Sample records for technology development-contractors coordination
-
Key drivers for informal project coordination among sub-contractors
DEFF Research Database (Denmark)
Aagaard, Annabeth; Eskerod, Pernille; Madsen, Erik Skov
2015-01-01
understandings. Still though, many sub-contractors choose not to coordinate informally. The purpose of this paper is to identify drivers that enhance or inhibits informal coordination in projects. A qualitative, explorative case study approach was applied. Fifteen SME sub-contractors within the offshore wind...... are massive. Six drivers which enhance informal coordination and three drivers which inhibit informal coordination among sub-contractors in projects were identified. The findings imply that management in project-oriented organizations can enhance informal coordination across project sub-contractors...... and by facilitating trust building, by emphasizing previous collaboration successes with the sub-contractors and the possibility of future common projects, by being explicit about expectations on informal coordination, and by developing sub-contractor contracts that are not as tight in economic terms, but instead...
-
Highway vehicle systems contractors coordination meeting. Seventeenth summary report
Energy Technology Data Exchange (ETDEWEB)
None
1979-01-01
Separate abstracts was prepared for each of the 62 papers presented at the Contractors' Coordination meeting on highway vehicle systems. One paper had previously appeared in DOE's data base.
-
Information technology boosts contractor's economic success
International Nuclear Information System (INIS)
Penny, M.; Vasey, G.M.
1995-01-01
This article will discuss the advantages of Information Technology (IT) and how one drilling contractor, Global Marine, has applied this technology. The company has applied it in an efficient manner which has provided business benefits and cost reductions that have helped its operations be more successful. The following are the different aspects of information technology that led to the contractor's success: cost reduction measures; migration to a client/server IT infrastructure; IT business benefits; and keys to obtaining business benefits from IT
-
Proceedings of the fuels technology contractors review meeting
Energy Technology Data Exchange (ETDEWEB)
Malone, R.D. [ed.
1993-11-01
The Fuels Technology Contractors Review Meeting was held November 16-18, 1993, at the Morgantown Energy Technology Center (METC) in Morgantown, West Virginia. This meeting was sponsored and hosted by METC, the Office of Fossil Energy, U.S. Department of Energy (DOE). METC periodically provides an opportunity to bring together all of the R&D participants in a DOE-sponsored contractors review meeting to present key results of their research and to provide technology transfer to the active research community and to the interested public. This meeting was previously called the Natural Gas Technology Contractors Review Meeting. This year it was expanded to include DOE-sponsored research on oil shale and tar sands and so was retitled the Fuels Technology Contractors Review Meeting. Current research activities include efforts in both natural gas and liquid fuels. The natural gas portion of the meeting included discussions of results summarizing work being conducted in fracture systems, both natural and induced; drilling, completion, and stimulation research; resource characterization; delivery and storage; gas to liquids research; and environmental issues. The meeting also included project and technology summaries on research in oil shale, tar sands, and mild coal gasification, and summaries of work in natural-gas fuel cells and natural-gas turbines. The format included oral and poster session presentations. Individual papers have been processed separately for inclusion in the Energy Science and Technology database.
-
Energy Technology Data Exchange (ETDEWEB)
Geiling, D.W. (USDOE Morgantown Energy Technology Center, WV (USA)); Goldberg, P.M. (eds.) (USDOE Pittsburgh Energy Technology Center, PA (USA))
1990-01-01
The 1990 Advanced Research and Technology Development (AR TD) Direct Utilization, and Instrumentation and Diagnostics Contractors Review Meeting was held September 16--18, 1990, at the Hyatt at Chatham Center in Pittsburgh, PA. The meeting was sponsored by the US Department of Energy (DOE), Office of Fossil Energy, and the Pittsburgh and Morgantown Energy Technology Centers. Each year the meeting provides a forum for the exchange of information among the DOE AR TD contractors and interested parties. This year's meeting was hosted by the Pittsburgh Energy Technology Center and was attended by 120 individuals from industry, academia, national laboratories, and other governmental agencies. Papers were presented on research addressing coal surface, science, devolatilization and combustion, ash behavior, emission controls for gases particulates, fluid bed combustion and utilization in diesels and turbines. Individual reports are processed separately for the data bases.
