressing implementation problems are becoming more complicated due to organizational and personnel changes affecting the nuclear power industry. The ability of regulators and licensees to effectively monitor and manage the safety-related performance of contractors will likely be affected by forthcoming organization and personnel changes due to: the aging of the workforce; the decline of the nuclear industry; and the deregulation of nuclear power. The objective of this report is to provide a review of current and potential future challenges facing safety-related contractor activities at nuclear power plants. The purpose is to assist SKI in establishing a strategy for the proactive oversight of contractor safety-related activities at Swedish nuclear power plants and facilities. The nature and role of contractors at nuclear plants is briefly reviewed in the first section of the report. The second section describes the essential elements of the contract management process. Although organizations have had decades of experience with the a contract management process, there remain a number of common implantation weaknesses that have lead to serious contractor-related incidents and accidents. These implementation weaknesses are summarized in the third section. The fourth section of the report highlights the

Safety-Related Contractor Activities at Nuclear Power Plants. New Challenges for Regulatory Oversight

Energy Technology Data Exchange (ETDEWEB)

Chockie, Alan [Chockie Group International, Inc., Seattle, WA (United States)

2005-09-15

The use of contractors has been an integral and important part of the design, construction, operation, and maintenance of nuclear power plants. To ensure the safe and efficient completion of contracted tasks, each nuclear plant licensee has developed and refined formal contract management processes to meet their specific needs and plant requirements. Although these contract management processes have proven to be effective tools for the procurement of support and components tailored to the needs of nuclear power plants, contractor-related incidents and accidents have revealed some serious weaknesses with the implementation of these processes. Identifying and addressing implementation problems are becoming more complicated due to organizational and personnel changes affecting the nuclear power industry. The ability of regulators and licensees to effectively monitor and manage the safety-related performance of contractors will likely be affected by forthcoming organization and personnel changes due to: the aging of the workforce; the decline of the nuclear industry; and the deregulation of nuclear power. The objective of this report is to provide a review of current and potential future challenges facing safety-related contractor activities at nuclear power plants. The purpose is to assist SKI in establishing a strategy for the proactive oversight of contractor safety-related activities at Swedish nuclear power plants and facilities. The nature and role of contractors at nuclear plants is briefly reviewed in the first section of the report. The second section describes the essential elements of the contract management process. Although organizations have had decades of experience with the a contract management process, there remain a number of common implantation weaknesses that have lead to serious contractor-related incidents and accidents. These implementation weaknesses are summarized in the third section. The fourth section of the report highlights the

Energy Management in Small Commercial Buildings: A Look at How HVAC Contractors Can Deliver Energy Efficiency to this Segment

Energy Technology Data Exchange (ETDEWEB)

Hult, Erin; Granderson, Jessica; Mathew, Paul

2014-07-01

While buildings smaller than 50,000 sq ft account for nearly half of the energy used in US commercial buildings, energy efficiency programs to-date have primarily focused on larger buildings. Interviews with stakeholders and a review of the literature indicate interest in energy efficiency from the small commercial building sector, provided solutions are simple and low-cost. An approach to deliver energy management to small commercial buildings via HVAC contractors and preliminary demonstration findings are presented. The energy management package (EMP) developed includes five technical elements: benchmarking and analysis of monthly energy use; analysis of interval electricity data (if available), a one-hour onsite walkthrough, communication with the building owner, and checking of results. This data-driven approach tracks performance and identifies low-cost opportunities, using guidelines and worksheets for each element to streamline the delivery process and minimize the formal training required. This energy management approach is unique from, but often complementary to conventional quality maintenance or retrofit-focused programs targeting the small commercial segment. Because HVAC contractors already serve these clients, the transaction cost to market and deliver energy management services can be reduced to the order of hundreds of dollars per year. This business model, outlined briefly in this report, enables the offering to benefit the contractor and client even at the modest expected energy savings in small buildings. Results from a small-scale pilot of this approach validated that the EMP could be delivered by contractors in 4-8 hours per building per year, and that energy savings of 3-5percent are feasible through this approach.

Operations Strategy and –Innovation? -A Contractor Implementing Lean

DEFF Research Database (Denmark)

Koch, Christian; Simonsen, Rolf

2006-01-01

Traditional strategic management and operations strategy wants us to believe that the implementation of management concepts is a simple strategic choice made by top managers. In this paper we introduce the story of Lean Construction entering into the organisation of a Danish contractor. Lean...... concepts. The paper presents findings from empirical work in collaboration with a large Danish contractor. The case is analysed from the perspective of operation strategy and political process. It is observed how the management concept is socially constructed and negotiated through political action of key...

29 CFR 471.16 - Under what circumstances may a contractor be reinstated?

Science.gov (United States)

2010-07-01

..., DEPARTMENT OF LABOR NOTIFICATION OF EMPLOYEE RIGHTS UNDER FEDERAL LABOR LAWS OBLIGATIONS OF FEDERAL CONTRACTORS AND SUBCONTRACTORS; NOTIFICATION OF EMPLOYEE RIGHTS UNDER FEDERAL LABOR LAWS General Enforcement... 29 Labor 2 2010-07-01 2010-07-01 false Under what circumstances may a contractor be reinstated...

48 CFR 2945.104 - Review and correction of contractors' property control systems.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 7 2010-10-01 2010-10-01 false Review and correction of... contractors' property control systems. When the Government's property administrator determines that review and... administrator must review the system to determine whether the contractor will be able to meet the requirements...

Examining the Dynamics of Novation from the Principal Contractor's and Architect's Perspectives

Directory of Open Access Journals (Sweden)

Alan Griffith

2012-11-01

Full Text Available Design and build is a popular form of procurement worldwide. In its conventional form, it is characterised by the integration between design and construction. Novation, a variant of design and build where design responsibility is transferred from designer to contractor as procurement evolves, has gained in popularity. However, the characteristics of the process, although well identified, continue to create confusion and problems for clients and contractors alike. This paper focuses on the dynamics of design and build novation from the principal contractor's and architect's perspectives. It embraces key aspects of both the pre-contract and post-contract environment. Its contribution forms a part of a major UK Government funded research project investigating design and build best practice. The findings presented in this paper broadly indicate that contractors believe novated design and build can be disadvantageous and that considerable fragmentation can be created in what should be an integrated procurement approach.

United States extension of indemnification to utilities and contractors

International Nuclear Information System (INIS)

Cunningham, G.H.

1988-01-01

The status of legislation in the United States, usually known as the Price-Anderson Act, provides an assured source and means of compensation for members of the public who may be injured as a result of a nuclear accident at a licensed commercial nuclear power plant or at a facility of the United States Government operated by a contractor. First a brief overview of the Act and its history is given, then the course of legislation to extend the Price-Anderson Act through the United States Congress is charted with comments made on the major issues of the debate. The Act requires that a least $560 million in insurance and/or Government indemnity is available to cover public liability claims arising out of an accident at a nuclear power plant. The Act also limits the total liability of all persons for any nuclear incident to a predetermined amount and this is one issue discussed. Final action on the legal situation should be taken in 1988. (U.K.)

Process waste assessment approach, training and technical assistance for DOE contractors

International Nuclear Information System (INIS)

Pemberton, S.

1994-03-01

The Department of Energy (DOE) and its contractors are faced with a large waste management problem as are other industries. One of the tools used in a successful waste minimization pollution prevention (WMin/P2) program is a process waste assessment (PWA). The purpose of this project was to share the Kansas City Plant's (KCP's) PWA expertise with other DOE personnel and DOE contractors. This consisted of two major activities: (1) The KCP's PWA graded approach methodology was modified with the assistance of DOE/Defense Program's laboratories, and (2) PWA training and technical assistance were provided to interested DOE personnel and DOE contractors. This report documents the FY93 efforts, lesson learned, and future plans for both PWA-related activities

Excessive Profits of German Defense Contractors

Science.gov (United States)

2014-09-01

its business unit Thyssen Krupp Marine Systems, is a German defense contractor. (2) Tognom AG Tognum AG owned the MTU Friedrichshafen GmbH before... Friedrichshafen provided engines for many ships of the German Navy and for German battle tanks, such as the Leopard I and Leopard II. MTU refers to the

Methods Dealing with Complexity in Selecting Joint Venture Contractors for Large-Scale Infrastructure Projects

Directory of Open Access Journals (Sweden)

Ru Liang

2018-01-01

Full Text Available The magnitude of business dynamics has increased rapidly due to increased complexity, uncertainty, and risk of large-scale infrastructure projects. This fact made it increasingly tough to “go alone” into a contractor. As a consequence, joint venture contractors with diverse strengths and weaknesses cooperatively bid for bidding. Understanding project complexity and making decision on the optimal joint venture contractor is challenging. This paper is to study how to select joint venture contractors for undertaking large-scale infrastructure projects based on a multiattribute mathematical model. Two different methods are developed to solve the problem. One is based on ideal points and the other one is based on balanced ideal advantages. Both of the two methods consider individual difference in expert judgment and contractor attributes. A case study of Hong Kong-Zhuhai-Macao-Bridge (HZMB project in China is used to demonstrate how to apply these two methods and their advantages.

SPEAR 3 Upgrade Project: The Final Year

International Nuclear Information System (INIS)

Hettel, R

2004-01-01

During April, 2003, the SPEAR 2 storage ring, which served the high energy physics community from 1972 to 1987, and the synchrotron radiation community for an additional 15 years, was removed from its shielding tunnel in order to install the new 3-GeV, 500-mA SPEAR 3 light source. From May to November, SSRL will excavate the tunnel floor and pour a new concrete floor, and then install pre-assembled girders holding magnets, copper vacuum chambers, PEP-II-style rf cavities, and beam line front end components. At the same time, power supply, instrumentation and control, and other ancillary systems will be configured, leading to a commissioning period beginning in November 2003. The progress of accelerator component implementation and installation during the final year of the project will be reviewed

42 CFR 405.1010 - When CMS or its contractors may participate in an ALJ hearing.

Science.gov (United States)

2010-10-01

... 42 Public Health 2 2010-10-01 2010-10-01 false When CMS or its contractors may participate in an... Hearings § 405.1010 When CMS or its contractors may participate in an ALJ hearing. (a) An ALJ may request, but may not require, CMS and/or one or more of its contractors to participate in any proceedings...

Occupational dose reduction at Department of Energy contractor facilities: Study of ALARA programs

International Nuclear Information System (INIS)

Dionne, B.J.; Meinhold, C.B.; Khan, T.A.; Baum, J.W.

1992-03-01

This report provides the US Department of Energy (DOE) and its contractors with information that will be useful for reducing occupational radiation doses at DOE's nuclear facilities. In 1989 and 1990, health physicists from the Brookhaven National Laboratory's (BNL) ALARA Center visited twelve DOE contractor facilities with annual collective dose equivalents greater than 100 person-rem (100 person-cSv). The health physicists interviewed radiological safety staff, engineers, and training personnel who were responsible for dose control. The status of ALARA practices at the major contractor facilities was compared with the requirements and recommendation in DOE Order 5480.11 ''Radiation Protection for Occupational Workers'' and PNL-6577 ''Health Physics Manual of Good Practices for Reducing Radiation Exposure to Levels that are as Low as Reasonably Achievable.'' The information and data collected are described and examples of successful practices are presented. The findings on the status of the DOE Contractor ALARA Programs are summarized and evaluated. In addition, the supplement to this report contains examples of good-practice documents associated with implementing the major elements of a formally documented ALARA program for a major DOE contractor facility

Factors and values of willingness to pay for improved construction waste management--a perspective of Malaysian contractors.

Science.gov (United States)

Begum, Rawshan Ara; Siwar, Chamhuri; Pereira, Joy Jacqueline; Jaafar, Abdul Hamid

2007-01-01

Malaysia is facing an increase in the generation of waste and of accompanying problems with the disposal of this waste. In the last two decades, extensive building and infrastructure development projects have led to an increase in the generation of construction waste material. The construction industry has a substantial impact on the environment, and its environmental effects are in direct relation to the quality and quantity of the waste it generates. This paper discusses general characteristics of the construction contractors, the contractors' willingness to pay (WTP) for improved construction waste management, determining factors which affect the amount of their willingness to pay, and suggestions and policy implications in the perspective of construction waste management in Malaysia. The data in this study is based on contractors registered with the construction industry development board (CIDB) of Malaysia. Employing the open ended contingent valuation method, the study assessed the contractors' average maximum WTP for improved construction waste management to be RM69.88 (1US$=3.6 RM) per tonne of waste. The result shows that the average maximum WTP is higher for large contractors than for medium and small contractors. The highest average maximum WTP value is RM88.00 for Group A (large contractors) RM78.25 for Group B (medium-size contractors) and RM55.80 for Group C (small contractors). One of the contributions of this study is to highlight the difference of CIDB registration grade in the WTP for improved construction waste management. It is found that contractors' WTP for improved waste collection and disposal services increases with the increase in contractors' current paid up capital. The identified factors and determinants of the WTP will assist the formulation of appropriate policies in addressing the construction waste problem in Malaysia and indirectly improve the quality of construction in the country.

Experiences of final year nursing students in their preparedness to become registered nurses

Directory of Open Access Journals (Sweden)

S Carlson

2005-09-01

Full Text Available The objectives of this study were: firstly, to explore and describe the experiences of final year nursing students relating to how they experience their preparedness to fulfil the role of professional nurse; secondly, to explore and describe the experiences of novice professional nurses in the role of professional nurse; finally, to generate a model which will assist the final year nursing student to become a professional nurse. A theory-generative, qualitative, explorative, descriptive and contextual research design was utilized to reach the objectives of the study. Results indicated that final year nursing students experience a lack of confidence to take on the responsibilities of professional nursing. The results are displayed in table form and discussed in the article. This abstract forms part of a bigger study that addresses the professional maturity of the novice professional nurse for the practice of nursing.

Information for contractors' staff

CERN Multimedia

The Dosimetry Service

2005-01-01

We have observed a significant decrease in the number of completed Certificates for Work in Controlled Radiation Areas being submitted with applications for dosimeters for your staff. Henceforth, we shall no longer be able to issue dosimeters without a certificate, which must be signed by the employee and the contractor's radiation-protection expert. You can obtain the certificate form from the Dosimetry Service at Building 24/E-011 or from our Website: http://service-rp-dosimetry.web.cern.ch/service-rp-dosimetry/. Thank you for your understanding. The Dosimetry Service

The transition into veterinary practice: Opinions of recent graduates and final year students

Directory of Open Access Journals (Sweden)

Hudson Neil PH

2011-09-01

Full Text Available Abstract Background The transition from veterinary student to member of the veterinary profession is known to be challenging. This study aimed to determine and compare the opinions of final year veterinary students and recent graduates on graduate attributes that ease this transition. Methods The study was carried out across 3 veterinary schools in the United Kingdom. Paper based or electronic surveys were used. Final year students in the 3 schools were surveyed either electronically (school A or on paper (schools B and C. Student cohort sizes were 112, 227 and 102 respectively. Recent graduates were contacted either at a reunion event (school A or electronically from database records (school B and school C. Cohort sizes of contacted graduates were 80, 175 and 91 respectively. Respondents were asked to rate 42 individual attributes on a 5 point Likert scale. Focus groups with final year students and recent graduates and telephone interviews with recent graduates were carried out. Data were analysed by two researchers through a combination of manual coding and thematic analysis. Data were grouped into broad themes then sorted into narrower themes. Data were then searched for counter examples. Results Response rates for final year students were 34% (school A, 36% (school B and 40% (school C. Response rates for recent graduates were 56% (school A, 20% (school B and 11% (school C. There was a high level of agreement between the cohorts with respect to communication skills, problem solving and decision making skills, recognition of own limitations and the ability to cope with pressure all rated unanimously important or very important. Business acumen, knowledge of veterinary practice management and research skills were the 3 attributes ranked at the bottom of the list. Nine attributes were identified with a significantly different (p Conclusions Recent graduates and final year students rate highly the attributes which help foster the client

75 FR 33237 - Defense Federal Acquisition Regulation Supplement; Contractor Insurance/Pension Review (DFARS...

Science.gov (United States)

2010-06-11

... Acquisition Regulation Supplement; Contractor Insurance/Pension Review (DFARS Case 2009-D025) AGENCY: Defense.../Pension Review from Procedures, Guidance, and Information to the Defense Acquisition Regulation Supplement..., February 23, 2006, moved requirements for Contractor Insurance/Pension Review (CIPR) from DFARS 242.7302 to...

Migrant and Seasonal Agricultural Worker Protection Act: Forestry contractors' model operating plan

Science.gov (United States)

Dan Bremer

2007-01-01

The Model Operating Plan for forestry contractors is a voluntary plan for compliance with the Migrant and Seasonal Agricultural Worker Protection Act (MSPA) of 1983, with amendments passed in 1996 and 1997. This plan is designed as a guide for forestry contractors who wish to comply with all federal, state, and local rules and regulations that govern their employer/...

Research on Contractor Selection Based on Project Partnership%项目合作关系下承包商选择的研究

Institute of Scientific and Technical Information of China (English)

王舜; 马钦海; 冯卓

2012-01-01

针对建筑行业中业主与承包商通过合作可以实现双方共赢,但传统的承包商选择模型难以选择到合作关系下的承包商这一问题,利用因子分析法对影响建筑行业中项目合作成功的16个变量进行分析,提出了项目合作关系下承包商选择的基本框架,从一个全新的角度诠释了合作关系下的承包商选择的标准.指出业主企业在竞购阶段选取项目合作的承包商时应注重承包商的这四个方面：合作意愿、敏捷性能力、合作能力和竞购能力,为业主企业在竞购阶段正确选择项目合作承包商提供参考.%In view of the fact that with a more traditional contractor selection model it is rather difficult to pick out the right contractors based on project partnership,although both clients and contractors might benefit through cooperation in the construction industry,a factor analysis is employed to analyze the 16 variables affecting the successful project cooperation in the construction industry.It then puts forward a basic framework of contractor selection based on project partnership and interprets the criteria for contractor selection from a new perspective.Finally,the paper points out that clients should attach great importance to the following four aspects： willingness to cooperate,agility,ability to cooperate and capability of procurement,which could provide reference for them to select appropriate contractors at the procurement stage.

Project Delivery Acquisition and Contracting Plan for the Tank Farm Contractor

International Nuclear Information System (INIS)

MERCADO, L.C.

2000-01-01

This document is a plan presenting the process, strategies and approaches for vendor contracting by the Tank Farm Contractor. The plan focuses on contracting structures, practices, methods, and desired approaches in contracting. The U.S. Department of Energy (DOE), Office of River Protection (ORP) has contracted with the CH2M HILL Hanford Group, Inc. (CHG), as the Tank Farm Contractor (TFC), to support vitrification of Hanford Site tank waste by the Privatization Contractor. During Waste Feed Delivery Phase 1, waste will be retrieved from certain double-shell tanks and delivered to the Privatization Contractor to meet contract feed delivery requirements. Near-term project goals include upgrading infrastructure systems; retrieving and delivering the waste; and accepting the waste packages for interim onsite storage and disposal. Project Delivery includes individual projects assigned to provide the infrastructure and systems responsible to provide engineering, design, procurement, installation/construction, and testing/turnover of systems for retrieval of waste from Hanford double-shell tanks. This plan sets the requirements for projects work scope, contracting practices, structures, methods, and performance measurements. The plan is designed to integrate Life-Cycle Projects acquisitions and provide a consistent contracting approach. This effort will serve as a step improvement in contract reform implementing commercial practices into DOE projects

Contractors' Support of U.S. Operations in Iraq

National Research Council Canada - National Science Library

Frisk, Daniel; Trunkey, R. D; Talaber, Adam; Adedeji, Adebayo; Liu, Victoria; Dennis, Robert; Gullo, Theresa; Sammartino, Frank; Murphy, Robert; Elsea, Jennifer

2008-01-01

.... This paper, which covers the period from 2003 through 2007, provides an overview of the federal costs of employing contractors in Iraq and in nearby countries, the type of products and services...

How Do Contractors Select Suppliers for Greener Construction Projects? The Case of Three Swedish Companies

Directory of Open Access Journals (Sweden)

Shahin Mokhlesian

2014-06-01

Full Text Available There are many studies of contractor selection based on clients and the selection of suppliers by contractors. However, supplier selection specifically related to green construction projects has been much less studied. Green construction differs from conventional construction because of differences in its underlying principles and use of environmentally-friendly materials and technologies. This paper studies how procurers in contractor companies in Sweden adopt green projects and how contractor perception of supplier mastery of green knowledge affects supplier selection. The investigation is based on a set of semi-structured interviews conducted among three large contractors in Sweden. A main finding is that the perceived differences between green and conventional projects do not change supplier selection dramatically. An implication is that “greener projects” is a more appropriate denotation than “green project”. Evidence shows that suppliers’ green knowledge is an important factor in supplier selection, as respondents rated suppliers’ knowledge of green projects as very important, and to fix his, there was a consensus among respondents about the need for close collaboration between contractors and suppliers. To ensure knowledge acquisition from suppliers and to increase their competitive advantage over rivals, contractors collaborate with their suppliers in a partnering setting. It is anticipated that the results of this study will be used to fill the gap in the literature on supplier selection in green projects and can also be used for construction firms contemplating getting involved in green projects.

48 CFR 227.7207 - Contractor data repositories.

Science.gov (United States)

2010-10-01

... repositories. 227.7207 Section 227.7207 Federal Acquisition Regulations System DEFENSE ACQUISITION REGULATIONS... Computer Software and Computer Software Documentation 227.7207 Contractor data repositories. Follow 227.7108 when it is in the Government's interests to have a data repository include computer software or to...

48 CFR 245.608-7 - Reimbursement of cost for transfer of contractor inventory.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 3 2010-10-01 2010-10-01 false Reimbursement of cost for transfer of contractor inventory. 245.608-7 Section 245.608-7 Federal Acquisition Regulations System... Reporting, Redistribution, and Disposal of Contractor Inventory 245.608-7 Reimbursement of cost for transfer...

Key aspects in managing safety when working with multiple contractors: A case study

NARCIS (Netherlands)

Drupsteen, L.; Rasmussen, H.B.; Ustailieva, E.; Kampen, J. van

2015-01-01

Working with multiple contractors in a shared workplace can introduce and increase safety risks due to complexity. The aim of this study was to explore how safety issues are recognized in a specific case and to identify whether clients and contractors perceive problems similarly. The safety issues

Private Security Contractors in Iraq: Background, Legal Status, and Other Issues

Science.gov (United States)

2008-09-29

reporting procedures, bad investigation methods and unfair double standards amongst employees should not be condoned." Tom Jackman , “Security Contractor...Cleared in Two Firings”, Washington Post, August 2, 2007. p. A-15. 43 Tom Jackman . “U.S. Contractor Fired on Iraqi Vehicles for Sport, Suit Alleges...Public Diplomacy and Public Affairs Karen Hughes , speaking before the Council on Foreign Relations, New York City, N.Y., on May 10, 2006, said of the new

Design management of general contractor under nuclear power project EPC mode

International Nuclear Information System (INIS)

Su Shaojian

2013-01-01

Design management has not yet formed a theoretical system recognized, general contractor design managers under nuclear power project EPC Mode lack the clear theory basis. This paper aims to discuss Design management from the angle of general contractor under nuclear power project EPC mode, Gives the concept of design management Clearly, by Combining the characteristics of nuclear power project, Gives the specific content and meaning of the design management of nuclear power project. (authors)

Defense Trade Contractors Engage in Varied International Alliances

National Research Council Canada - National Science Library

2000-01-01

.... Generally, two or more companies form a team by negotiating an agreement to work together to pursue a particular government procurement, with one company acting as the primary contractor and others as subcontractors...

Technical assistance contractor Management Plan

International Nuclear Information System (INIS)

1993-09-01

The Technical Assistance Contractor (TAC) for the Uranium Mill Tailings Remedial Action (UMTRA) Project comprises Jacobs Engineering Group Inc. (JEG) and its major teaming partners [Roy F. Weston, Inc. (RFW), Sergent, Hauskins ampersand Beckwith Agra, Inc. (SHB Agra), and Geraghty ampersand Miller, Inc. (G ampersand M)]. The first three companies have worked together effectively on the UMTRA Project for more than 10 years. With the initiation of the UMTRA Groundwater Project in April 1991, a need arose to increase the TAC's groundwater technical breadth and depth, so G ampersand M was brought in to augment the team's capabilities. The TAC contract's scope is to provide technical, analytical, environmental, engineering, design, inspection, and management support services to the US Department of Energy (DOE) for both surface and groundwater projects. The TAC team continues to support the DOE in completing surface remedial actions and initiating groundwater remediation work for start-up, characterization, design, construction oversight, and remedial operations. A key feature of the TAC's management approach is the extensive set of communication systems implemented for the UMTRA Project. These systems assist all functional disciplines in performing UMTRA Project tasks associated with management, technical support, administrative support, and financial/project controls

Defense Contract Audit Agency Audits of Contractor Compliance with Cost Accounting Standards

Science.gov (United States)

1999-01-11

Appendix B. Continued Need for Cost Accounting Standards Asset Valuations. GAAP requires that assets be revalued after mergers and acquisitions. If the...purchase method is used to revalue assets , depreciation and amortization costs may increase drastically to be passed on as increased costs on...contractor fully for the assets through normal depreciation . Contractor Pension Plans. Government-funded pension assets must be properly allocated

Out of the Shadows: The Health and Well-Being of Private Contractors Working in Conflict Environments.

Science.gov (United States)

Dunigan, Molly; Farmer, Carrie M; Burns, Rachel M; Hawks, Alison; Setodji, Claude Messan

2014-01-01

Over the past decade, private contractors have been deployed extensively around the globe. In addition to supporting U.S. and allied forces in Iraq and Afghanistan, contractors have assisted foreign governments, nongovernmental organizations, and private businesses by providing a wide range of services, including base support and maintenance, logistical support, transportation, intelligence, communications, construction, and security. At the height of the conflicts in Iraq and Afghanistan, contractors outnumbered U.S. troops deployed to both theaters. Although these contractors are not supposed to engage in offensive combat, they may nonetheless be exposed to many of the stressors that are known to have physical and mental health implications for military personnel. RAND conducted an online survey of a sample of contractors who had deployed on contract to a theater of conflict at least once between early 2011 and early 2013. The survey collected demographic and employment information, along with details about respondents' deployment experience (including level of preparation for deployment, combat exposure, and living conditions), mental health (including probable posttraumatic stress disorder, depression, and alcohol misuse), physical health, and access to and use of health care. The goal was to describe the contractors' health and well-being and to explore differences across the sample by such factors as country of citizenship, job specialty, and length and frequency of contract deployment. The findings provide a foundation for future studies of contractor populations and serve to inform policy decisions affecting contractors, including efforts to reduce barriers to mental health treatment for this population.

Nevada State plan; final approval determination. Occupational Safety and Health Administration (OSHA), U.S. Department of Labor. Final State plan approval--Nevada.

Science.gov (United States)

2000-04-18

This document amends OSHA's regulations to reflect the Assistant Secretary's decision granting final approval to the Nevada State plan. As a result of this affirmative determination under section 18(e) of the Occupational Safety and Health Act of 1970, Federal OSHA's standards and enforcement authority no longer apply to occupational safety and health issues covered by the Nevada plan, and authority for Federal concurrent jurisdiction is relinquished. Federal enforcement jurisdiction is retained over any private sector maritime employment, private sector employers on Indian land, and any contractors or subcontractors on any Federal establishment where the land is exclusive Federal jurisdiction. Federal jurisdiction remains in effect with respect to Federal government employers and employees. Federal OSHA will also retain authority for coverage of the United States Postal Service (USPS), including USPS employees, contract employees, and contractor-operated facilities engaged in USPS mail operations.

48 CFR 3.104-4 - Disclosure, protection, and marking of contractor bid or proposal information and source...

Science.gov (United States)

2010-10-01

... otherwise authorized by law or regulation. Any release containing contractor bid or proposal information or..., and marking of contractor bid or proposal information and source selection information. 3.104-4... marking of contractor bid or proposal information and source selection information. (a) Except as...

Contractors perspective for critical factors of cost overrun in highway projects of Sindh, Pakistan

Science.gov (United States)

Sohu, Samiullah; Abdullah, Abd Halid; Nagapan, Sasitharan; Fattah, Abdul; Ullah, Kaleem; Kumar, Kanesh

2017-10-01

Construction industry of Pakistan is creating a number of opportunities in employment as well as plays a role model for economy development of the country. This construction industry has a serious issue of cost overrun in all construction projects especially in construction of highway projects. Cost overrun is a serious and critical issue in construction of highway projects which gives negative impact to construction practitioners because it is not only cross the approved budget but also approved time of the project. The main objective of this study is to find out critical factors causing cost overrun in highway projects of Sindh according to contractors' perspectives. Deep literature review was carried out and a total of 64 factors of cost overrun were identified. To achieve the objective, a questionnaire was designed and distributed among 16 selected respondents who have more than 20 years of experience in construction of highway projects. The results from analysis found that most critical factors of cost overrun in the order of importance include financial and cash flow difficulties faced by contractor, frequent changes in design, changes in price of materials, poor planning by client, change in scope of project, change in specification of materials and delay in taking decisions. This study will assist contractors to narrow down some of the critical factors that would lead to cost overrun, and therefore be prepared with the ways to mitigate these problems in construction of highway projects of Sindh province.

Technical Assistance Contractor management plan. Revision 1

International Nuclear Information System (INIS)

1995-08-01

The Technical Assistance Contractor (TAC) for the Uranium Mill Tailings Remedial Action (UMTRA) Project comprises Jacobs Engineering Group Inc. (JEG) as the prime contractor and three teaming partner subcontractors: Roy F. Weston, Inc. (RFW), AGRA Earth and Environmental, Inc. (AGRA), and Geraghty and Miller, Inc. (G and M). The TAC contract's scope is to provide technical, analytical, environmental, engineering, design, inspection, and management support services to the US Department of Energy (DOE) for both Surface and Ground Water Projects. The TAC team supports the DOE in completing surface remedial action and initiating ground water remediation work for start-up, characterization, compliance planning, design, construction oversight, and remedial operations. The TAC provides the DOE UMTRA Project Team with a dedicated management, scientific, and technical resource base in Albuquerque, New Mexico, which is supplemented by corporate resources. A carefully developed and maintained staff of technical experts is available to assess, analyze, develop, and execute cost-effective solutions to the demanding technical and institutional problems presented by the UMTRA Project

Perceived stress at transition to workplace: a qualitative interview study exploring final-year medical students’ needs

Directory of Open Access Journals (Sweden)

Moczko TR

2016-01-01

Full Text Available Tobias R Moczko,1,2,* Till J Bugaj,1,* Wolfgang Herzog,1 Christoph Nikendei1 1Department for General Internal and Psychosomatic Medicine, University Hospital of Heidelberg, Heidelberg, 2School of Medicine, Faculty of Health, Witten/Herdecke University, Witten, Germany *These authors contributed equally to this work Objectives: This study was designed to explore final-year medical students’ stressors and coping strategies at the transition to the clinical workplace. Methods: In this qualitative study, semi-standardized interviews with eight final-year medical students (five male, three female; aged 25.9±1.4 years were conducted during their internal medicine rotation. After verbatim transcription, a qualitative content analysis of students’ impressions of stress provoking and easing factors during final-year education was performed. Results: Students’ statements regarding burdens and dealing with stress were classified into four main categories: A perceived stressors and provoking factors, B stress-induced consequences, C personal and external resources for preventing and dealing with stress, and D final-year students’ suggestions for workplace improvement. Conclusion: Final-year medical students perceived different types of stress during their transition to medical wards, and reported both negative consequences and coping resources concerning perceived stress. As supervision, feedback, and coping strategies played an important role in the students’ perception of stress, final-year medical education curricula development should focus on these specifically. Keywords: undergraduate medical education, stress prevention, final-year medical education, workplace learning, qualitative research

48 CFR 22.1503 - Procedures for acquiring end products on the List of Products Requiring Contractor Certification...

Science.gov (United States)

2010-10-01

... end products on the List of Products Requiring Contractor Certification as to Forced or Indentured... products on the List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor... contracting officer must check the List of Products Requiring Contractor Certification as to Forced or...

Phase V storage (Project W-112) Central Waste Complex operational readiness review, final report

International Nuclear Information System (INIS)

Wight, R.H.

1997-01-01

This document is the final report for the RFSH conducted, Contractor Operational Readiness Review (ORR) for the Central Waste Complex (CWC) Project W-112 and Interim Safety Basis implementation. As appendices, all findings, observations, lines of inquiry and the implementation plan are included

Phase 5 storage (Project W-112) Central Waste Complex operational readiness review, final report

Energy Technology Data Exchange (ETDEWEB)

Wight, R.H.

1997-05-30

This document is the final report for the RFSH conducted, Contractor Operational Readiness Review (ORR) for the Central Waste Complex (CWC) Project W-112 and Interim Safety Basis implementation. As appendices, all findings, observations, lines of inquiry and the implementation plan are included.

78 FR 64143 - 30-Day Notice of Proposed Information Collection: Contractor's Requisition-Project Mortgages

Science.gov (United States)

2013-10-25

... DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT [Docket No. FR-5683-N-88] 30-Day Notice of Proposed Information Collection: Contractor's Requisition--Project Mortgages AGENCY: Office of the Chief Information... Title of Information Collection: Contractor's Requisition--Project Mortgages. OMB Approval Number: 2502...

Awareness and Use of Social Bookmarking Services by Final Year ...

African Journals Online (AJOL)

The Web is now more interactive than ever before. So many ... To assess the use of social bookmarking services by the final year students of Afe .... Delicious, developed in 2003 is perhaps the best known currently of all such tools (Lund et al,.

2005 River Corridor Cleanup Contractor Revegetation Monitoring Report

Energy Technology Data Exchange (ETDEWEB)

A. L. Johnson

2005-09-12

This report contains a compilation of the results of vegetation monitoring data that were collected in the spring and summer of 2005 for the Environmental Restoration Contractor's revegetation and mitigation areas on the Hanford Site.

Army Depot Maintenance: More Effective Use of Organic and Contractor Resources

Science.gov (United States)

1990-06-04

terkerrny (PA) RRAD Red River (TX) IBAD Lexingtor).Bluegrass (KY) 3MPUAD Pueblo (CO) 2000 ANAD CCAD TEAD TOAD SAAO LEAD FMD LBAD PUAfl j] Aut)’onzed Onboard...until it is received by the contractor. That problem could be eliminated by redesigning the process. Specifically, the FTA document that notifies the...should revise CCSS to allow the FTM document to generate an image to LCA, the FTA to create a due-in to the contractor, and CCSS to determine the depot

75 FR 6669 - Federal Acquisition Regulation; Submission for OMB Review; Contractors' Purchasing Systems Reviews

Science.gov (United States)

2010-02-10

...' Purchasing Systems Reviews AGENCIES: Department of Defense (DOD), General Services Administration (GSA), and... collection requirement concerning contractors' purchasing systems reviews. A request for public comments was..., Washington, DC 20405. Please cite OMB Control No. 9000-0132, Contractors' Purchasing Systems Review, in all...

78 FR 45945 - 60-Day Notice of Proposed Information Collection: Contractor's Requisition-Project Mortgages

Science.gov (United States)

2013-07-30

... DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT [Docket No. FR-5687-N-34] 60-Day Notice of Proposed Information Collection: Contractor's Requisition--Project Mortgages AGENCY: Office of the Assistant Secretary... Section A. A. Overview of Information Collection Title of Information Collection: Contractor's Requisition...

Financial Planning and Management Practices of Electrical Contractors

Directory of Open Access Journals (Sweden)

Lucko Gunnar

2016-12-01

Full Text Available Contractors must carefully manage their cash outflows (e.g., for materials to enable their work and inflows (after the work to be profitable, particularly in an economy that is still recovering from the 2008-2012 recession that grew out of the mortgage crisis. Their importance for business success is undisputed, as bankruptcies due to insufficient cash flow underline. Therefore, this study investigated current business practices of electrical contracting companies of different sizes with respect to their financial planning and management. A detailed questionnaire was developed with best guidelines on survey studies and pilot testing. It was sent to members of the National Electrical Contractors Association. Respondent anonymity was ensured. The survey recorded demographics, business practices, operating conditions, and other important factors using 57 subquestions. Each section allowed feedback to clarify the numerical responses. Responses were well distributed across company sizes, so that the results are representative for the entire industry. The results indicated that contractors generally have a substantial amount of experience in financial decision making. Their approach is conservative and focuses on healthy growth. Yet, opportunities to fine-tune business practices are identified, e.g., immediate invoicing, considering discounts to accelerate payment receipts, attempting to negotiate and use favorable credit terms, reviewing payment performance, and performing frequent cash flow forecasts. Some of the differences in the responses can be attributed to different company sizes. To help especially smaller companies in planning their cash flow, a spreadsheet for implementation has been created.

Institutional and resource constraints that inhibit contractor ...

African Journals Online (AJOL)

Results show that contractors face institutional constraints (work allocation limitations, lack of performance incentives and high transaction costs, such as negotiation costs, the risk of a loss in work and contract default risk), cash flow problems, poor physical infrastructure and a lack of labour. It is expected that the promotion ...

Private Military Contractors, War Crimes and International ...

African Journals Online (AJOL)

The end of the Cold War witnessed the growth and spread of legally established private military contractors (PMCs) playing largely undefined roles in wars, international security and post-conflict reconstruction. The operations of PMCs in Iraq and Afghanistan in the 21st century have been marked by gross human rights ...

Defense Department Profit and Contract Finance Policies and Their Effects on Contract and Contractor Performance

National Research Council Canada - National Science Library

Arnold, Scot A; Harmon, Bruce R; Tyson, Karen W; Fasana, Kenton G; Wait, Christopher S

2009-01-01

.... The goal of profit policy is a contract price that reimburses the contractor for its costs, provides the necessary incentives to yield beneficial performance, and provides the contractor with sufficient risk reward...

Tapping into the teaching experiences of final year education students to increase support for students in their first year

Directory of Open Access Journals (Sweden)

Gretchen Geng

2017-03-01

Full Text Available This study investigates the mentorship of pairing first year and final year teacher education students during their school placements or practicum. Participating students were studied using an Interpretative Phenomenological Analysis (IPA approach and undertaking Perceived Stress Scale (PSS to interpret their experience and their stress levels in the peer mentorship program. This peer mentoring program offered benefits for the first year education students by reducing their stress levels significantly and providing reassurance about their performance during school practicum. It also prepared the final year students for taking on teacher mentor roles. While the student mentorship program cannot replace the support provided by schools and universities, it does offer first year students reassurance as to their practical teaching abilities and performance. In addition, this study provides several perspectives on student mentorship during teaching practicum that are worthy of further research.

WORKER PROTECTION: Federal Contractors and Violations of Labor Law

National Research Council Canada - National Science Library

1995-01-01

... of Federal Contract Compliance Programs (OFCCP). Federal law and an executive order place greater responsibilities on federal contractors compared with other employers In some areas of workplace activity...

When Contractors Deploy: A Guide for the Operational Commander

National Research Council Canada - National Science Library

Buhler, Carl

2000-01-01

.... Furthermore, this paper also lists four recommendations for operational commanders and the military on how to better integrate contractors into the military effort, especially during hostile combat situations...

APPROVAL OF WASTE TREATMENT AND IMMOBILIZATION PLANT CONTRACTOR-INITIATED AUTHORIZATION BASIS AMENDMENT REQUESTS (ABAR)

International Nuclear Information System (INIS)

JONES GL

2008-01-01

The objective is to describe the process used by the Office of River Protection (ORP) for evaluating and implementing Contractor-initiated changes to the Waste Treatment and Immobilization Plant (WTP) Authorization Basis (AB). The WTP Project's history has provided a unique challenge for establishing and maintaining an ORP-approved AB during design and construction. Until operations begin, the project cannot implement the classic Unreviewed Safety Question (USQ) process to determine when ORP approval of Contractor-initiated changes is required. A 'quasiUSQ' process has been implemented that defines when AB changes could occur. The three types of AB changes are (1) Limited Scope Changes, (2) Authorization Basis Deviations, and (3) Authorization Basis Amendment Request (ABAR). DOE RL/REG 97-13, 'Office of River Protection Position on Contractor-Initiated Changes to the Authorization Basis', describes the process the WTP Contractor must follow to make changes to the AB, with and without ORP approval. The process uses a 'safety evaluation' process that is similar to the USQ process but at a more qualitative level. The maturation of the WTP Contractor's facility design and activities, and other changing conditions, resulted in a process that allows the Contractor to make changes to the AB without ORP approval; however, those changes that may significantly affect nuclear safety do require ORP approval. This process balances the WTP regulatory principle of efficiency with assurance that adequate safety will not be compromised. The process has reduced the number of ABARs requiring ORP approval and reduced the potential for delays in design and procurement activities

Defense Department Profit and Contract Finance Policies and Their Effects on Contract and Contractor Performance

National Research Council Canada - National Science Library

Arnold, Scot A; Harmon, Bruce R; Tyson, Karen W; Fasana, Kenton G; Wait, Christopher S

2008-01-01

.... The goal of profit policy is a contract price that reimburses the contractor for its costs, provides the necessary incentives to yield beneficial performance, and to provide the contractor with sufficient risk reward...