-
National Research Council Canada - National Science Library
2004-01-01
.... The report discusses the steps DoD needs to take to identify unclassified export-controlled technology and to ensure that DoD contractors, universities, and Federally Funded Research and Development...
-
48 CFR 939.7002 - Contractor acquisition of information technology.
2010-10-01
... information technology. 939.7002 Section 939.7002 Federal Acquisition Regulations System DEPARTMENT OF ENERGY SPECIAL CATEGORIES OF CONTRACTING ACQUISITION OF INFORMATION TECHNOLOGY Implementing DOE Policies and Procedures 939.7002 Contractor acquisition of information technology. (a) Management and operating (M&O...
-
Development and validation of a strategic repositioning model for defense and aerospace contractors
Bers, John A.
Strategic repositioning refers to the organized efforts of defense contractors to "reposition" a technology that they have developed for a defense sector customer into a civilian or commercial market. The strategic repositioning model developed here is a structural model: it seeks to isolate the factors that influence choice of strategy, which in turn influences the organization's performance. The model draws from the prior experience of contractors (through interviews and surveys) and companies in other sectors (through a review of the relevant published research). (1) Over all, the model accounted for 55% of the variance in financial performance of the sample and 35% for the underlying population. (2) Key success factors include a rigorous planning process, a target market in the growth (vs. incubation) stage, a priority on market leadership as well as financial return, the ability to operate in an ambiguous business environment, and a relatively short time horizon but strong corporate support. (3) The greatest challenges that a contractor is likely to encounter are understanding his new customers' buying practices, strong competition, and adapting his technology to their needs and price expectations. (4) To address these issues contractors often involve partners in their entry strategy, but partnerships of equals tend to be more difficult to bring off than direct entry strategies. (5) The two major target market categories--government and commercial--present different challenges. Commercial customers are more likely to resist doing business with the contractor, while contractors entering government and other noncommercial markets are more likely to encounter price resistance, low technical sophistication among customers, and difficulties reaching their customer base. (6) Despite these differences across markets, performance is not influenced by the target market category, nor by the type of product or service or the contractor's functional orientation (marketing
-
Reid, Concha M.; Miller, Thomas B.; Mercer, Carolyn R.; Jankovsky, Amy L.
2010-01-01
Technical Interchange Meeting was held at Saft America s Research and Development facility in Cockeysville, Maryland on Sept 28th-29th, 2010. The meeting was attended by Saft, contractors who are developing battery component materials under contracts awarded through a NASA Research Announcement (NRA), and NASA. This briefing presents an overview of the components being developed by the contractor attendees for the NASA s High Energy (HE) and Ultra High Energy (UHE) cells. The transition of the advanced lithium-ion cell development project at NASA from the Exploration Technology Development Program Energy Storage Project to the Enabling Technology Development and Demonstration High Efficiency Space Power Systems Project, changes to deliverable hardware and schedule due to a reduced budget, and our roadmap to develop cells and provide periodic off-ramps for cell technology for demonstrations are discussed. This meeting gave the materials and cell developers the opportunity to discuss the intricacies of their materials and determine strategies to address any particulars of the technology.
-
Copp, Susan L.
2010-01-01
The objective of this research was to use technology to develop an on-line orientation manual for clinical research coordinators. Many clinical research coordinators begin their careers as staff nurses and have little knowledge related to clinical research. As such, when they transition to a career in clinical research they lack the knowledge…
-
CSIR Research Space (South Africa)
Dlungwana, Wilkin S
2008-11-01
Full Text Available to be suffered, but an opportunity to be managed. The notion of South Africa’s “technology colony” status is explored to highlight the country’s challenges in terms of technological development. The authors suggest that an Integrated Emerging Contractor...