BUSINESS STRATEGY OF LARGE CONTRACTORS IN ADOPTING INDUSTRIALISED BUILDING SYSTEM (IBS: THE MALAYSIAN CASE

Directory of Open Access Journals (Sweden)

FRANKY AMBON

2012-12-01

Full Text Available Industrialised Building System (IBS is the term coined by the government and industry in Malaysia to represent the construction industry and the application of prefabrication method in building construction. The purpose of this exploratory research paper is to highlight business strategy being pursued by large Malaysian contractors in adopting IBS. The paper uses case study as research method. The analysis is based primarily on cross-case analysis and pattern matching technique. The paper observes contractors which involved in IBS are part of larger holding companies in a corporate set-up include design and manufacturing subsidiaries. The companies positioned themselves as one-stop total solution provider for IBS and offer a wider range of services from design, production, and installation to clients. To become competitive and able to create total solution, contractors need to establish cluster and consortium of integrated project team by creating a partnership when and where it is needed. A vendor development programme modelled along the lines of the development of automotive industry should also be established. Future empirical studies should extensively examine these areas, especially the development of business model for contractors. The availability of this model could help to accelerate the uptake of IBS among contractors.

The reliability of randomly selected final year pharmacy students in ...

African Journals Online (AJOL)

Employing ANOVA, factorial experimental analysis, and the theory of error, reliability studies were conducted on the assessment of the drug product chloroquine phosphate tablets. The G–Study employed equal numbers of the factors for uniform control, and involved three analysts (randomly selected final year Pharmacy ...

Academic achievement of final-year medical students on a rural ...

African Journals Online (AJOL)

Academic achievement of final-year medical students on a rural clinical platform: Can we dispel the myths? ... African Journal of Health Professions Education ... Background: There is a growing body of literature relating to the establishment of rural clinical training platforms for medical students describing many positive ...

Perception of final year medical students about the choice of ...

African Journals Online (AJOL)

Background: In Nigeria and many other countries, many specialties had problems with recruitment of medical teachers outside the core clinical departments. Objective: We aim at determining the factors that influence the choice of medical microbiology as a speciality among final year medical students in University of ...

Report: Management Alert - EPA Has Not Initiated Required Background Investigations for Information Systems Contractor Personnel

Science.gov (United States)

Report #17-P-0409, September 27, 2017. Not vetting contractor personnel before granting them network access exposes the EPA to risks. Contractor personnel with potentially questionable backgrounds who access sensitive agency data could cause harm.

Vertical integration of basic science in final year of medical education.

Science.gov (United States)

Rajan, Sudha Jasmine; Jacob, Tripti Meriel; Sathyendra, Sowmya

2016-01-01

Development of health professionals with ability to integrate, synthesize, and apply knowledge gained through medical college is greatly hampered by the system of delivery that is compartmentalized and piecemeal. There is a need to integrate basic sciences with clinical teaching to enable application in clinical care. To study the benefit and acceptance of vertical integration of basic science in final year MBBS undergraduate curriculum. After Institutional Ethics Clearance, neuroanatomy refresher classes with clinical application to neurological diseases were held as part of the final year posting in two medical units. Feedback was collected. Pre- and post-tests which tested application and synthesis were conducted. Summative assessment was compared with the control group of students who had standard teaching in other two medical units. In-depth interview was conducted on 2 willing participants and 2 teachers who did neurology bedside teaching. Majority (>80%) found the classes useful and interesting. There was statistically significant improvement in the post-test scores. There was a statistically significant difference between the intervention and control groups' scores during summative assessment (76.2 vs. 61.8 P Vertical integration of basic science in final year was beneficial and resulted in knowledge gain and improved summative scores. The classes were found to be useful, interesting and thought to help in clinical care and application by majority of students.

2006 Fundamental Research Underlying Solid-State Lighting: Contractors Meeting

Energy Technology Data Exchange (ETDEWEB)

Fitzsimmons, Tim [Dept. of Energy (DOE), Washington, DC (United States). Office of Basic Energy Sciences. Division of Materials Sciences and Engineering; Kini, Arvind [Dept. of Energy (DOE), Washington, DC (United States). Office of Basic Energy Sciences. Division of Materials Sciences and Engineering; Kelley, Dick [Dept. of Energy (DOE), Washington, DC (United States). Office of Basic Energy Sciences. Division of Materials Sciences and Engineering

2006-02-01

This volume highlights the scientific content of the 2006 Fundamental Research Underlying Solid-State Lighting Contractors Meeting sponsored by the Division of Materials Sciences and Engineering (DMS&E) in the Office of Basic Energy Sciences (BES) of the U. S. Department of Energy (DOE). This meeting is the second in a series of research theme-based Contractors Meetings and will focus on BES/DMS&E-funded research that underpins solid-state lighting technology. The meeting will feature research that cuts across several DMS&E core research program areas. The major programmatic emphasis is on developing a fundamental scientific base, in terms of new concepts and new materials that could be used or mimicked in designing novel materials, processes or devices.

Attitude of final year medical students of a Nigerian university ...

African Journals Online (AJOL)

Doctors' attitude towards homosexuality may determine their responses and care for patients whose sexual orientation is homosexuality. Despite this, there is near absence of data on the attitude of medical students to homosexuals in Nigeria. Thus, this study investigated the attitude of final year medical students to ...

Education Intervention on Chronotherapy for Final-Year Pharmacy Students

Directory of Open Access Journals (Sweden)

Gagandeep Kaur

2015-11-01

Full Text Available Chronotherapy involves altering the timing of medication administration in coordination with the body’s circadian rhythms to improve the overall control of disease and to minimise treatment side effects. Training on chronotherapy requires students to map different topics learnt in earlier years of their professional degree and apply these concepts clinically. This requires strategic educational design. Therefore, the aim of the study was to develop, implement and evaluate an educational intervention focusing on the application of chronotherapy for final-year undergraduate pharmacy students. An educational intervention utilizing multiple learning strategies for enhancing chronotherapy related awareness was designed and implemented in the final year undergraduate pharmacy cohort at the University of Sydney Australia (2013. A custom-designed questionnaire measuring awareness about (13 items scored 0 or 1, and attitudes (12 items scored on a Likert scale of 1–5 towards chronotherapy was administered pre and post intervention to evaluate its impact. The pre-intervention mean total awareness and attitude scores were 6.5 ± 2.0 (score range 0–13 and 47.4 ± 6.9 (score range 12–60 respectively. The mean total post-intervention scores were significantly higher for total awareness (10.1 ± 1.9 and attitude (54.0 ± 6.0. Carefully designed educational interventions utilising pedagogic principles for pharmacy students can improve awareness of and enhance positive attitudes toward pharmacists’ roles in optimizing drug therapy using chronotherapy.

Contractor selection: a quantitative, consensus-friendly, transparent ...

African Journals Online (AJOL)

This article offers a method for selecting contractors in an objective, transparent and participative way. The use of the Decision Analysis System (DAS), also referred to as decision-making by objectives, makes it possible that a large number of objectives can be taken into account to select the best amongst a wide range of ...

Control of subcontractors by civil works contractor for a nuclear power plant

International Nuclear Information System (INIS)

Jiang Xinguo

1995-10-01

The civil works (CW) contractor is responsible for managing its subcontractors according to the requirements of quality assurance programme including the establishment of organization, quality assurance management, document control, material control, construction schedule control, inspection and test control, non-conformance control, corrective actions and executive technical files. The responsibilities of the plant owner, the CW contractor and its subcontractors in relation to performing their functions in the above-mentioned activities are described in detail

Control of subcontractors by civil works contractor for a nuclear power plant

Energy Technology Data Exchange (ETDEWEB)

Xinguo, Jiang [Huaxing Construction Company, Yizheng, JS (China)

1995-10-01

The civil works (CW) contractor is responsible for managing its subcontractors according to the requirements of quality assurance programme including the establishment of organization, quality assurance management, document control, material control, construction schedule control, inspection and test control, non-conformance control, corrective actions and executive technical files. The responsibilities of the plant owner, the CW contractor and its subcontractors in relation to performing their functions in the above-mentioned activities are described in detail.

Security of payment regime in construction industry: are Malaysian sub-contractors ready?

OpenAIRE

Supardi, Azizan; Adnan, Hamimah; Mohammad, Mohammad Fadhil

2011-01-01

In Malaysia, the particularly small sized sub-contractors are definitely benefited from payment provisions in the proposed Construction Industry Payment and Adjudication Act (CIPA Act), but need to enhance their knowledge in order to improve their awareness of the benefits of the Act. Accordingly, this on-going research attempts to introduce proper guidelines to the sub-contractors, in giving the knowledge, to claim for payment. Firstly, the research explored the problems and legal issues rel...

Technical Assistance Contractor management plan. Revision 1

Energy Technology Data Exchange (ETDEWEB)

NONE

1995-08-01

The Technical Assistance Contractor (TAC) for the Uranium Mill Tailings Remedial Action (UMTRA) Project comprises Jacobs Engineering Group Inc. (JEG) as the prime contractor and three teaming partner subcontractors: Roy F. Weston, Inc. (RFW), AGRA Earth and Environmental, Inc. (AGRA), and Geraghty and Miller, Inc. (G and M). The TAC contract`s scope is to provide technical, analytical, environmental, engineering, design, inspection, and management support services to the US Department of Energy (DOE) for both Surface and Ground Water Projects. The TAC team supports the DOE in completing surface remedial action and initiating ground water remediation work for start-up, characterization, compliance planning, design, construction oversight, and remedial operations. The TAC provides the DOE UMTRA Project Team with a dedicated management, scientific, and technical resource base in Albuquerque, New Mexico, which is supplemented by corporate resources. A carefully developed and maintained staff of technical experts is available to assess, analyze, develop, and execute cost-effective solutions to the demanding technical and institutional problems presented by the UMTRA Project.

Evaluation Criteria to Deliverables Crosswalk for the Tank Farm Contractor (Supercedes HNF-2020)

International Nuclear Information System (INIS)

WOJTASEK, R.D.

2000-01-01

Before the Office of River Protection can authorize proceeding with Phase 1B, the Tank Farm Contractor (TFC) must demonstrate readiness to retrieve and deliver the waste to the privatization contractor and to receive and dispose of the products and by-products returned from treatment. The TFC has organized their plans for providing these support services into the within the River Protection Project

Defense Organization Officials Did Not Consistently Comply With Requirements for Assessing Contractor Performance

Science.gov (United States)

2017-02-01

must evaluate compliance with reporting requirements frequently so they can readily identify delinquent past performance reports.24 The FAR also...problems the contractor recovered from without impact to the contract/ order. There should have been no significant weaknesses identified. A...contractor had trouble overcoming and state how it impacted the Government. A Marginal rating should be supported by referencing the management tool

Highway vehicle systems contractors coordination meeting. Seventeenth summary report

Energy Technology Data Exchange (ETDEWEB)

None

1979-01-01

Separate abstracts was prepared for each of the 62 papers presented at the Contractors' Coordination meeting on highway vehicle systems. One paper had previously appeared in DOE's data base.

76 FR 27648 - Submission for OMB Review; Preventing Personal Conflicts of Interest for Contractor Employees...

Science.gov (United States)

2011-05-12

...; Preventing Personal Conflicts of Interest for Contractor Employees Performing Acquisition Functions AGENCY... approve a new information collection requirement regarding Preventing Personal Conflicts of Interest for... Conflicts of Interest for Contractor Employees Performing Acquisition Functions by any of the following...

DOE Human Genome Program contractor-grantee workshop

Energy Technology Data Exchange (ETDEWEB)

NONE

1996-01-01

This volume contains the proceedings for the DOE Human Genome Program`s Contractor-Grantee Workshop V held in Sante Fe, New Mexico January 28, February 1, 1996. Presentations were divided into sessions entitled Sequencing; Mapping; Informatics; Ethical, Legal, and Social Issues; and Infrastructure. Reports of individual projects described herein are separately indexed and abstracted for the database.

78 FR 17673 - Federal Acquisition Regulation; Submission for OMB Review; Contractors' Purchasing Systems Reviews

Science.gov (United States)

2013-03-22

... collection would violate the fundamental purposes of the Paperwork Reduction Act because of the burden it... subcontracting. We submit that fundamental preparation for a review is part of a contractor's normal course of... accounting of the contractors' time expenditure needed to prepare for a CPSR and respond to any contracting...

48 CFR 45.402 - Title to contractor-acquired property.

Science.gov (United States)

2010-10-01

... the contract. Under fixed-price type contracts, in the absence of financing provisions or other... item. If a deliverable item is to be retained by the contractor for use after inspection and acceptance...

Poor academic performance: A perspective of final year diagnostic radiography students

International Nuclear Information System (INIS)

Gqweta, Ntokozo

2012-01-01

Introduction: A study was conducted on final year diagnostic radiography students at a University of Technology in Durban. The aim of the study was to investigate the final year diagnostic radiography students' opinions and views on academic performance in order to inform teaching and learning methods. The objectives were: •To explore the students' opinions regarding poor performance. •To identify strategies to improve academic performance. Method: A qualitative, interpretive approach was used to explain and understand the students' lived experiences of their academic performances. A short open ended questionnaire was administered to a cohort of final diagnostic radiography students following feedback on a written assessment. Questionnaire responses were then manually captured and analyzed. Results: Five (5) themes were identified that could possibly be associated with poor academic performance. These themes were, poor preparation, lack of independent study, difficulty in understanding learning content and misinterpretation of assessment questions, inefficient studying techniques as well as perceived improvement strategies. Conclusion: Students identified their inadequate preparation and the lack of dedicated independent studying as the main reasons for poor performance. Students preferred to be taught in an assessment oriented manner. However their identified improvement strategies were aligned with the learner centred approach.

What Do Final Year Engineering Students Know about Sustainable Development?

Science.gov (United States)

Nicolaou, I.; Conlon, E.

2012-01-01

This paper presents data from a project that aims to determine the level of knowledge and understanding of engineering students about sustainable development (SD). The data derive from a survey completed by final year engineering students in three Irish Higher Education Institutions. This paper is part of a larger study that examines the…

Needs of Non Energy-Focused Contractors

Energy Technology Data Exchange (ETDEWEB)

Liaukus, C.

2012-12-01

To better understand the informational needs of non energy-focused contractors, including what information they need to motivate them to become energy-focused, the BARA team studied the type of information provided by the national programs, trade associations, and manufacturers that were researched for the related technical report: Effective Communication of Energy Efficiency. While that report focused on the delivery method, format, and strategy of the information, this study examines the content being put forward.

Needs of Non-Energy Focused Contractors

Energy Technology Data Exchange (ETDEWEB)

Liakus, C. [Building Media and the Building America Retrofit Alliance (BARA), Wilmington, DE (United States)

2012-12-01

To better understand the informational needs of non-energy focused contractors, including what information they need to motivate them to become energy-focused, the BARA team studied the type of information provided by the national programs, trade associations, and manufacturers that were researched for the related technical report: Effective Communication of Energy Efficiency. While that report focused on the delivery method, format, and strategy of the information, this study examines the content being put forward.

Contractors on the Battlefield Force Multipliers or Force Dividers?

National Research Council Canada - National Science Library

Nelson, Kim

2000-01-01

.... An increased reliance on contractor support has helped ease the burden on a heavily reduced force structure, but has left military commanders vulnerable to declaring a non-mission capable status during times of crisis...

On the relationship between financial measures and contractor pricing strategy: Empirical tests in the defense aerospace industry

OpenAIRE

Moses, O. Douglas

1987-01-01

This report includes two separate but related empirical studies of the relationship between financial measures for defense aerospace contractors and pricing strategies adopted by contractors. Two pricing strategies are identified: skimming and penetration. Collectively the findings indicate that the adoption of a particular pricing strategy is associated with the financial condition of the contractor as reflected in measures of risk, asset utilization and organizational slack. Keywords: Finan...

75 FR 78755 - Notice of Initial Determination Revising the List of Products Requiring Federal Contractor...

Science.gov (United States)

2010-12-16

... Products Requiring Federal Contractor Certification as to Forced/Indentured Child Labor Pursuant to... products requiring federal contractor certification as to the use of forced or indentured child labor. To.... 13126 (``Prohibition of Acquisition of Products Produced by Forced or Indentured Child Labor''), in...

77 FR 59418 - Notice of Initial Determination Revising the List of Products Requiring Federal Contractor...

Science.gov (United States)

2012-09-27

... of products requiring federal contractor certification as to the use of forced or indentured child... DEPARTMENT OF LABOR Notice of Initial Determination Revising the List of Products Requiring Federal Contractor Certification as to Forced/Indentured Child Labor Pursuant to Executive Order 13126...

76 FR 61384 - Notice of Initial Determination Revising the List of Products Requiring Federal Contractor...

Science.gov (United States)

2011-10-04

... Maintenance of the List of Products Requiring Federal Contractor Certification as to Forced or Indentured... DEPARTMENT OF LABOR Notice of Initial Determination Revising the List of Products Requiring Federal Contractor Certification as to Forced/Indentured Child Labor Pursuant to Executive Order 13126...

40 CFR 35.938-6 - Progress payments to contractors.

Science.gov (United States)

2010-07-01

... on nor diverted to another job; and (iii) A fabrication period of more than 6 months is anticipated...: (i) A first payment upon submission by the prime contractor of shop drawings for the equipment or...

75 FR 69037 - Medicaid Program; Recovery Audit Contractors

Science.gov (United States)

2010-11-10

... DEPARTMENT OF HEALTH AND HUMAN SERVICES Centers for Medicare & Medicaid Services 42 CFR Part 455 [CMS-6034-P] RIN 0938-AQ19 Medicaid Program; Recovery Audit Contractors AGENCY: Centers for Medicare & Medicaid Services (CMS), HHS. ACTION: Proposed rule. SUMMARY: This proposed rule would provide guidance to...

Comparative Study On The Ethical Perceptions Of Contractors And Designers In The China Construction Industry

Science.gov (United States)

Kang, Byung Gyoo; Long, Kaiwen; Zhang, Cheng; Li Hao, Jian

2017-12-01

Ethics is becoming one of the most important requirements for successful business in the 21st century. The construction industry cannot be exceptional from this trend. However construction ethics management requires different approaches from other industries, as the products of the industry are construction projects which are completely different from mass production. Contractors and designers are two major participants in construction projects. The roles and responsibilities of these two project stakeholders decisively influence all aspects of construction project. Practically ethical perceptions of contractors and designers are one of main aspects to be considered for the effective and efficient management of ethics for the construction industry. This research has investigated the ethical perceptions of contractors and designers in the China construction industry. A questionnaire survey which contains 15 ethical issues and 6 demographic factors has been conducted. 170 construction professionals from construction companies and consulting companies have been participated in this survey. These 15 ethical issues are ranked in terms of seriousness, frequency and importance for both contractors and designers as a single group to understand the overall perceptions in the industry. The analysis has also been conducted for contractors and designers respectively to make comparisons between them. The top three serious ethical issues in the industry are ‘Bribery and corruption’, ‘Failure to practice whistle-blowing’ and ‘Improper bidding practices’. Contractors and designers showed similar outcomes for the top five important ethical issues. But for the middle ranged ethical issues, they showed some differences. Further researches are required to identify the causes of the similarity and differences.

48 CFR 970.2703-2 - Patent rights clause provisions for management and operating contractors.

Science.gov (United States)

2010-10-01

...-by-case basis. If the time period expired due to negligence by the contractor, DOE may grant a... to avoid such negligence in the future. If a contractor is requesting an extension of time in which... Law 101-189, section 3133(d), and the DOE owned facility is involved in weapons related research and...

Global petroleum fiscal systems compared by contractor take

International Nuclear Information System (INIS)

Johnston, D.

1994-01-01

Petroleum fiscal terms in most countries are tougher than in the US, but these countries have more geological potential and still may be economically attractive. The market for exploration capital and technology is super competitive and getting more sophisticated. Governments are increasingly aware of the global market for exploration acreage or rehabilitation projects. For many oil companies, an important part of the negotiations is to secure terms acceptable to the potential partner. Knowing the market and what terms are realistic depends on a region's potential and other factors. Most countries developing petroleum fiscal systems are opting for the production sharing contract (PSC). This trend began in the 1960s. Now, nearly half of the countries with petroleum potential have a system based on the PSC. However, financial results could be the same in a royalty/tax arrangement. Economics depend primarily on division of profits or what is known as government/contractor take. The paper discusses contractor take, estimating take, Indonesian split, and take implications

A Novel Approach to Selecting Contractor in Agent-based Multi-sensor Battlefield Reconnaissance Simulation

Directory of Open Access Journals (Sweden)

Xiong Li

2012-11-01

Full Text Available This paper presents a novel approach towards showing how contractor in agent-based simulation for complex warfare system such as multi-sensor battlefield reconnaissance system can be selected in Contract Net Protocol (CNP with high efficiency. We first analyze agent and agent-based simulation framework, CNP and collaborators, and present agents interaction chain used to actualize CNP and establish agents trust network. We then obtain contractor's importance weight and dynamic trust by presenting fuzzy similarity-based algorithm and trust modifying algorithm, thus we propose contractor selecting approach based on maximum dynamic integrative trust. We validate the feasibility and capability of this approach by implementing simulation, analyzing compared results and checking the model.

Impact of Extending Sexual Orientation and Gender Identity Nondiscrimination Requirements to Federal Contractors

OpenAIRE

Badgett, M.V. Lee

2012-01-01

A federal executive order that would require contractors to prohibit discrimination based on sexual orientation and gender identity would protect up to 16.5 million more workers than are already protected by state or private anti-discrimination policies. Currently, state laws or private voluntary policies already protect 61% of federal contractor employees from sexual orientation discrimination and 41% from gender identity discrimination. Research also suggests an executive order would not di...

Use of mobile learning technology among final year medical students in Kenya.

Science.gov (United States)

Masika, Moses Muia; Omondi, Gregory Barnabas; Natembeya, Dennis Simiyu; Mugane, Ephraim Mwatha; Bosire, Kefa Ogonyo; Kibwage, Isaac Ongubo

2015-01-01

Mobile phone penetration has increased exponentially over the last decade as has its application in nearly all spheres of life including health and medical education. This study aimed at assessing the use of mobile learning technology and its challenges among final year undergraduate students in the College of Health sciences, University of Nairobi. This was a cross-sectional descriptive study conducted among final year undergraduate students at the University of Nairobi, College of Health Sciences. Self-administered, anonymous questionnaires were issued to all final year students in their lecture rooms after obtaining informed consent. Data on demographics, mobile device ownership and mobile learning technology use and its challenges was collected. Data entry and analysis was done using SPSS(®). Chi-square and t-test were used for bivariate analysis. We had 292 respondents; 62% were medical students, 16% were nursing students, 13% were pharmacy students and 9% were dental surgery students. The majority were female (59%) and the average age was 24 years. Eighty eight percent (88%) of the respondents owned a smart device and nearly all of them used it for learning. 64% of the respondents used medical mobile applications. The main challenges were lack of a smart device, lack of technical know-how in accessing or using apps, sub-optimal internet access, cost of acquiring apps and limited device memory. Mobile learning is increasingly popular among medical students and should be leveraged in promoting access and quality of medical education.

Prenatal sex and other preferences for reproductive career of final year graduation girl students

Directory of Open Access Journals (Sweden)

Yugantara R Kadam

2013-01-01

Full Text Available Background: Marriage of girls just after graduation is common in Western Maharashtra. This study was planned to know the views of final year graduation student towards reproductive carrier. Aim: To interact with final year girl students of various streams to know their preferences on various aspects of reproductive carrier and contraceptive awareness. Material and Methods: Study-design: Cross-sectional. Study-setting: Academic institutes of Sangli-Miraj-Kupwad Corporation area. Study-subject: All willing final year Girl students. Exclusion Criteria: Married girls. Sample size: All final year girl students Sampling Technique: Cluster sample Study-Duration: 7 months. Study-tool: Pretested questionnaire. Statistical Analysis: Percentages, Chi-square test. Results: All girls who have responded prefer marrying and having first child at right age. All feel spacing is needed, at least of 2 years. Two children was the most common choice (52.3%. Forty-three percent girls feel male child is must and 52.3% of total girls will like to have sex determination done if required. Total 47.24% girls were unaware about any contraceptive methods but 88.2% girls knew the place of its availability. Most common source of information about contraceptive was school and friends. E-pill was known to 41.5% of girls. All girls felt the need for more information about reproductive health and according to 81.3% right age for it is 15-18 years. Conclusion: Girls have correct reproductive preferences except sex of child. Sex preference and Low contraceptive awareness needs strong intervention.

Investigating the determinants of contractor's construction and demolition waste management behavior in Mainland China.

Science.gov (United States)

Wu, Zezhou; Yu, Ann T W; Shen, Liyin

2017-02-01

The abundant generation of construction and demolition (C&D) waste presents a significant challenge to the sustainable development of the construction industry in Mainland China. As the implementer of construction activities, the contractor's C&D waste management performance plays an important role in C&D waste minimization. This paper aims to investigate the determinants of the contractor's C&D waste management behavior in Mainland China. The Theory of Planned Behavior (TPB) was selected as the basis of the theoretical model. In addition, three contextual constructs (i.e., economic viability, governmental supervision, and project constraints) were introduced, formulating the initial model. Based on the initial model, eight constructs were identified and seven hypotheses were proposed. A questionnaire survey was conducted to collect data and a Structural Equation Modeling (SEM) analysis was employed to test the proposed hypotheses. Results showed that the C&D waste management intention is not a significant determinant of contractor's C&D waste management behavior. The most important determinant is economic viability, followed by governmental supervision as the second most important determinant. Nevertheless, the construct of project constraints is an insignificant determinant for contractor's adoption of C&D waste management behavior. The research findings imply that, in Mainland China, the government, at this stage, plays an important role in guiding and promoting the contractor to exhibit better C&D waste management behavior. Copyright © 2016 Elsevier Ltd. All rights reserved.

Determining Success Criteria and Success Factors for International Construction Projects for Malaysian Contractors

Directory of Open Access Journals (Sweden)

Ali Mohammed Alashwal

2017-06-01

Full Text Available The success of international construction projects is fraught with various challenges such as competitiveness, lack of resources, versatile global economy, and specific conditions in the host country. Malaysian contractors have been venturing into global construction market since early 1980s. However, their venturing was not successful all the time. The number of international projects awarded to Malaysian contractors has reduced drastically during the past decade. Taking advantage of this experience, this paper aims to identify the success criteria and success factors of international construction projects. The data was collected from 120 respondents using a questionnaire survey and analysed using principal component analysis and regression analysis. The results revealed three principal criteria of project success namely, Management Success, Functional Success, and Organisation Success. The main components of success factors include Team Power and Skills, Resource Availability, External Environment, Organisation Capability, Project Support, and Project Organisation. Further analysis emphasized the importance of strong financing capacity of contractors, project social environment, and competence of the project manager in achieving project success. The results of this paper can serve as a guideline for contractors and project managers to achieve success in this context. Future studies may provide in-depth analysis of success criteria and success factors specific for construction project type and host-country location.

Program Evaluation: A Consumer Evaluation of Alternative Contractor Concepts in Government Food Service

Science.gov (United States)

1974-09-01

food service facilities. The food factors (quality, variety, and quantity, in that order) were generally rated by consumers as most serious problems, in keeping with many previous survey studies of military food service system. The contractor food service concept with raw food provided by the contractor, as exemplified by Fort Myer, significantly reduced consumer problems in food service personnel, speed, hours, environment, and convenience of location, and also reduced the degree to which food variety,

48 CFR 939.7002 - Contractor acquisition of information technology.

Science.gov (United States)

2010-10-01

... information technology. 939.7002 Section 939.7002 Federal Acquisition Regulations System DEPARTMENT OF ENERGY SPECIAL CATEGORIES OF CONTRACTING ACQUISITION OF INFORMATION TECHNOLOGY Implementing DOE Policies and Procedures 939.7002 Contractor acquisition of information technology. (a) Management and operating (M&O...

48 CFR 919.7006 - Incentives for DOE contractor participation.

Science.gov (United States)

2010-10-01

... disadvantaged businesses, women-owned small businesses, HBCUs, other minority institutions of higher learning... contractor participation. 919.7006 Section 919.7006 Federal Acquisition Regulations System DEPARTMENT OF ENERGY SOCIOECONOMIC PROGRAMS SMALL BUSINESS PROGRAMS The Department of Energy Mentor-Protege Program 919...

Is Late or Non-Payment a Significant Problem to Malaysian Contractors?

Directory of Open Access Journals (Sweden)

M.E. Che Munaaim

2007-12-01

Full Text Available Some developed countries have drawn lip construction-specific statutory security of payment acts/legislations typically known as Construction Contracts Act to eliminate poor payment practices and to assist continuous uninterrupted construction works. Malaysia too cannot pretend not to have these problems. This paper presents findings of a study conducted amongst Malaysian contractors with the aims to determine the seriousness of late and non- payment problems; to identify the main causes and effects of late and non-payment; and to identify ways to sustain the payment flows in the Malaysian construction industry. The study focused on contractual payments from the paymaster (government or private to the contractors. The main factors for late and nonpayment in the construction industry identified from the study include: delay in certification, paymaster's poor financial management, local culture/attitude, pay master's failure to implement good governance in business, underpayment of certified amounts by the pay master and the use of 'pay when paid' clauses in contracts. The research findings show that late and non-payment can create cash flow problems, stress and financial hardship on the contractors. Amongst the most appropriate solutions to overcome the problem of late and non-payment faced by local contractors include: a right to regular periodic payment, a right to a defined time frame (or payment and a right to a speedy dispute resolution mechanism. Promptness of submitting, processing, issuing interim payment certificates and honouring the certificates are extremely important issues in relation to progress payment claims. Perhaps, an increased sense of professionalism in construction industry could overcome some of the problems related to late and non- payment issues.

Final-year student nurses' perceptions of role transition.

Science.gov (United States)

Doody, Owen; Tuohy, Dympna; Deasy, Christine

Role transition can be both challenging and exciting. This study presents the findings of phase one of a two-part study conducted by Deasy et al (2011), which explored final-year student nurses' (n=116) perceptions and expectations of role transition. The students were registered on four-year BSc nursing programmes at an Irish university. Data was analyzed using SPSS (version 16). A response rate of 84% was achieved. Over half of respondents said they were adequately prepared for the post of registered nurse. Respondents generally perceived themselves to be competent across a range of domains: managing workloads; prioritizing care delivery; interpersonal skills; time management skills; ethical decision making; and providing health information and education. In contrast, not all were confident about their knowledge and many expected the transition to be problematic. Most expected to be supported and to receive constructive feedback. Recommendations include nurturing supportive work environments to reduce stress and increase confidence.

Preaward Evaluation and Responsibility Determination of Foreign Contractors.

Science.gov (United States)

1988-12-01

3 Contractor Country Contract Number Bundesamt Fuer Wehrtechnik FRG DAJA3786C0326 Bundesamt Fuer Wehrtechnik FRG F6154686D0022 Construcciones ...Aeronauticas SA Spain F0960385C0006 Construcciones Aeronauticas SA Spain F4260086C6464 Daimler Benz AG FRG DAJA3778GOO11 Eaton Corp. FRG F0960382D0663

Research 0n Incentive Mechanism of General Contractor and Subcontractors Dynamic Alliance in Construction Project Based on Team Cooperation

Science.gov (United States)

Yin, Honglian; Sun, Aihua; Liu, Quanru; Chen, Zhiyi

2018-03-01

It is the key of motivating sub-contractors working hard and mutual cooperation, ensuring implementation overall goal of the project that to design rational incentive mechanism for general contractor. Based on the principal-agency theory, the subcontractor efforts is divided into two parts, one for individual efforts, another helping other subcontractors, team Cooperation incentive models of multiple subcontractors are set up, incentive schemes and intensities are also given. The results show that the general contractor may provide individual and team motivation incentives when subcontractors working independently, not affecting each other in time and space; otherwise, the general contractor may only provide individual incentive to entice teams collaboration between subcontractors and helping each other. The conclusions can provide a reference for the subcontract design of general and sub-contractor dynamic alliances.

Performance-Based Contractor Prequalification as an Alternative to Performance Bonds

Science.gov (United States)

2014-08-01

State departments of transportation rely on private industry construction contractors to build, rehabilitate, and replace their infrastructure assets. The Federal Highway Administration (FHWA) is interested in providing guidance that State transporta...

Do final-year medical students have sufficient prescribing competencies? A systematic literature review.

Science.gov (United States)

Brinkman, David J; Tichelaar, Jelle; Graaf, Sanne; Otten, René H J; Richir, Milan C; van Agtmael, Michiel A

2018-04-01

Prescribing errors are an important cause of patient safety incidents and are frequently caused by junior doctors. This might be because the prescribing competence of final-year medical students is poor as a result of inadequate clinical pharmacology and therapeutic (CPT) education. We reviewed the literature to investigate which prescribing competencies medical students should have acquired in order to prescribe safely and effectively, and whether these have been attained by the time they graduate. PubMed, EMBASE and ERIC databases were searched from the earliest dates up to and including January 2017, using the terms 'prescribing', 'competence' and 'medical students' in combination. Articles describing or evaluating essential prescribing competencies of final-year medical students were included. Twenty-five articles describing, and 47 articles evaluating, the prescribing competencies of final-year students were included. Although there seems to be some agreement, we found no clear consensus among CPT teachers on which prescribing competencies medical students should have when they graduate. Studies showed that students had a general lack of preparedness, self-confidence, knowledge and skills, specifically regarding general and antimicrobial prescribing and pharmacovigilance. However, the results should be interpreted with caution, given the heterogeneity and methodological weaknesses of the included studies. There is considerable evidence that final-year students have insufficient competencies to prescribe safely and effectively, although there is a need for a greater consensus among CPT teachers on the required competencies. Changes in undergraduate CPT education are urgently required in order to improve the prescribing of future doctors. © 2018 VU University Medical Centre. British Journal of Clinical Pharmacology published by John Wiley & Sons Ltd on behalf of British Pharmacological Society.

Owner and Contractor Perceptions Toward Factors Causing Delays in Structural and Finishing Works

Directory of Open Access Journals (Sweden)

Loanata V.R.

2010-01-01

Full Text Available A construction project comprises of a number of work packages, which are subjected to delays. These delays may be caused by many on-site factors. The aim of this research is to represent owner and contractors perceptions towards delay factors that frequently occur in structural and finishing works. Data for analysis were gathered by distributing questionnaire. A total of 198 sets of questionnaire were gathered and used for subsequent analyses. In general, design changes during construction are perceived by respondents as the most frequent factor to cause delay in all structural and finishing works. The results also show that there are a number of differences between owner’s and contractor’s perceptions towards the occurrences of the factors. Whilst most contractors concern that information factors related to project design and scope frequently causing delays in construction works, owners consider many contractor originated factors, as most frequent delay causes.

77 FR 54864 - Federal Acquisition Regulation; Documenting Contractor Performance

Science.gov (United States)

2012-09-06

....g., late or nonpayment to subcontractors, trafficking violations, tax delinquency, failure to report... applicable) (e.g.; late or nonpayment to subcontractors, trafficking violations, tax delinquency, failure to... that allowing contractors to ``report to the CPARS system'' would have a negative impact on future...

A Management Case Analysis of the Department of Defense Contractor Risk Assessment Guide Program

Science.gov (United States)

1990-12-01

ORGANIZATION ......... 17 1. Past Government Organization Problems... 17 2. Current Government Organization ......... 17 3. The Contractor’s Organizatin ...Program and urged CODSIA to take a leadership role in encouraging its members to participate. The DCAA [Ref ll:p. 45] informed defense contractors in...conferences, and through the leadership of officials including the Under Secretary of the Navy for Acquisition, DOD Comptroller General, DOD Inspector General

Analysis of final year DVM research projects submitted to the Faculty ...

African Journals Online (AJOL)

This study analyzed the intellectual output of the undergraduate final year students. research projects submitted to the Faculty of Veterinary Medicine, Usmanu Danfodiyo University, Sokoto, from 1994 to 2004. The findings of the study show that a total of 194 research projects were produced within the period under study.

A Compulsory Bioethics Module for a Large Final Year Undergraduate Class

Science.gov (United States)

Pearce, Roger S.

2009-01-01

The article describes a compulsory bioethics module delivered to [approximately] 120 biology students in their final year. The main intended learning outcome is that students should be able to analyse and reason about bioethical issues. Interactive lectures explain and illustrate bioethics. Underlying principles and example issues are used to…

Reflective ability and moral reasoning in final year medical students: a semi-qualitative cohort study.

Science.gov (United States)

Chalmers, Patricia; Dunngalvin, Audrey; Shorten, George

2011-01-01

Moral reasoning and reflective ability are important concepts in medical education. To date, the association between reflective ability and moral reasoning in medical students has not been measured. This study tested the hypotheses that, amongst final year medical students, (1) moral reasoning and reflective ability improve over time and (2) positive change in reflective ability favourably influences moral reasoning. With Institutional Ethical approval, 56 medical students (of a class of 110) participated fully both at the beginning and end of the final academic year. Reflective ability and moral reasoning were assessed at each time using Sobral's reflection-in-learning scale (RLS), Boenink's overall reflection score and by employing Kohlberg's schema for moral reasoning. The most important findings were that (1) Students' level of reflective ability scores related to medicine decreased significantly over the course of the year, (2) students demonstrated a predominantly conventional level of moral reasoning at both the beginning and end of the year, (3) moral reasoning scores tended to decrease over the course of the year and (4) RLS is a strong predictor of change in moral reasoning over time. This study confirms the usefulness of Sobral's RLS and BOR score for evaluating moral development in the context of medical education. This study further documents regression and levelling in the moral reasoning of final year medical students and a decrease in reflective ability applied in the medical context. Further studies are required to determine factors that would favourably influence reflective ability and moral reasoning among final year medical students.

41 CFR 109-1.5204 - Review and approval of a designated contractor's personal property management system.

Science.gov (United States)

2010-07-01

... property management system. (a) An initial review of a designated contractor's personal property management... follow-on contract. The purpose of the review is to determine whether the contractor's system provides... by the property administrator that all major system deficiencies identified in the review or...

Summary Report of the Seventh Annual NASA/Contractors Conference on Quality and Productivity: "Total Quality Leadership"

Science.gov (United States)

1991-01-01

More than 750 NASA, government, contractor, and academic representatives attended the Seventh Annual NASA/Contractors Conference on Quality and Productivity on October 12-13, 1990, in Grenelefe, Florida. The panel presentations and keynote speeches revolving around the theme of 'Total Quality Leadership" provided a solid base of understanding of the importance, benefits, and principles of total quality management. The implementation of these strategies is critical if we are to effectively pursue our mission of continuous quality improvement and reliability in our products, processes, and services. The annual NASA/contractors conferences serve as catalysts for achieving success in this mission.

A pattern of contractor selection for oil and gas industries in a safety approach using ANP-DEMATEL in a Grey environment.

Science.gov (United States)

Gharedaghi, Gholamreza; Omidvari, Manouchehr

2018-01-11

Contractor selection is one of the major concerns of industry managers such as those in the oil industry. The objective of this study was to determine a contractor selection pattern for oil and gas industries in a safety approach. Assessment of contractors based on specific criteria and ultimately selecting an eligible contractor preserves the organizational resources. Due to the safety risks involved in the oil industry, one of the major criteria of contractor selection considered by managers today is safety. The results indicated that the most important safety criterion of contractor selection was safety records and safety investments. This represented the industry's risks and the impact of safety training and investment on the performance of other sectors and the overall organization. The output of this model could be useful in the safety risk assessment process in the oil industry and other industries.

Unit 1 and Unit 2 Nuclear Power Plant Mochovce construction finishing from primary contractor of technological part. Skoda Praha a. s. point of view

International Nuclear Information System (INIS)

Horky, F.

2000-01-01

In this paper the history of delivery of technological part for NPP V-1 Mochovce as well as of reconstruction and safety improvements by the Skoda Praha a.s. is presented. Primary contractor of technological part Skoda Praha together with its final suppliers proved ability to realize under hard conditions such a complicated work what was indisputedly Units 1 and 2 finishing. Company proved capability to conform itself flexibly in the course of work to requirements of customer for realization of safety measures which means that Units 1 and 2 fully satisfy international standards. By fulfilment of primary contractor of technology obligations and above all by takeover of complex responsibility for both Units putting in operation including responsibility for 'past' Skoda Praha put away one of basic problems which occurred in decision making to whom will be assigned construction finishing contract. These facts fully qualify Skoda Praha to be selected for possible Units 3 and 4 construction finishing as one of chief construction finishing participant

Sharing lessons learned and best practices in deactivation and decommissioning techniques among U.S. Department of Energy contractors

International Nuclear Information System (INIS)

Lackey, Michael B.; Waisley, Sandra L.; Dusek, Lansing G.

2007-01-01

Approximately $153.2 billion of work currently remains in the United States Department of Energy's (DOE's) Office of Environmental Management (EM) life cycle budget for United States projects. Contractors who manage facilities for the DOE have been challenged to identify transformational changes to reduce the life cycle costs and develop a knowledge management system that identifies, disseminates, and tracks the implementation of lessons learned and best practices. At the request of the DOE's EM Office of Engineering and Technology, the Energy Facility Contractors Group (EFCOG) responded to the challenge with formation of the Deactivation and Decommissioning (D and D) and Facility Engineering (DD/FE) Working Group. Since October 2006, members have already made significant progress in realizing their goals: adding new D and D best practices to the existing EFCOG Best Practices database; participating in lessons learned forums; and contributing to a DOE initiative on identifying technology needs. The group is also participating in a DOE project management initiative to develop implementation guidelines, as well as a DOE radiation protection initiative to institute a more predictable and standardized approach to approving authorized limits and independently verifying cleanup completion at EM sites. Finally, a D and D hotline to provide real-time solutions to D and D challenges is also being launched. (authors)

A contractor report to the Department of Energy on environmental management baseline programs and integration opportunities (discussion draft)

International Nuclear Information System (INIS)

1997-05-01

In July 1996, the US Department of Energy (DOE) Assistant Secretary for Environmental Management (EM) chartered a government contractor led effort to develop a suite of technically defensible, integrated alternatives which meet the EM mission. The contractor team was challenged to ''think outside-the-box'' for solutions that cross traditional site boundaries and enable the programs to get the job done at an earlier date and at a lower cost. This report documents baseline programs current plans for material disposition and presents the opportunities for additional acceleration of cleanup and cost savings. A graphical depiction of the disposition of EM-owned waste and material from current state to final disposition is shown as disposition maps in Attachments 1, 3, 5, 7, 9, and 11. These disposition maps detail the material disposition at eleven major DOE sites as planned in the current discussion draft plan, Accelerating Cleanup: Focus on 2006. Maps reflecting material disposition at additional sites will be added in the future. Opportunities to further accelerate the cleanup of DOE-EM sites and reduce the overall cost of cleanup are depicted in the alternative disposition maps shown in Attachments 2, 4, 6, 8, 10, and 12. These integration opportunities bring nation-wide resources to bear on common problems facing the DOE sites

MRP II (material requirements planning): one year later.

Science.gov (United States)

Tull, W L; Norman, R L

1994-08-01

This article addresses the continued need for the behavior change process that must be managed long after materiel requirements planning (MRP II) implementation. Mason & Hanger, Pantex Plant is the final assembly and dismantlement facility for all United States nuclear weapons. On October 1, 1990, Mason & Hanger implemented a full production cutover to MRP II. One year later, following class A certification, the MRP II implementation team is still actively managing the change process through education and training programs and overall continuous improvement initiatives. Actual behavior change problems are identified together with the proven solutions implemented in a government-owned, contractor-operated facility environment. Performance measurements ranging from senior management planning to shop floor accomplishments and cost variance reports are shown as normal management tools used to identify target improvement areas.

DOE Human Genome Program: Contractor-Grantee Workshop IV, November 13--17, 1994, Santa Fe, New Mexico

Energy Technology Data Exchange (ETDEWEB)

1994-10-01

This volume contains the proceedings of the fourth Contractor-Grantee Workshop for the Department of Energy (DOE) Human Genome Program. Of the 204 abstracts in this book, some 200 describe the genome research of DOE-funded grantees and contractors located at the multidisciplinary centers at Lawrence Berkeley Laboratory, Lawrence Livermore National Laboratory, and Los Alamos National Laboratory; other DOE-supported laboratories; and more than 54 universities, research organizations, and companies in the United States and abroad. Included are 16 abstracts from ongoing projects in the Ethical, Legal, and Social Issues (ELSI) component, an area that continues to attract considerable attention from a wide variety of interested parties. Three abstracts summarize work in the new Microbial Genome Initiative launched this year by the Office of Health and Environmental Research (OHER) to provide genome sequence and mapping data on industrially important microorganisms and those that live under extreme conditions. Many of the projects will be discussed at plenary sessions held throughout the workshop, and all are represented in the poster sessions.

Final-year medical students′ perceptions regarding the curriculum in public health

Directory of Open Access Journals (Sweden)

Mitrakrishnan Rayno Navinan

2011-01-01

Full Text Available Background: The Faculty of Medicine, University of Colombo, has an integrated curriculum in which teaching of public health takes place through a series of modules which span the full five-year study programme. Aim: To assess final year medical student perceptions regarding the public health curriculum and to identify factors which influence this. Materials and Methods: The study was cross sectional. Convenience sampling was utilized on final-year students of the Faculty of Medicine, University of Colombo, Sri Lanka. A self-administered 4-point Likert scale questionnaire covered general opinion on public healthcare and perceptions about the curriculum. Data were analyzed using descriptive statistics and Chi-square tests. Results: One hundred and eighty four students (94% participated in the study. Eighty-two percent (148 viewed public health as an important field. Only 9% (16 were interested in a career in public health. A significant association was found between choosing public health as career and the following: perception of public health as an important field; holding a good opinion about public health prior to commencement of the course; having found the field-based experience enjoyable and beneficial to the community; and feeling competent to work in the community at the end of the course (P < 0.01. With regard to teaching methods, group activities and discussion-centered activities were identified positively (153, 83% and 125, 68% respectively. The majority of students indicated that they were not stimulated to read more on the subject or regularly revise what they have learnt, both during the introductory public health programme and during the final year. Conclusions: The curriculum has been able to create a positive opinion about public health. However, students lack enthusiasm to learn independently. Experiential, group-centered teaching activities and a constructivist approach may be more effective in promoting independent learning

The selection of construction sub-contractors using the fuzzy sets theory

International Nuclear Information System (INIS)

Krzemiński, Michał

2015-01-01

The paper presents the algorithm for the selection of sub-contractors. Main area of author’s interest is scheduling flow models. The ranking task aims at execution time as short as possible Brigades downtime should also be as small as possible. These targets are exposed to significant obsolescence. The criteria for selection of subcontractors will not be therefore time and cost, it is assumed that all those criteria be meet by sub-contractors. The decision should be made in regard to factors difficult to measure, to assess which is the perfect application of fuzzy sets theory. The paper will present a set of evaluation criteria, the part of the knowledge base and a description of the output variable

Attitudes toward Psychiatry among Final-Year Medical Students in Kumasi, Ghana

Science.gov (United States)

Laugharne, Richard; Appiah-Poku, John; Laugharne, Jon; Shankar, Rohit

2009-01-01

Objective: Most sub-Saharan African countries have fewer psychiatrists than one per one million people. One possible reason could be that medical students have a negative attitude toward the specialty. The authors evaluated the attitudes toward a career in psychiatry of final-year medical students in Kumasi, Ghana, and compare these with attitudes…

Assessing the readiness of contractors in implementing low carbon ...

African Journals Online (AJOL)

For the implementation of low carbon construction in our construction industry, the contractors need to be ready and have knowledge to adopt low carbon construction ... A checklist was established by summarizing the highest low carbon activities from each category which were sustainable site planning and management, ...

78 FR 12106 - Debarment, Suspension, and Ineligibility of Contractors

Science.gov (United States)

2013-02-21

... include a recommendation by the SDC as to a proposed course of action; (2) The debarment decision-making... proposed debarment; (3) The suspension decision-making process, which shall afford the contractor (and any... Management, Contracting; Attention: Contracting Policy, 1900 E Street NW., Washington, DC 20415; or email...

75 FR 3977 - Addressing Tax Delinquency by Government Contractors

Science.gov (United States)

2010-01-25

... Part II The President Memorandum of January 20, 2010--Addressing Tax Delinquency by Government... of January 20, 2010 Addressing Tax Delinquency by Government Contractors Memorandum for the Heads of... contracts are awarded to tens of thousands of companies with serious tax delinquencies. The total amount in...

The operation of contractors on nuclear sites: French regulations

International Nuclear Information System (INIS)

Mayoux, J.C.; Derche, B.

1985-01-01

The first purpose of this paper is to show how the French common law -as it results from the code of labour and holdings of the courts- deals with the intervention of contractors. The second part analyses the special regulations in force to ensure radiation protection [fr

Maintenance and operations contractor plan for transition to the project Hanford management contract (PHMC)

Energy Technology Data Exchange (ETDEWEB)

Waite, J.L.

1996-04-12

This plan has been developed by Westinghouse Hanford Company (WHC), and its subcontractors ICF Kaiser Hanford (ICF KH) and BCS Richland, Inc. (BCSR), at the direction of the US Department of Energy (DOE), Richland Operations Office (RL). WHC and its subcontractors are hereafter referred to as the Maintenance and Operations (M and O) Contractor. The plan identifies actions involving the M and O Contractor that are critical to (1) prepare for a smooth transition to the Project Hanford Management Contractor (PHMC), and (2) support and assist the PHMC and RL in achieving transition as planned, with no or minimal impact to ongoing baseline activities. The plan is structured around two primary phases. The first is the pre-award phase, which started in mid-February 1996 and is currently scheduled to be completed on June 1, 1996, at which time the contract is currently planned to be awarded. The second is the follow-on four-month post-award phase from June 1, 1996, until October 1, 1996. Considering the magnitude and complexity of the scope of work being transitioned, completion in four months will require significant effort by all parties. To better ensure success, the M and O Contractor has developed a pre-award phase that is intended to maximize readiness for transition. Priority is given to preparation for facility assessments and processing of personnel, as these areas are determined to be on the critical path for transition. In addition, the M and O Contractor will put emphasis during the pre-award phase to close out open items prior to contract award, to include grievances, employee concerns, audit findings, compliance issues, etc.

Agencies Need Improved Financial Data Reporting for Private Security Contractors

National Research Council Canada - National Science Library

Warren, David R; Bianco, Michael A; Nasser, Waheed; Kusman, Richard R; Shafer, James; Venner, Jason; Walls, Lovell Q; Wright, Samson J

2008-01-01

Section 842 of the National Defense Authorization Act of 2008 (Public Law 110-181), required SIGIR to, among other things, develop a plan to evaluate various characteristics of contracting for private security contractor services in Iraq...

9 CFR 201.94 - Information as to business; furnishing of by packers, swine contractors, live poultry dealers...

Science.gov (United States)

2010-01-01

... of by packers, swine contractors, live poultry dealers, stockyard owners, market agencies, and... poultry dealers, stockyard owners, market agencies, and dealers. Each packer, swine contractor, live poultry dealer, stockyard owner, market agency, and dealer, upon proper request, shall give to the...

Bretylium potentiation of the contractor responses of isolated rabbit aortic strips to potassium and tyramine.

Science.gov (United States)

Kurahashi, K; Shibata, S

1971-09-01

1. Pretreatment of rabbit aortic strips with bretylium potentiated the contractor response to potassium and tyramine but not to noradrenaline. On the other hand, such pretreatment inhibited the response to nicotine.2. Even in reserpinized or cold stored aortic strips, pretreatment with bretylium enhanced the contractor response to potassium and tyramine.3. Pretreatment of fresh, reserpinized, or cold stored aortic strips with pheniprazine potentiated the contractor response to potassium and tyramine.4. Pretreatment of aortic strips with bretylium or pheniprazine did not potentiate the response to 5-hydroxytryptamine (5-HT).5. The results indicate that both bretylium and pheniprazine potentiate the action of tyramine and potassium, not by presynaptic mechanisms, but by postsynaptic action, causing an increase in the sensitivity of the effector cells to the stimulants.

24 CFR 1000.44 - What prohibitions on the use of debarred, suspended, or ineligible contractors apply?

Science.gov (United States)

2010-04-01

... 24 Housing and Urban Development 4 2010-04-01 2010-04-01 false What prohibitions on the use of debarred, suspended, or ineligible contractors apply? 1000.44 Section 1000.44 Housing and Urban Development... § 1000.44 What prohibitions on the use of debarred, suspended, or ineligible contractors apply? In...

Certification of ERDA contractors' packaging with respect to compliance with DOT specification 7A performance requirements

International Nuclear Information System (INIS)

Edling, D.A.; Griffin, J.F.

1975-01-01

The purpose of this study was to have one ERDA contractor: (1) compile a list of specification packagings, proposed by ERDA contractors, for shipping Type A quantities of radioactive material, and (2) analyze these packages for conformance to Specification 7A requirements. This study was divided into two phases. Phase I provides a report on those packages which could be shown, based on existing test data and engineering analyses, to conform to DOT Specification 7A packaging requirements. The results of Phase I are discussed in detail in the publication, ''Certification of AEC Contractor's Packagings With Respect to Compliance with DOT Specification 7A Performance Requirements -- Phase I Summary Report,'' D. A. Edling, H. E. Meyer and G. L. Phillabaum (Schedule 189C, May 26, 1974). The objectives of Phase II were: (1) identification of packages from Phase I for which available information was not adequate for certification. (Those specification containers used by ERDA contractors and those containers for which adequate information was available for certification are listed in the Phase I summary report.); (2) identification of specific test/engineering analysis data required; (3) generation/procurement of these data; and (4) documentation of study results for use by all ERDA contractors and private industry. The results of Phase II of the study are presented. (U.S.)

South African Private Security Contractors Active in Armed Conflicts ...

African Journals Online (AJOL)

Not only is this legislation completely unique, but it appears wholly at odds with international opinion. In this article we place private security contractors (PSCs) under the microscope of international law, exploring the role they play in armed conflicts, and the status afforded them by international humanitarian law (IHL).

Economic impact study of the Uranium Mill Tailings Remedial Action Project in Colorado: Colorado State fiscal year 1994. Revision 1

International Nuclear Information System (INIS)

1994-12-01

The Colorado economic impact study summarizes employment and economic benefits to the state from activities associated with the Uranium Mill Tailings Remedial Action (UMTRA) Project during Colorado state fiscal year 1994 (1 July 1993 through 30 June 1994). To capture employment information, a questionnaire was distributed to subcontractor employees at the active UMTRA Project sites of Grand Junction, Naturita, Gunnison, and Rifle, Colorado. Economic data were requested from each site prime subcontractor, as well as from the Remedial Action Contractor. Information on wages, taxes, and subcontract expenditures in combination with estimates and economic multipliers is used to estimate the dollar economic benefits to Colorado during the state fiscal year. Finally, the fiscal year 1994 estimates are compared to fiscal year 1993 employment and economic information

Building America Best Practices Series. Volume 17 - Energy Renovations-Insulation: A Guide for Contractors to Share With Homeowners

Energy Technology Data Exchange (ETDEWEB)

Baechler, Michael C. [Pacific Northwest National Lab. (PNNL), Richland, WA (United States); Adams, K. T. [Pacific Northwest National Lab. (PNNL), Richland, WA (United States); Hefty, M. G. [Pacific Northwest National Lab. (PNNL), Richland, WA (United States); Gilbride, T. L. [Pacific Northwest National Lab. (PNNL), Richland, WA (United States); Love, Pat M. [Oak Ridge National Lab. (ORNL), Oak Ridge, TN (United States)

2012-05-01

This guide will help contractors and homeowners identify ways to make their homes more comfortable, more energy efficient, and healthier to live in. It also identifies the steps to take, with the help of a qualified home performance contractor, to increase their home’s insulation, ensure healthy levels of ventilation, and prevent moisture problems. Contractors can use this document to explain the value of these insulation measures to their customers. The references in this document provide further explanation of insulation techniques and technologies.

[The competent surgeon. Bridging the gap between undergraduate final year and postgraduate surgery training].

Science.gov (United States)

Kadmon, M; Ganschow, P; Gillen, S; Hofmann, H S; Braune, N; Johannink, J; Kühn, P; Buhr, H J; Berberat, P O

2013-10-01

Competency-based frameworks rely on relevant professional competency rather than formal regulations. The transitional phase between final year undergraduate and common trunk postgraduate medical training is characterized by an increase of professional responsibility whereby previously acquired knowledge, skills and abilities have to be merged and applied to patients. Undergraduate and postgraduate training programs should ensure a successive transfer of responsibility for medical practice to final year students and young residents depending on individual competence. The concept of entrustable professional activities (EPA) represents a curricular concept based on concrete medical tasks which may be assigned to the responsibility of the trainee.

Analysis of final year DVM research projects submitted to the Faculty ...

African Journals Online (AJOL)

Central Research Laboratory

in the library. The essence of this study is to guide prospective final year students and researchers in the choice of research topics as this will help in saving their time. It will also ... and Undergraduate projects of the same department in 2002. Obajemu (1999) also .... majority of the rural people. The distribution by animal ...

Contractors' Perception of factors Contributing to Project Delay: Case Studies of Commercial Projects in Klang Valley, Malaysia

Directory of Open Access Journals (Sweden)

Azlan Shah Ali

2010-12-01

Full Text Available Delay in construction projects is a situation where the project cannot be completed under the planned time. It is a common issue faced in the construction industry all over the world especially in developing countries. In the Malaysian construction industry, 17.3% of construction projects experience more than 3 months delay and some of them are abandoned. Hence, the study of factors contributing to delay is very important in order to reduce the number of projects that experience delay in project delivery. Three objectives of the research have been formulated, namely (1 to identify factors that contribute to delay in construction projects; (2 to analyse and rank the causes of delay rated by contractors; and (3 to study the effects of delay in construction projects. One hundred questionnaires were distributed during data collection stage and only 36 responses received. The respondents only consist of contractors and sub-contractors because the scope of the research focuses on contractors' perception. The data collected was analysed using SPSS software. Seven factors that contribute to delay were identified through literature review, namely contractors' financial difficulties, construction mistakes and defective work, labour shortage, coordination problems, shortage of tools and equipment, material shortage and poor site management. Of those factors, the three most important factors were found to be labour shortage, contractors' financial difficulties and construction mistakes and defective works. Besides project delay, the research shows that cost overrun and extension of time (EOT are the most common effects of delay in construction projects.

Private Security Contractors in Iraq: Background, Legal Status, and Other Issues

National Research Council Canada - National Science Library

Elsea, Jennifer K; Serafino, Nina M

2007-01-01

.... From the information available in published sources, this apparently is the first time that the United States has depended on contractors to provide such extensive security in a hostile environment...

29 CFR 471.15 - Under what circumstances must a contractor be provided the opportunity for a hearing?

Science.gov (United States)

2010-07-01

...-MANAGEMENT STANDARDS, DEPARTMENT OF LABOR NOTIFICATION OF EMPLOYEE RIGHTS UNDER FEDERAL LABOR LAWS OBLIGATIONS OF FEDERAL CONTRACTORS AND SUBCONTRACTORS; NOTIFICATION OF EMPLOYEE RIGHTS UNDER FEDERAL LABOR... 29 Labor 2 2010-07-01 2010-07-01 false Under what circumstances must a contractor be provided the...

40 CFR 35.2035 - Rotating biological contractor (RBC) replacement grants.

Science.gov (United States)

2010-07-01

... treatment works owner, the applicant, its engineers, contractors, equipment manufacturers or suppliers; (b) The RBC failure has significantly increased the project's capital or operation and maintenance costs; (c) The modification/replacement project meets all requirements of EPA's construction grant and other...

Emotional intelligence and academic performance in first and final year medical students: a cross-sectional study.

Science.gov (United States)

Chew, Boon How; Zain, Azhar Md; Hassan, Faezah

2013-03-27

Research on emotional intelligence (EI) suggests that it is associated with more pro-social behavior, better academic performance and improved empathy towards patients. In medical education and clinical practice, EI has been related to higher academic achievement and improved doctor-patient relationships. This study examined the effect of EI on academic performance in first- and final-year medical students in Malaysia. This was a cross-sectional study using an objectively-scored measure of EI, the Mayer-Salovey-Caruso Emotional Intelligence Test (MSCEIT). Academic performance of medical school students was measured using continuous assessment (CA) and final examination (FE) results. The first- and final-year students were invited to participate during their second semester. Students answered a paper-based demographic questionnaire and completed the online MSCEIT on their own. Relationships between the total MSCEIT score to academic performance were examined using multivariate analyses. A total of 163 (84 year one and 79 year five) medical students participated (response rate of 66.0%). The gender and ethnic distribution were representative of the student population. The total EI score was a predictor of good overall CA (OR 1.01), a negative predictor of poor result in overall CA (OR 0.97), a predictor of the good overall FE result (OR 1.07) and was significantly related to the final-year FE marks (adjusted R(2) = 0.43). Medical students who were more emotionally intelligent performed better in both the continuous assessments and the final professional examination. Therefore, it is possible that emotional skill development may enhance medical students' academic performance.

48 CFR 622.1503 - Procedures for acquiring end products on the List of Products Requiring Contractor Certification...

Science.gov (United States)

2010-10-01

... end products on the List of Products Requiring Contractor Certification as to Forced or Indentured... List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor. (e) The... manufacture an end product furnished pursuant to a contract awarded subject to the certification required in...

2004 Power marketing program final EIS - final environmental impact statement. Volume 2 - appendices

International Nuclear Information System (INIS)

1997-02-01

This volume contains appendices to the Final Environmental Impact Statement (FEIS) for the Power Marketing Program proposal of the Western Area Power Administration. The FEIS identified peaking power scheduling as the environmentally preferred alternative, and presented the analysis of alternatives and environmental impacts. Sixteen appendices to the FEIS are included in this document. The appendices are: Statutory and Legal Framework; Sierra Nevada Region Customer Groups and Economic Regions; Renewable Technology Cost Information Matrix; Hydrological Assumptions; Recreation Resources; Archaeological and Historical Resources; Incremental Power Resources; Air Quality Regulatory Structure; Energy Generation; Stage Contents Relationships for Regulating Reservoirs; Power Costs; Socioeconomic Impacts; Projected Air Resource Impacts; Land use, Water Quality, and Solid Waste Impact Factors; Draft Environmental Impact Statement Comments and Responses, and Contractor Disclosure Statements. 21 figs., 24 tabs

Private Security Contractors in Iraq: Background, Legal Status, and Other Issues

National Research Council Canada - National Science Library

Elsea, Jennifer K; Schwartz, Moshe; Nakamura, Kennon H

2008-01-01

.... In Iraq, private firms known as Private Security Contractors (PSCs) serve to protect individuals, transport convoys, forward operating bases, buildings, and other economic infrastructure, and are training Iraqi police and military personnel...

The weaknesses of China's contractors in overseas construction project management: 2 case studies

Directory of Open Access Journals (Sweden)

Ph. D. Mo Xuan

2012-05-01

Full Text Available The practices of international construction contracting have been prevalent increasingly over the past half a centuru, Altough the contractors of highly developed world have dominated this field, there tends to be more players from newly emerging countries like China. The history of China's contractors performing in the overseas construction markets is divided into 3 major phases, namely the planning economy era, reform and openness perios and the latest nwe millennium. However, the know-how and techniques of modern project management have been widely deployed in China for merely 2 decades. While competing with those veterans in overseas markets, China's contractors still lack adequate advantages as well as experiences, leading to the underperformance or even failures. A 2-dimension framework of overseas project management, comprising the external risk and internal function aspects , is proposed. Based on the analysis of 2 recent cases in Saudi Arabia an Poland respectively, it's foung that the low cost strategy management in risk, commerce, cost, human resources, etc. are their fatal weaknesses.

42 CFR 455.232 - Medicaid integrity audit program contractor functions.

Science.gov (United States)

2010-10-01

... 42 Public Health 4 2010-10-01 2010-10-01 false Medicaid integrity audit program contractor functions. 455.232 Section 455.232 Public Health CENTERS FOR MEDICARE & MEDICAID SERVICES, DEPARTMENT OF HEALTH AND HUMAN SERVICES (CONTINUED) MEDICAL ASSISTANCE PROGRAMS PROGRAM INTEGRITY: MEDICAID Medicaid...

Off-Site Prefabrication: What Does it Require from the Trade Contractor?

DEFF Research Database (Denmark)

Bekdik, Baris; Hall, Daniel; Aslesen, Sigmund

2016-01-01

The purpose of the paper is to show what is required to industrialize a building process from the standpoint of the trade contractor. Rationalization of building processes has, over the years, caught the attention of numerous IGLC papers. Although significant contributions have been made to further...... understand and improve existing construction processes, relatively few contributions have focused on the opportunities for industrialization from the trade contractor’s perspective. This paper uses an in-depth case study to address the deployment strategy for off-site fabrication techniques and processes...... at only one case study, the conclusions are limited in generalizability to other prefabrication operations. However, it represents an important in-depth case from the trade contractors’ perspective and will contribute to the growing body of research focused on industrialization and prefabrication in lean...

Annual report: Purchasing and Materials Management Organization, Sandia National Laboratories, fiscal year 1992

Energy Technology Data Exchange (ETDEWEB)

Zaeh, R.A.

1993-04-01

This report summarizes the purchasing and transportation activities of the Purchasing and Materials Management Organization for Fiscal Year 1992. Activities for both the New Mexico and California locations are included. Topics covered in this report include highlights for fiscal year 1992, personnel, procurements (small business procurements, disadvantaged business procurements, woman-owned business procurements, New Mexico commercial business procurements, Bay area commercial business procurements), commitments by states and foreign countries, and transportation activities. Also listed are the twenty-five commercial contractors receiving the largest dollar commitments, commercial contractors receiving commitments of $1,000 or more, integrated contractor and federal agency commitments of $1,000 or more from Sandia National Laboratories/New Mexico and California, and transportation commitments of $1,000 or more from Sandia National Laboratories/New Mexico and California.

Contractor-Client Communications Checklist for Spray Polyurethane Foam (SPF), Incluyendo la Versión de Español

Science.gov (United States)

This checklist provides professional contractors and clients topics to discuss so that the client understands what to expect when a professional contractor installs SPF insulation. Lista de verificación de comunicación del contratista y el cliente.

Evaluation of safety assessment methodologies in Rocky Flats Risk Assessment Guide (1985) and Building 707 Final Safety Analysis Report (1987)

International Nuclear Information System (INIS)

Walsh, B.; Fisher, C.; Zigler, G.; Clark, R.A.

1990-01-01

FSARs. Rockwell International, as operating contractor at the Rocky Flats plant, conducted a safety analysis program during the 1980s. That effort resulted in Final Safety Analysis Reports (FSARs) for several buildings, one of them being the Building 707 Final Safety Analysis Report, June 87 (707FSAR) and a Plant Safety Analysis Report. Rocky Flats Risk Assessment Guide, March 1985 (RFRAG85) documents the methodologies that were used for those FSARs. Resources available for preparation of those Rocky Flats FSARs were very limited. After addressing the more pressing safety issues, some of which are described below, the present contractor (EG ampersand G) intends to conduct a program of upgrading the FSARs. This report presents the results of a review of the methodologies described in RFRAG85 and 707FSAR and contains suggestions that might be incorporated into the methodology for the FSAR upgrade effort

GBI assessment checklist: Level of awareness of the contractors in the Malaysian construction industry

Science.gov (United States)

Marhani, M. A.; Muksain, M. A. S.

2018-02-01

Malaysia has developed Green Building Index (GBI) as the green rating tool for buildings and townships to encourage sustainability in the construction industry. Understanding the roles and tasks of a contractor is essential in accomplishing the GBI assessment on a green building project. However, there are challenges in adapting the GBI. The objective of this paper is to identify the knowledge of contractor for each area of assessments in GBI’s checklist. Data were collected through the questionnaire surveys to the selected contractors, which were involved in GBI projects. The findings revealed that most of the respondents agreed and acknowledged the impact of each criterion in the assessment. Thus, it is highly recommended to educate and change the public perception on the awareness of the green building. Aside, more research and development (R&D) process should be encouraged to accelerate the GBI certificate implementation in the construction industry. In conclusion, proper education training, more legislative and financial framework are essential for the future of green building projects.

Technical Baseline Summary Description for the Tank Farm Contractor

International Nuclear Information System (INIS)

TEDESCHI, A.R.

2000-01-01

This document is a revision of the document titled above, summarizing the technical baseline of the Tank Farm Contractor. It is one of several documents prepared by CH2M HILL Hanford Group, Inc. to support the U.S. Department of Energy Office of River Protection Tank Waste Retrieval and Disposal Mission at Hanford

48 CFR 970.5227-11 - Patent rights-management and operating contracts, for-profit contractor, non-technology transfer.

Science.gov (United States)

2010-10-01

... affiliates, if any, within the corporate structure of which the Contractor is a party and includes the right... benefits are, to the extent permitted by law or Government regulations, available to the public on... rights—(1) Assignment to the Government. Except to the extent that rights are retained by the Contractor...

N Area Final Project Program Plan

International Nuclear Information System (INIS)

Day, R.S.; Duncan, G.M; Trent, S.J.

1998-07-01

The N Area Final Project Program Plan is issued for information and use by the U.S. Department of Energy (DOE), the Environmental Restoration Contractor (ERC) for the Hanford Site, and other parties that require workscope knowledge for the deactivation of N Reactor facilities and remediation of the 100-N Area. This revision to the program plan contains the updated critical path schedule to deactivate N Reactor and its supporting facilities, cleanout of the N Reactor Fuel Storage Basin (105-N Basin), and remediate the 100-N Area. This document reflects notable changes in the deactivation plan for N Reactor, including changes in deactivation status, the N Basin cleanout task, and 100-N Area remediation

48 CFR 627.203 - Patent indemnification of Government by contractor.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 4 2010-10-01 2010-10-01 false Patent indemnification of Government by contractor. 627.203 Section 627.203 Federal Acquisition Regulations System DEPARTMENT OF STATE GENERAL CONTRACTING REQUIREMENTS PATENTS, DATA, AND COPYRIGHTS Patents 627.203 Patent indemnification of...

48 CFR 53.303-WH-347 - Department of Labor Form WH-347, Payroll (For Contractor's Optional Use).

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Department of Labor Form WH-347, Payroll (For Contractor's Optional Use). 53.303-WH-347 Section 53.303-WH-347 Federal... Illustrations of Forms 53.303-WH-347 Department of Labor Form WH-347, Payroll (For Contractor's Optional Use...

Representation a Framwork for Contractors Selection Via of Health, Safety and Environment

Directory of Open Access Journals (Sweden)

Shahram Mahmoudi

2016-12-01

Full Text Available Introduction: Quality and efficiency of health, safety, and environment (HSE management systems play a vital role in achieving their goals. Considering outputs and objective achievement make continuous improvement of services and products, internal and external customer satisfaction, adopting a systematic way for performing various tasks, system performance and analysis very important. The present study was conducted to construct a proper framework for assessing MAPNA group contractors in terms of their health, safety, and environment performance.  . Method: In the first step of the study, all documents and literature associated with performance assessment were reviewed. In the second step, using a focus group approach, a basic model for assessing HSE management system was designed. Lastly, the framework was tested and credited on three major contractors of MAPNA group. Results: The proposed framework was composed of five criteria. The main criteria was the pattern of HSE process implementation which had seven sub-criteria and 120 guiding hints. Moreover, the five criteria were able to assess the organizational capabilities in terms of health, safety, and environment management.. Conclusion: The proposed framework make contractors able to promote their HSE performances by identifying organizational strong and weak points, prioritizing improvement projects, and also monitoring the pace of improvement in achieving organizational excellence..

Causes of Contractor's Business Failure in Developing Countries: The Case of Palestine

Directory of Open Access Journals (Sweden)

Sherif Mohamed

2006-12-01

Full Text Available The construction industry has unique characteristics that sharply distinguish it from other sectors of the economy. It is fragmented, very sensitive to the economic cycles and political environment, and has a significantly high rate of business failure. Business failure, collapse and bankruptcy are common terms in the industry due to the many risks inherited in how the industry operates. Throughout the world, the relative ease of entry gives rise to a large number of contracting firms competing fiercely in the market exposing many of them to business failure, Palestine is no exception. The objectives of this paper are to report on a research study which aims at exploring the causes of contractor's business failure in Palestine, and investigating their severity from the contractor's point of view. The study's results shows that the main causes of business failure are delay in collecting debt from clients (donors, border closure, heavy dependence on bank loans and payment of high interest on these loans, lack of capital, absence of industry regulations, low profit margin due to high competition, awarding contracts by client to the lowest bidder, and lack of experience in contract management. Based on these findings, recommendations to the Palestinian National Authority (PNA and local contractors are presented in this paper.

Final year student nurses' experiences of wound care: an evaluation.

Science.gov (United States)

Ousey, Karen; Stephenson, John; Cook, Leanne; Kinsey, Laura; Batt, Sarah

2013-03-01

This article reports on research to explore if pre-registration nursing students felt prepared to manage patients' skin integrity effectively on registration. Final year nursing students completing adult, child and mental health fields were invited to complete questionnaires to investigate the amount of teaching sessions delivered in university in relation to managing skin integrity during their 3-year training programme, discover if pre-registration nursing students received supplementary management of skin integrity teaching in the clinical areas, explore which member of staff in the clinical areas supported the students' learning in the area of skin integrity. Data was collected on 217 final year students (196 females and 21 males) at two higher education institutions in the north of England. The majority of respondents (n = 146; 68%) reported receiving less than 10 hours formal teaching at university on the subject of skin integrity over their 3-year courses. Of those registered on degree courses, 134 students (71%) reported receiving less than 10 hours formal teaching over their 3-year courses, compared with only 12 students (46%) registered on diploma courses. Some 198 (99%) of respondents reported that their clinical teaching was undertaken by registered nurses all or some of the time. Other health professionals were reported to provide substantially less clinical teaching; with the next largest contribution reported to be provided by specialist nurses, who provided all clinical teaching to 36 respondents (19%) and some clinical teaching to 115 respondents (59%). Some 149 respondents (70%) reported that the teaching they received had developed their knowledge and skills to maintain skin integrity for all patients. Respondents claimed that teaching received had developed their knowledge and skills, reporting an average of 16.9 hours spent in directed study; whereas those who did not claim that teaching they had received had developed their knowledge and

Hand in Glove? Small Building Contractors, Mobile Technology and Innovation

DEFF Research Database (Denmark)

Buser, Martine; Koch, Christian; Tambo, Torben

2010-01-01

for construction are developing as well. A recent review shows a small portfolio of systems using mobile computing to support specifically the construction project processes. The aim of this paper is to evaluate the use of mobile computing at small construction contractors. The paper presents a quantitative...

The factors impacted to local contractor from Foreign Direct Investment in advancing economic hub development in Iskandar Malaysia

Science.gov (United States)

Syafiq Salim, Muhamad; Zakaria, Rozana; Aminuddin, Eeydzah; Hamid, Abdul Rahim Abdul; Abdullah, Redzuan; Shahzaib Khan, Jam

2018-04-01

Iskandar Malaysia is an advanced economic hub which is rapidly growing in the State of Johor. It has been an attractive place for Foreign Direct Investment (FDI) to invest. Many sectors are affected by the presence of FDI including the construction sector. This paper highlights the investigation on the effects of FDI to the local contractor in the Iskandar Malaysia Development. In this study, a questionnaire survey was carried out to gain the information on problems from internal factors and external factors that caused the limitation on involvement in FDI project by local contractors. 73 numbers of local contractor registered under CIDB in class G5, G6 and G7 are the respondents. Frequency analysis and Average Index Analysis are used for the results. This study provides the factors that impacted local construction players in Iskandar Malaysia Development. This study has portrayed that FDI plays a vital and significant role in spearheading the active involvement of local contractors in an urban sustainable development.

Exploring factors affecting owners' trust of contractors in construction projects: a case of China.

Science.gov (United States)

Tai, Shuangliang; Sun, Chengshuang; Zhang, Shoujian

2016-01-01

It has been found that a low level of trust among members of a construction project team leads to poor performance in China. Many researchers have described the challenges, consequently advocating partnering as an attractive approach for more valuable cooperation. Because substantial investments have been poured into construction projects since the year 2000, trust research will improve the performance of construction projects and will be meaningful to the Chinese construction industry. The purpose of this paper is to investigate the attributes affecting owners' trust of contractors, to understand the potential properties of these factors, and to rank the factors in order of importance. Twenty-four attributes are identified from a literature review. Supported by qualitative reviews, a questionnaire is conducted to obtain relevant data, and 168 valid responses are obtained for data analysis. Principal component analysis (PCA) is employed to find the factor structure of the identified trust attributes. By the method of PCA, the attributes are extracted into eight factors, including interaction history, information sharing and communication, contract and institution, relation-specific investment, reputation, integrity, competence, and opportunistic behaviour. The value and originality of this paper are embodied in using PCA to understand the various attribute groupings and to illuminate trust impact factors in the Chinese context. When they understand the critical factors affecting trust better, owners and contractors can devise more appropriate strategies to improve performance.

Requirements for the project management in the client / engineering contractor relationship

International Nuclear Information System (INIS)

Hack, W.L.

1995-01-01

Investment projects impose a multitude of requirements upon clients and engineering contractors to cope with the management of project inherent conflicts. The paper reviews certain aspects on why such conflicts develop, and how they may be resolved. (orig.)

7th Annual NASA/Contractors Conference on Quality and Productivity: "Total Quality Leadership"

Science.gov (United States)

1991-01-01

More than 750 NASA, government, contractor, and academic representatives attended the Seventh Annual NASA/Contractors Conference on Quality and Productivity on October 12-13, 1990, in Grenelefe, Florida. The panel presentations and keynote speeches revolving around the theme of 'Total Quality Leadership' provided a solid base of understanding of the importance, benefits, and principles of total quality management. The implementation of these strategies is critical if we are to effectively pursue our mission of continuous quality improvement and reliability in our products, processess, and services. The annual NASA/contractors conferences serve as catalysts for achieving success in this mission. The conference was highlighted by the announcement of the first recipients of the George M. Low Trophy: NASA's Quality and Excellence Award. My congratulations go out to all nine finalist organizations and to the two recipients of this prestigious honor: Rockwell Space Systems Division and Marotta Scientific Controls, Inc. (the first small business to achieve this honor). These organizations have demonstrated a commitment to quality that is unsurpassed in the aerospace industry. This report summarizes the presentations and is not intended to be a verbatim proceedings document. You are encouraged to contact the speakers with any requests for further information.

42 CFR 421.316 - Limitation on Medicare integrity program contractor liability.

Science.gov (United States)

2010-10-01

... services to a MIP contractor is not in violation of any criminal law or civilly liable under any law of the United States or of any State (or political subdivision thereof) by reason of the performance of any duty...

Final Report-Confirmatory Survey Results for the ABB Combustion Engineering Site, Windsor, Connecticut; Revision 1 (DCN 5158-SR-02-1) (Docket No. 030-03754; RFTA No. 12-003)

Energy Technology Data Exchange (ETDEWEB)

ADAMS, WADE C

2013-01-28

The objectives of the confirmatory activities were to provide independent contractor field data reviews and to generate independent radiological data for use by the NRC in evaluating the adequacy and accuracy of the contractor's procedures and FSS results. ORAU reviewed ABB CE's decommissioning plan, final status survey plan, and the applicable soil DCGLs, which were developed based on an NRC-approved radiation dose assessment. The surveys included gamma surface scans, gamma direct measurements, and soil sampling.

Performance-Based Contractor Prequalification as an Alternative to Performance Bonds [Tech Brief

Science.gov (United States)

2014-01-01

State transportation departments must rely on private industry construction contractors to build, rehabilitate, and replace their infrastructure assets. The Federal Highway Administration (FHWA) is interested in ensuring that State transportation dep...

Listening to Student Views on the Transition from Work Placement to the Final Year

Science.gov (United States)

Anderson, Pamela; Novakovic, Yvonne

2017-01-01

This paper addresses a gap in the literature on student work placements, specifically the challenges of returning to final-year study after a year out. We focus on students in an Accountancy and Finance Department at one UK University who alerted us to the ways in which they struggled during the transition back to full-time study. Their accounts…

Construction contractors and healthcare delivery in South Africa: challenges and interventions

CSIR Research Space (South Africa)

Van Wyk, Llewellyn V

2007-10-01

Full Text Available This paper compares the demand side requirements of the National Department of Health with the supply-side capabilities of the construction industry as determined by the Register of Contractors. It finds that only a small percentage of registered...

THE EVALUATION OF THE IMPLEMENTATION OF CONTRACTOR SAFETY MANAGEMENT SYSTEM (CSMS PROGRAM ON TURNAROUND PROJECT (TA AT PT. PUPUK SRIWIDJAJA (PUSRI PALEMBANG

Directory of Open Access Journals (Sweden)

Muhammad Arif

2016-03-01

Full Text Available Background :Turnaround is one of the done by contractor in which if it is not managed well, it could cause work accident. The purpose of this study was to evaluate the implementation of contractor safety management system (CSMS program on turnaround project at PT. Pupuk Sriwidjaja Palembang. Method : This study was a qualitative study. The information was obtained from deep interview, observation and the study of document. The data was analyzed by using content analysis. The validity of the instruments was tested through triangulation of sources, method and data Result : The program implementation Contractor Safety Management System (CSMS on a turnaround project is already well underway only on projects in addition to departments turnaround K3 & LH less involved in the risk assessment stage, pre-qualification and selection of contractors. Conclusion : The implementation of the program Contractor Safety Management System (CSMS on a turnaround project at PT. Pupuk Sriwidjaja Palembang are in accordance with the Code of Labor Management Health, Safety and Environmental Protection Contractor BPMIGAS. It is advisable to PT. Pupuk Sriwidjaja Palembang in order to improve communication between departments procure goods and services with K3 and LH-related departments work tendered as the risk assessment stage, pre-qualification and selection on work tendered. Need sanctions against contractors who do not regularly report performance data K3.

Programmatic Baseline Summary for Phase 1 Privatization for the Tank Farm contractor

International Nuclear Information System (INIS)

DIEDIKER, J.A.

2000-01-01

The document describes the systematic integrated baseline planning process and provides a summary of the Tank Farm Contractor scope, schedule and cost analysis developed in support of the Phase 1 privatization mission

Programmatic Baseline Summary for Phase 1 Privatization for the Tank Farm contractor

Energy Technology Data Exchange (ETDEWEB)

DIEDIKER, J.A.

2000-04-22

The document describes the systematic integrated baseline planning process and provides a summary of the Tank Farm Contractor scope, schedule and cost analysis developed in support of the Phase 1 privatization mission.

TWRS Final Safety Analysis Report (FSAR) integrated control decision team (ICDT) meetings January 22 - 31,1997

International Nuclear Information System (INIS)

Saladin, V.L.

1997-01-01

U.S. Department of Energy (DOE), Richland Operations Office (RL) letter 97-MSD-163 dated January 15, 1997, directed the Project Hanford Management Contractor (Contractor), Fluor Daniel Hanford, inc., to form a joint RL-Contractor Integrated Control Decision Team (ICDT) to evaluate the Tank Waste Remediation System (TWRS) Final Safety Analysis Report (FSAR) accident scenarios that were identified to be above the risk evaluation guidelines (radiological and/or toxicological) defined by the April 8, 1996, letter from J. Kinzer, RL-TWRS (96-MSO-069) to Dr. A. L. Trego, Westinghouse Hanford Company. The ICDT evaluated six postulated accidents from the draft FSAR which had analyzed consequences above the DOE directed risk evaluation guidelines after controls were applied. The accidents were: (1) Organic Solvent Fires; (2) Organic Salt-Nitrate Fire; (3) Spray Leak; (4) Flammable Gas; (5) Steam Intrusion; and (6) Seismic Event. Five of the postulated accidents exceed radiological risk guidelines. Although the postulated steam intrusion accident does not exceed the radiological risk guidelines, it was considered in the ICDT evaluation because its calculated consequences exceed toxicological risk evaluation guidelines. Figure 1 delineates the mitigated and unmitigated risk evaluations performed for the FSAR

23 CFR Appendix C to Subpart A of... - Federal-Aid Highway Contractors Annual EEO Report (Form PR-1391)

Science.gov (United States)

2010-04-01

... 23 Highways 1 2010-04-01 2010-04-01 false Federal-Aid Highway Contractors Annual EEO Report (Form PR-1391) C Appendix C to Subpart A of Part 230 Highways FEDERAL HIGHWAY ADMINISTRATION, DEPARTMENT OF... Part 230—Federal-Aid Highway Contractors Annual EEO Report (Form PR-1391) EC14OC91.000 ...

48 CFR 245.610-4 - Contractor inventory in foreign countries.

Science.gov (United States)

2010-10-01

..., DRMS disposal activities shall be used to dispose of surplus contractor inventory located outside the... property covered by this contract will be used in (name of country). In the event of resale or export by... equivalent in other currency at the official exchange rate, the Purchaser agrees to obtain the approval of...

48 CFR 52.227-11 - Patent Rights-Ownership by the Contractor.

Science.gov (United States)

2010-10-01

... variety has been reproduced with recognized characteristics. Nonprofit organization means a university or...) Communications. [Complete according to agency instructions.] (k) Subcontracts. (1) The Contractor shall include... international agreements entered into by the Government before or after the effective date of the contract and...

Final Year Project Report

Energy Technology Data Exchange (ETDEWEB)

Hubsch, Tristan [Howard University

2013-06-20

In the last years of this eighteen-year grant project, the research efforts have focused mostly on the study of off-shell representations of supersymmetry, both on the worldline and on the world- sheet, i.e., both in supersymmetric quantum mechanics and in supersymmetric field theory in 1+1-dimensional spacetime.

Course experiences, satisfaction and career intent of final year pre-registration Australian pharmacy students

Directory of Open Access Journals (Sweden)

Shen G

2014-06-01

Full Text Available Background: In Australia, the profession of pharmacy has undergone many changes to adapt to the needs of the community. In recent years, concerns have been raised with evidence emerging of workforce saturation in traditional pharmacy practice sectors. It is not known how current final year pharmacy students’ perceive the different pharmacy career paths in this changing environment. Hence investigating students’ current experiences with their pharmacy course, interaction with the profession and developing an understanding of their career intentions would be an important step, as these students would make up a large proportion of future pharmacy workforce Objective: The objective of this study was thus to investigate final year students’ career perspectives and the reasons for choosing pharmacy, satisfaction with this choice of pharmacy as a tertiary course and a possible future career, factors affecting satisfaction and intention of future career paths. Methods: A quantitative cross sectional survey of final year students from 3 Australian universities followed by a qualitative semi-structured interview of a convenience sample of final year students from the University of Sydney. Results: ‘Interest in health and medicine’ was the most important reason for choosing pharmacy (n=238. The majority of students were ‘somewhat satisfied’ with the choice of pharmacy (35.7% as a course and possible future career. Positive associations were found between satisfaction and reasons for joining pharmacy such as ‘felt pharmacy is a good profession’ (p=0.003 while negative associations included ‘joined pharmacy as a gateway to medicine or dentistry’ (p=0.001. Quantitate and qualitative results showed the most frequent perception of community pharmacy was ‘changing’ while hospital and pharmaceutical industry was described as ‘competitive’ and ‘research’ respectively. The highest career intention was community followed by hospital

Course experiences, satisfaction and career intent of final year pre-registration Australian pharmacy students.

Science.gov (United States)

Shen, Grace; Fois, Romano; Nissen, Lisa; Saini, Bandana

2014-04-01

In Australia, the profession of pharmacy has undergone many changes to adapt to the needs of the community. In recent years, concerns have been raised with evidence emerging of workforce saturation in traditional pharmacy practice sectors. It is not known how current final year pharmacy students' perceive the different pharmacy career paths in this changing environment. Hence investigating students' current experiences with their pharmacy course, interaction with the profession and developing an understanding of their career intentions would be an important step, as these students would make up a large proportion of future pharmacy workforce. The objective of this study was thus to investigate final year students' career perspectives and the reasons for choosing pharmacy, satisfaction with this choice of pharmacy as a tertiary course and a possible future career, factors affecting satisfaction and intention of future career paths. A quantitative cross sectional survey of final year students from 3 Australian universities followed by a qualitative semi-structured interview of a convenience sample of final year students from the University of Sydney. 'Interest in health and medicine' was the most important reason for choosing pharmacy (n=238). The majority of students were 'somewhat satisfied' with the choice of pharmacy (35.7%) as a course and possible future career. Positive associations were found between satisfaction and reasons for joining pharmacy such as 'felt pharmacy is a good profession' (p=0.003) while negative associations included 'joined pharmacy as a gateway to medicine or dentistry' (p=0.001). Quantitate and qualitative results showed the most frequent perception of community pharmacy was 'changing' while hospital and pharmaceutical industry was described as 'competitive' and 'research' respectively. The highest career intention was community followed by hospital pharmacy. Complex factors including university experiences are involved in shaping

A New Data Acquisition Portal for the Sacramento River Settlement Contractors

Science.gov (United States)

Narlesky, P. E., C. A.; Williams, P. E., A. M.

2017-12-01

In 1964, the United States Bureau of Reclamation (Reclamation) executed settlement contracts with the Sacramento River Settlement Contractors (SRSC), entities which hold water rights along the Sacramento River with area of origin protection or that are senior to Reclamation's water rights for Shasta Reservoir. Shasta is the cornerstone of the federal Central Valley Project (CVP), one of the nation's largest multi-purpose water conservation programs. In order to optimize CVP operations for multiple beneficial uses including water supply, fisheries, water quality, and waterfowl habitat, the SRSC voluntarily agreed to adaptively manage diversions throughout the year in close coordination with Reclamation. MBK Engineers assists the SRSC throughout this process by collecting, organizing, compiling, and distributing diversion data to Reclamation and others involved in operational decisions related to Shasta Reservoir and the CVP. To improve and expand participation in diversions reporting, we have developed the SRSC Web Portal, which launches a data-entry dashboard for members of the SRSC to facilitate recording and transmittal of both predicted and observed monthly and daily flow diversion data. This cloud-hosted system leverages a combination of Javascript interactive visualization libraries with a database-backed Python web framework to present streamlined data-entry forms and valuable SRSC program summary illustrations. SRSC program totals, which can now be aggregated through queries to the web-app's database backend, are used by Reclamation, SRSC, fish agencies, and others to inform operational decisions. By submitting diversion schedules and tracking actual diversions through the portal, contractors will also be directly contributing to the development of a richer and more consistently-formatted historical record for demand hydrology in the Sacramento River Watershed; this may be useful in future water supply studies. Adoption of this technology will foster an

Identifying environmental safety and health requirements for an Environmental Restoration Management Contractor

International Nuclear Information System (INIS)

Beckman, W.H.; Cossel, S.C.; Alhadeff, N.; Lindamood, S.B.; Beers, J.A.

1993-10-01

The purpose of the Standards/Requirements Identification Program, developed partially in response to the Defense Nuclear Facilities Safety Board Recommendation 90-2, was to identify applicable requirements that established the Environmental Restoration Management Contractor's (ERMC) responsibilities and authorities under the Environmental Restoration Management Contract, determine the adequacy of these requirements, ascertain a baseline level of compliance with them, and implement a maintenance program that would keep the program current as requirements or compliance levels change. The resultant Standards/Requirements Identification Documents (S/RIDs) consolidate the applicable requirements. These documents govern the development of procedures and manuals to ensure compliance with the requirements. Twenty-four such documents, corresponding with each functional area identified at the site, are to be issued. These requirements are included in the contractor's management plan

Contingency Contractor Optimization Phase 3 Sustainment Verification and Validation V&V) Report - Contingency Contractor Optimization Engineering - Prototype

Energy Technology Data Exchange (ETDEWEB)

Bandlow, Alisa [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States). Operations Research and Computational Analysis; Durfee, Justin David [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States). Operations Research and Computational Analysis; Frazier, Christopher Rawls [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States). Operations Research and Computational Analysis; Gearhart, Jared Lee [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States). Operations Research and Computational Analysis; Jones, Katherine A. [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States). Operations Research and Computational Analysis; Adair, Kristin Lynn [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States). Operations Research and Computational Analysis; Turgeon, Jennifer [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States). High Confidence System Environments

2016-04-01

The reports and test plans contained within this document serve as supporting materials to the activities listed within the “Contingency Contractor Optimization Tool – Prototype (CCOT-P) Verification & Validation Plan” [1]. The activities included test development, testing, peer reviews, and expert reviews. The engineering prototype reviews were done for both the software and the mathematical model used in CCOT-P. Section 2 includes the peer and expert review reports, which summarize the findings from each of the reviews and document the resolution of any issues. Section 3 details the test plans that were followed for functional testing of the application through the interface. Section 4 describes the unit tests that were run on the code.

Difficulties Encountered by Final-Year Male Nursing Students in Their Internship Programmes

Science.gov (United States)

Al-Momani, Mohammed Mahmoud

2017-01-01

Background The cultural norms of the Kingdom of Saudi Arabia do not encourage men to choose nursing as a career. Understanding male nursing students’ experiences of their clinical exposure to the nursing profession throughout their internship might increase their retention. This study explored the experiences of final-year male nursing students as they transitioned to the role of registered nurse. Methods A qualitative descriptive research design with an inductive content-analysis approach was used. The experiences of 22 final-year male nursing students from three public hospitals in a major city of Saudi Arabia were explored. The data were collected using focus-group interviews and documentary analysis in March 2015 and May 2015. Results Content analysis revealed three major themes: the societal and cultural image of male nurses, male students’ engagement in nursing practice, and restructuring the internship programmes’ policies to suit male students’ needs. Conclusion The findings reveal issues that mainly stem from negative social views of nursing as a male profession. Considering the students’ social and cultural needs during their internship programme will facilitate their transition into the role of registered nurse and their retention in the nursing profession. PMID:28951687

Clinical observed performance evaluation: a prospective study in final year students of surgery.

LENUS (Irish Health Repository)

Markey, G C

2010-06-24

We report a prospective study of clinical observed performance evaluation (COPE) for 197 medical students in the pre-qualification year of clinical education. Psychometric quality was the main endpoint. Students were assessed in groups of 5 in 40-min patient encounters, with each student the focus of evaluation for 8 min. Each student had a series of assessments in a 25-week teaching programme. Over time, several clinicians from a pool of 16 surgical consultants and registrars evaluated each student by direct observation. A structured rating form was used for assessment data. Variance component analysis (VCA), internal consistency and inter-rater agreement were used to estimate reliability. The predictive and convergent validity of COPE in relation to summative OSCE, long case, and overall final examination was estimated. Median number of COPE assessments per student was 7. Generalisability of a mean score over 7 COPE assessments was 0.66, equal to that of an 8 x 7.5 min station final OSCE. Internal consistency was 0.88-0.97 and inter-rater agreement 0.82. Significant correlations were observed with OSCE performance (R = 0.55 disattenuated) and long case (R = 0.47 disattenuated). Convergent validity was 0.81 by VCA. Overall final examination performance was linearly related to mean COPE score with standard error 3.7%. COPE permitted efficient serial assessment of a large cohort of final year students in a real world setting. Its psychometric quality compared well with conventional assessments and with other direct observation instruments as reported in the literature. Effect on learning, and translation to clinical care, are directions for future research.

Comparative cross-sectional study of empathy among first year and final year medical students in Jimma University, Ethiopia: Steady state of the heart and opening of the eyes

Directory of Open Access Journals (Sweden)

Dehning Sandra

2012-05-01

Full Text Available Abstract Background There is general consent that empathy is crucial for the physician-patient relationship and thus an important issue in medical education. This comparative study was designed to examine the differences in empathy between first year and final year medical students in Jimma University, Ethiopia. Methods A comparative cross-sectional study among 131 first year and 106 final year medical students was conducted in Jimma University, Ethiopia on academic year 2010/11. The study subjects were selected using simple random sampling technique from the list of the students. Study participation was voluntary. The Balanced Emotional Empathy Scale (BEES was used for the detection of “heart-reading”, i.e. emotional empathy and the Reading the Mind in the Eyes test (RME-R test to evaluate “mind-reading”, i.e. cognitive empathy. We performed t-test to compare the mean difference in empathy and RME-R scores between the two groups of students. A linear regression was computed to identify potential factors influencing the BEES and RME-R. Results Out of the total 237 students, 207 (87.3% were males. The mean age of first year and final year students was 19.3 ± 1.1 and 24.0 ± 1.4 years respectively. First year students have scored 40.6 ± 23.8 while final year students scored 41.5 ± 20.8 mean in the BEES measuring emotional empathy score. However, this difference was not statistically significant (t = −0.30, df = 231, P-value >0.05. Final year students had significantly higher mean cognitive empathy score (17.8 ± 4.5 than first year students (14.4 ± 4.8 [β = 2.7, 95%CI (1.20, 4.13]. Males had scored lower cognitive [β = −2.5, 95%CI (−4.37, −0.66] and emotional empathy [β = −12.0, 95%CI (−21.66, −5.46]. Conclusions Low emotional (BEES and cognitive empathy sores were found in first year and final year students of Jimma University could have implications on the medical

48 CFR 1852.245-70 - Contractor requests for Government-owned equipment.

Science.gov (United States)

2010-10-01

... the equipment and the reasons why contractor-owned property cannot be used, citing the applicable FAR... 1419, DOD Industrial Plant Equipment Requisition, or equivalent format, for each item requested and (ii... Government-owned equipment. 1852.245-70 Section 1852.245-70 Federal Acquisition Regulations System NATIONAL...

Directory of DOE and contractor personnel involved in non-government standards activities

Energy Technology Data Exchange (ETDEWEB)

NONE

1995-08-01

This document contains a listing of DOE employees and DOE contractors who have submitted form DOE F 1300.2, Record of Non-Government Standards Activity. Additional names were added from rosters supplied by non-Government standards bodies.

Students' Experiences of Clinic-Based Learning during a Final Year Veterinary Internship Programme

Science.gov (United States)

Matthew, Susan M.; Taylor, Rosanne M.; Ellis, Robert A.

2010-01-01

This study investigated veterinary students' experiences of clinic-based learning (CBL) during a comprehensive final year internship programme. Open-ended surveys (n = 93) were used to gather qualitative data about students' conceptions of what is learned during CBL and their approaches to learning in clinics. Phenomenography was used for detailed…

Brain drain: final year medical students' intentions of training abroad.

Science.gov (United States)

Bojanic, Ana; Bojanic, Katarina; Likic, Robert

2015-06-01

In Croatia, a new European Union (EU) member state since July 2013, there is already a shortage of around 3280 doctors to reach the European average. To investigate the emigration intentions of the current cohort of final year medical students at Zabreb School of Medicine. An electronic questionnaire was used in June 2013 to assess the attitudes of 232 final year medical students towards working conditions abroad and expectations for career opportunities in Croatia following accession to the EU. With an overall response rate of 87%, more than half of the surveyed students (106/202, 53%) intended to travel abroad, either for specialty (52/202, 26%) or subspecialty (54/202, 27%) training. More female students (58/135, 43%) than male students (17/62, 27%) indicated they would not emigrate. Most attractive emigration destinations were: Germany (34/121, 28%), USA (19/121, 16%), the UK (19/121, 16%), Switzerland (16/121, 13%) and Canada (11/121, 9%). The most important goals that respondents aimed to achieve through training abroad were to excel professionally (45/120, 38%), to prosper financially (20/120, 17%) and to acquire new experiences and international exposure (31/120, 26%). Students' motivating factors, goals for and positive beliefs about training abroad, as well as negative expectations regarding career opportunities in Croatia, may point towards actions that could be taken to help make Croatia a country that facilitates medical education and professional career development of young doctors. Published by the BMJ Publishing Group Limited. For permission to use (where not already granted under a licence) please go to http://group.bmj.com/group/rights-licensing/permissions.

Self-management support by final year nursing students: A correlational study of performance and person-related associated factors.

Science.gov (United States)

Duprez, Veerle; Beeckman, Dimitri; Verhaeghe, Sofie; Van Hecke, Ann

2017-09-01

Chronic conditions put a heavy burden on healthcare in every country. Supporting persons with a chronic illness to take an active role in the management of their condition is a core component in the Chronic Care Model. It implies confidence and good skills from professionals. To date, there is no evidence on final year nursing students' performance in supporting patients' self-management, nor on factors associated with this performance. To explore self-reported performance of supporting patients' self-management by final year nursing students, and person-related factors associated with this performance. A correlational multi-centre study of final year nursing students (N=256) from eight nursing schools. Students were recruited from a convenience sample of eight nursing schools. All final year students were invited to participate. Data were collected between January 2015 and May 2016 using self-administered validated questionnaires. Theoretical behavioural frameworks were used to select hypothesized associated factors for self-management support: self-efficacy to perform self-management support and socio-structural factors (Social Cognitive Theory); needs for autonomy, competence and relatedness, and patient-invested contingent self-esteem (Self-Determination Theory); and attitudes towards supporting patients' self-management (Theory of Planned Behaviour). Final year nursing students (N=256) reported an overall low level of performance in delivering self-management support during internship. Students lacked mainly competencies in collaborative goal setting and shared decision making. Students reported a significant gap between their confidence and their actual performance in self-management support (pLearning opportunities can be introduced in classroom activities and on internship. Copyright © 2017 Elsevier Ltd. All rights reserved.

Report to Congress on the Indemnification of Contractors Performing Environmental Restoration

Science.gov (United States)

1993-11-01

strategies have C-0 irwo-enal contracting experience within the Ibm aple in protecting assets hrm CERCLA ! components and the question of what role, if...federal Crawford v. National Lead Co.40 is another government owns tens of thousands of automobiles ; example of a failed government contractor defense

Final report of the decontamination and decommission of Building 31 at the Grand Junction Projects Office Facility

International Nuclear Information System (INIS)

Krabacher, J.E.

1996-07-01

The U.S. Department of Energy (DOE) Grand Junction Projects Office (GJPO) occupies a 61.7-acre facility along the Gunnison River near Grand Junction, Colorado. This site was contaminated with uranium ore and mill tailings during uranium refining activities of the Manhattan Engineer District and during pilot milling experiments conducted for the domestic uranium procurement program funded by the U.S. Atomic Energy Commission. The DOE Defense Decontamination and Decommissioning Program established the GJPO Remedial Action Project to clean up and restore the facility lands, improvements, and the underlying aquifer. The site contractor for the facility, Rust Geotech, also was the remedial action contractor. Radiological contamination was identified in Building 31 and the building was demolished in 1992. The soil area within the footprint of the building has been remediated in accordance with the identified standards and the area can be released for unlimited exposure and unrestricted use. This area was addressed in the summary final report of the remediation of the exterior areas of the GJPO facility. This document was prepared in response to a DOE request for an individual final report for each contaminated GJPO building

Current practices of construction waste reduction through 3R practice among contractors in malaysia: Case study in penang

Science.gov (United States)

Ng, L. S.; Tan, L. W.; Seow, T. W.

2017-11-01

The effectiveness of the implementation of construction waste reduction through 3R reflects the sustainability in construction waste management. Weak implementation of construction waste reduction through 3R among contractors will lead to unsustainable construction waste management. Increase in construction waste on landfills is critical especially on islands where land is very limited for solid waste disposal. This aim of this paper is to investigate current practice of construction waste reduction through 3R practice among contractors in Penang, Malaysia. The findings reported herein is based on feedbacks from 143 construction contractors of grade CIDB G7, G6 and G5 in Penang and experts from Penang Local Authority, CIDB in Penang and its Headquarters, National Solid Waste Management Department, and Headquarters of Solid Waste and Public Cleansing Management Corporation. Interviews and questionnaire surveys have been found that 3R practice is not mandatory in construction waste management in Penang. Only 39.8% construction contractors practiced 3R in managing their waste. Therefore, 3R practices should be emphasized in construction industry. Reducing wastes through 3R practices in construction industry is a way forward towards sustainable construction waste management especially in expanding the lifetime of landfill.

United States extension of indemnification to utilities and contractors

International Nuclear Information System (INIS)

Cunningham, G.

1988-01-01

This chapter discusses the status of the Price-Anderson Act which provides a means of compensation for members of the public who may be injured as a result of a nuclear incident at a licensed commercial power plant or a facility of the United States Government operated by a contractor. It describes the course of bills to extend the Act in 1987 and analyses some of the major issues of the debate (NEA) [fr

78 FR 58681 - Affirmative Action and Nondiscrimination Obligations of Contractors and Subcontractors Regarding...

Science.gov (United States)

2013-09-24

...\\ OMB Control Number 1293-0005, Federal Contractor Veterans' Employment Report, VETS-100/VETS-100A, http... the context of telecommuting, work arrangements that do not include a physical office setting, and the...

English Language Writing Anxiety among Final Year Engineering Undergraduates in University Putra Malaysia

Science.gov (United States)

Min, Lau Sing; Rahmat, Nurhazlini

2014-01-01

Second Language Writing Anxiety (SLWA) is considered one of the most crucial factors affecting all second language learning. This study focused on a group of final year Engineering students' English Language writing anxiety (N = 93) in relation to their gender, race and MUET results. The findings showed that the male gender, Chinese and MUET band…

48 CFR 1019.202-70-5 - Incentives for prime contractor participation.

Science.gov (United States)

2010-10-01

... DEPARTMENT OF THE TREASURY SOCIOECONOMIC PROGRAMS SMALL BUSINESS PROGRAMS Policies 1019.202-70-5 Incentives for prime contractor participation. (a) Under the Small Business Act, 15 U.S.C. 637(d)(4)(E), Treasury....219-75. (c) Before awarding a contract that requires a subcontracting plan, the existence of a mentor...

48 CFR 3052.219-72 - Evaluation of prime contractor participation in the DHS mentor-protégé program.

Science.gov (United States)

2010-10-01

... contractor participation in the DHS mentor-protégé program. 3052.219-72 Section 3052.219-72 Federal... Evaluation of prime contractor participation in the DHS mentor-protégé program. As prescribed in (HSAR) 48... the DHS Mentor-Protégé Program (JUN 2006) This solicitation contains a source selection factor or...

Parent Attitudes Toward the Virginia Beach Year-Round School Pilot Project. Final Report.

Science.gov (United States)

Schlechty, Phillip C.

Part of the Virginia Beach year-round school program evaluation, this final report contains a detailed analysis of parental attitudes, beliefs, and perceptions. The data leads to the following conclusions: a majority (53.3 percent) of parents are dubious or negative toward the 45-15 pilot project; a slight majority of parents in the pilot schools…

41 CFR 301-70.701 - Who has the authority to grant exemptions to mandatory use of Government contractor-issued travel...

Science.gov (United States)

2010-07-01

... grant exemptions to mandatory use of Government contractor-issued travel charge card for official travel... REQUIREMENTS Policies and Procedures Relating to Mandatory Use of the Government Contractor-Issued Travel Charge Card for Official Travel § 301-70.701 Who has the authority to grant exemptions to mandatory use...

Kennedy Space Center's NASA/Contractor Team-Centered Total Quality Management Seminar: Results, methods, and lessons learned

Science.gov (United States)

Kinlaw, Dennis C.; Eads, Jeannette

1992-01-01

It is apparent to everyone associated with the Nation's aeronautics and space programs that the challenge of continuous improvement can be reasonably addressed only if NASA and its contractors act together in a fully integrated and cooperative manner that transcends the traditional boundaries of proprietary interest. It is, however, one thing to assent to the need for such integration and cooperation; it is quite another thing to undertake the hard tasks of turning such a need into action. Whatever else total quality management is, it is fundamentally a team-centered and team-driven process of continuous improvement. The introduction of total quality management at KSC, therefore, has given the Center a special opportunity to translate the need for closer integration and cooperation among all its organizations into specific initiatives. One such initiative that NASA and its contractors have undertaken at KSC is a NASA/Contractor team-centered Total Quality Management Seminar. It is this seminar which is the subject of this paper. The specific purposes of this paper are to describe the following: Background, development, and evolution of Kennedy Space Center's Total Quality Management Seminar; Special characteristics of the seminar; Content of the seminar; Meaning and utility of a team-centered design for TQM training; Results of the seminar; Use that one KSC contractor, EG&G Florida, Inc. has made of the seminar in its Total Quality Management initiative; and Lessons learned.

Management assessment of tank waste remediation system contractor readiness to proceed with phase 1B privatization

International Nuclear Information System (INIS)

Honeyman, J.O.

1998-01-01

This Management Assessment of Tank Waste Remediation System (TWRS) Contractor Readiness to Proceed With Phase 1B Privatization documents the processes used to determine readiness to proceed with tank waste treatment technologies from private industry, now known as TWRS privatization. An overall systems approach was applied to develop action plans to support the retrieval and disposal mission of the TWRS Project. The systems and infrastructure required to support the mission are known. Required systems are either in place or plans have been developed to ensure they exist when needed. Since October 1996 a robust system engineering approach to establishing integrated Technical Baselines, work breakdown structures, tank farms organizational structure and configurations, work scope, and costs has become part of the culture within the TWRS Project. An analysis of the programmatic, management, and technical activities necessary to declare readiness to proceed with execution of the mission demonstrates that the system, personnel, and hardware will be on-line and ready to support the private contractors. The systems approach included defining the retrieval and disposal mission requirements and evaluating the readiness of the Project Hanford Management Contract (PHMC) team to support initiation of waste processing by the private contractors in June 2002 and to receive immobilized waste shortly thereafter. The Phase 1 feed delivery requirements from the private contractor Requests for Proposal were reviewed. Transfer piping routes were mapped, existing systems were evaluated, and upgrade requirements were defined

Proceedings of the natural gas RD&D contractors review meeting, Volume II

Energy Technology Data Exchange (ETDEWEB)

Malone, R.D. [ed.

1995-04-01

This is volume II of papers which were presented at the natural gas RD&D contractors review meeting. Topics include: natural gas upgrading, storage, well drilling, completion, and stimulation. Individual papers were processed separately for the United States Department of Energy databases.

The impact of customer-contractor interactions on spacecraft innovation: Insights from communication satellite history

Science.gov (United States)

Szajnfarber, Zoe; Stringfellow, Margaret V.; Weigel, Annalisa L.

2010-11-01

This paper captures a first detailed attempt to quantitatively analyze the innovation history of the space sector. Building on a communication satellite innovation metric and a spacecraft innovation framework developed as part of an ongoing project, this paper presents a preliminary model of global communication satellite innovation. In addition to innovation being a function of the rate of performance normalized by price, innovation was found to be strongly influenced by characteristics of the customer-contractor contractual relationship. Specifically, Department of Defense contracts tend to result in a lower level of innovation on average as compared to other customers. Also, particular customer-contractor pairs perform differently and exhibit a second order relationship in time.

Literature review on skills development frameworks for small and medium-sized contractors in the green building sector

CSIR Research Space (South Africa)

Dlungwana, Sihle

2018-01-01

Full Text Available on skills development frameworks for small and medium-sized contractors in the green building sector Sihle Dlungwana Senior Researcher, CSIR Built Environment Unit Introduction In 2011 the Department of Public Works adopted a Green Building... of their characteristics. Thematic analysis was used to analyse a number of articles in order to develop an appropriate framework for supporting future skills development programmes and tools for the green building sector. Defining a green contractor Generally...

Recovery Audit Contractor medical necessity readiness: one health system's journey.

Science.gov (United States)

Scott, Judith A; Camden, Mindy

2011-01-01

To develop a sustainable approach to Recovery Audit Contractor medical necessity readiness that mitigates the regulatory and financial risks of the organization. Acute care hospitals. Utilizing the model for improvement and plan-do-study-act methodology, this health system designed and implemented a medical necessity case management program. We focused on 3 areas for improvement: medical necessity review accuracy, review timeliness, and physician adviser participation for secondary reviews. Over several months, we improved accuracy and timeliness of our medical necessity reviews while also generating additional inpatient revenue for the health system. We successfully enhanced regulatory compliance and reduced our financial risks associated with Recovery Audit Contractor medical necessity audits. A successful medical necessity case management program can not only enhance regulatory compliance and reduce the amount of payments recouped by Medicare, but also generate additional inpatient revenue for your organization. With health care reform and accountable care organizations on the horizon, hospitals must find ways to protect and enhance revenue in order to carry out their missions. This is one way for case managers to help in that cause, to advocate for the care of their patients, and to bring value to the organization.

Ensuring Efficient Incentive and Disincentive Values for Highway Construction Projects: A Systematic Approach Balancing Road User, Agency and Contractor Acceleration Costs and Savings

Directory of Open Access Journals (Sweden)

Eul-Bum Lee

2018-03-01

Full Text Available United States State Highway Agencies (SHAs use Incentive/Disincentives (I/D to minimize negative impacts of construction on the traveling public through construction acceleration. Current I/D practices have the following short-comings: not standardized, over- or under-compensate contractors, lack of auditability result in disincentives that leave SHAs vulnerable to contractor claims and litigation and are based on agency costs/savings rather than contractor acceleration. Presented within this paper is an eleven-step I/D valuation process. The processes incorporate a US-nationwide RUC and agency cost calculation program, CA4PRS and a time-cost tradeoff I/D process. The incentive calculation used is the summation of the contractor acceleration and a reasonable contractor bonus (based on shared agency savings with an optional reduction of contractor’s own saving from schedule compression (acceleration. The process has a capability to be used both within the US and internationally with minor modifications, relies on historical costs, is simple and is auditable and repeatable. As such, it is a practical tool for optimizing I/D amounts and bridges the gap in existing literature both by its industry applicability, integrating the solution into existing SHA practices and its foundation of contractor acceleration costs.

Big Data Analysis of Contractor Performance Information for Services Acquisition in DoD: A Proof of Concept

Science.gov (United States)

2016-04-30

qÜáêíÉÉåíÜ=^ååì~ä= ^Åèìáëáíáçå=oÉëÉ~êÅÜ= póãéçëáìã= qÜìêëÇ~ó=pÉëëáçåë= sçäìãÉ=ff= = Big Data Analysis of Contractor Performance Information for Services...Director, Acquisition Career Management, ASN(RD&A) Big Data Analysis of Contractor Performance Information for Services Acquisition in DoD: A Proof of...oÉëÉ~êÅÜ=mêçÖê~ãW= `êÉ~íáåÖ=póåÉêÖó=Ñçê=fåÑçêãÉÇ=`Ü~åÖÉ= - 398 - Big Data Analysis of Contractor Performance Information for Services Acquisition in

48 CFR 52.236-1 - Performance of Work by the Contractor.

Science.gov (United States)

2010-10-01

... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Performance of Work by the....236-1 Performance of Work by the Contractor. As prescribed in 36.501(b), insert the following clause... the work and customary or necessary specialty subcontracting (see 36.501(a)).] Performance of Work by...

Entrepreneurship Antecedent on Student (Case : Female Students Final Year on Gunadarma University)

OpenAIRE

Ganefi, Marliza; Ratih, Sri Wulan Windu; Harmoni, Ati

2012-01-01

The purpose of this study is to examine and identify antecedents of female student entrepreneurial intention. This research attempts to investigate whether self-efficacy, perceptions of opportunities, prior knowledge of other entrepreneurs, and fear of failure are predictors of female student intention to be entrepreneur. As much as 233 students in their final year, selected proportionally from 12 study programs in Gunadarma University participated in the survey. Data was collected using ques...

Growth and final height of children with Gaucher disease: A 15-year follow-up at an Israeli Gaucher center.

Science.gov (United States)

Mendelsohn, Espen; Meir, Amos; Abrahamov, Aya; Elstein, Deborah; Zimran, Ari; Levy-Khademi, Floris

2018-02-01

It is held that enzyme replacement therapy (ERT) accelerates the growth rate in children with Gaucher disease, but its effect on final height has not been established with certainty. This study presents final heights of Gaucher patients followed up for 15years. The study included 41 adults with non-neuronopathic Gaucher disease. The final height of the patients and age at puberty was compared to their mid-parental target height and to their siblings' heights. Mean final height standard deviation score (HSDS) in the patients was -0.22, but none of the patients was abnormally short (HSDS of less than -2.2). Mean age at menarche of the female patients (14.7years) was significantly delayed compared to that of their mothers (P=0.0005), and mean age at first shaving in the boys was 16years. Our study showed that the mean final height of Gaucher patients fell below the mean of the 2000 CDC growth charts, but the patients were not of short stature (height less than the 3rd percentile). ERT treatment did not significantly impact the mean final HSDS. The onset of puberty, as indicated by the age at menarche, was delayed in girls with Gaucher disease. Copyright © 2016 Elsevier Inc. All rights reserved.

Radiation exposures for DOE [Department of Energy] and DOE contractor employees, 1988

International Nuclear Information System (INIS)

Merwin, S.E.; Traub, R.J.; Millet, W.H.

1990-12-01

This is the 21st in a series of annual radiation exposure reports published by the Department of Energy (DOE) or its predecessors. This report summarizes the radiation exposures received at DOE and DOE contractor facilities in 1988. Radiation exposures to both employees and visitors are included. Trends in radiation exposures are evaluated by comparing the doses received in 1988 to those received in previous years. The significance of the doses is addressed by comparing them to the DOE limits and by correlating the doses to health risks based on risk estimates from expert groups. This report represents a significant advancement from previous reports because it is the first for which detailed exposure data are available for each individual monitored at a DOE facility. This reports contains information on different types of radiation doses, such as penetrating, shallow, and neutron doses. It also contains analysis of exposures by age, sex, and occupation of the exposed individuals. This report is the first of any federal organization that presents such detailed exposure data. The purpose of this report is to disseminate information regarding radiation exposures received at US Department of Energy (DOE) and DOE contractor facilities. The primary purpose of this practice is to ensure that the DOE occupational dose limits are not exceeded and that as low as reasonably achievable (ALARA) goals are met. A secondary purpose, however, is to provide information that can be used by other organizations and individuals who wish to collect and analyze such information. This information may be useful for estimating the effect of changing dose limits on operations at DOE facilities, determining the progress of DOE with respect to the ALARA principle, or, in combination with epidemiological information, assisting researchers in determining whether or not low doses of ionizing radiation are harmful. 23 refs., 20 figs., 23 tabs

Quantity-split strategy under two-contractor competitive procurement environment

OpenAIRE

Boger, Dan C.; Liao, Shu S.

1988-01-01

This report discusses the various market scenarios that provide bid price manipulation opportunities under the dual source competition environment. Two different quantity-split strategies were developed one for the case when one of the suppliers does not have the capacity to produce the majority of the annual quantity requirement and the other for the case when neither contractor is interested in using low prices to capture the larger share of annual quantity. Keywords: Dual sourcing, Quantit...

The Excessive Profits of Defense Contractors: Evidence and Determinants

Science.gov (United States)

2012-04-30

UNILEVER NV $112,089,508 292 UL 2000 11 MOOG, INC. $111,608,841 293 MOG.A 3728 11 ALON USA L.P. $111,102,800 296 ALJ 2911 11 COCA - COLA ENTERPRISES...audits and investigations. As a national leader in the fight against procurement fraud, Miller participates in the U.S. Attorney General’s Financial Fraud...Excessive Profits of Defense Contractors: Evidence and Determinants1 Chong Wang—Wang is an assistant professor of financial management in the

78 FR 48123 - Federal Acquisition Regulation; Contractor Comment Period, Past Performance Evaluations

Science.gov (United States)

2013-08-07

....regulations.gov , including any personal and/or business confidential information provided. FOR FURTHER... equivalent of ``providing'' the past performance evaluation to the contractor, and it starts the suspense... explanations included, available to source selection officials within 14 days will be to the advantage of most...