-
Contractor evaluations in the contractor selection process.
2014-04-01
The current contractor evaluation system in use within the Kentucky Transportation Cabinet is based on the contractor evaluation system developed as part of SPR 212-00 "Quality Based Prequalification of Contractors." This system relies on average per...
-
CSIR Research Space (South Africa)
Dlungwana, Wilkin S
2004-11-01
Full Text Available Construction industry and indeed all small and medium-sized contractors play a significant socio-economic role in the developing countries. This paper highlights the importance of promoting sustainable building through the implementation...
-
Energy Technology Data Exchange (ETDEWEB)
Fitzsimmons, Tim [Dept. of Energy (DOE), Washington DC (United States). Office of Basic Energy Sciences. Division of Materials Sciences and Engineering
2006-05-16
This volume highlights the scientific content of the 2006 Hydrogen Contractors Meeting sponsored by the Division of Materials Sciences and Engineering (DMS&E) on behalf of the Office of Basic Energy Sciences (BES) of the U. S. Department of Energy (DOE). Hydrogen Contractors Meeting held from May 16-19, 2006 at the Crystal Gateway Marriott Hotel Arlington, Virginia. This meeting is the second in a series of research theme-based Contractors Meetings sponsored by DMS&E held in conjunction with our counterparts in the Office of Energy Efficiency and Renewable Energy (EERE) and the first with the Hydrogen, Fuel Cells and Infrastructure Technologies Program. The focus of this year’s meeting is BES funded fundamental research underpinning advancement of hydrogen storage. The major goals of these research efforts are the development of a fundamental scientific base in terms of new concepts, theories and computational tools; new characterization capabilities; and new materials that could be used or mimicked in advancing capabilities for hydrogen storage.
-
Coordination theory and collaboration technology
Olson, Gary M; Smith, John B
2001-01-01
The National Science Foundation funded the first Coordination Theory and Collaboration Technology initiative to look at systems that support collaborations in business and elsewhere. This book explores the global revolution in human interconnectedness. It will discuss the various collaborative workgroups and their use in technology. The initiative focuses on processes of coordination and cooperation among autonomous units in human systems, in computer and communication systems, and in hybrid organizations of both systems. This initiative is motivated by three scientific issues which have been
-
6 CFR 25.8 - Government contractor Defense.
2010-01-01
... 6 Domestic Security 1 2010-01-01 2010-01-01 false Government contractor Defense. 25.8 Section 25.8...-TERRORISM BY FOSTERING EFFECTIVE TECHNOLOGIES § 25.8 Government contractor Defense. (a) Criteria for... applicability of the government contractor defense. In determining whether to issue such Certification, the...
-
Hand in Glove? Small Building Contractors, Mobile Technology and Innovation
DEFF Research Database (Denmark)
Buser, Martine; Koch, Christian; Tambo, Torben
2010-01-01
for construction are developing as well. A recent review shows a small portfolio of systems using mobile computing to support specifically the construction project processes. The aim of this paper is to evaluate the use of mobile computing at small construction contractors. The paper presents a quantitative...
-
Coordinating technology introduction and entrepreneurial activities in rural areas
Fokkema, J.E.; Pennink, B.J.W.; Simatupang, T.M.
2017-01-01
© Copyright 2017 Inderscience Enterprises Ltd. The main purpose of this research is to investigate how technology introduction projects in rural areas should be coordinated in order to achieve local economic development and the role of social capital and entrepreneurial activities. Characteristics
-
Technology development and applications at Fernald
International Nuclear Information System (INIS)
Pettit, P.J.; Skriba, M.C.; Warner, R.D.
1995-01-01
At the Fernald Environmental Management Project (FEMP) northwest of Cincinnati, Ohio, the U.S. Department of Energy and contractor Fernald Environmental Restoration Management Corporation (FERMCO) are aggressively pursuing both the development and the application of improved, innovative technology to the environmental restoration task. Application of emerging technologies is particularly challenging in a regulatory environment that places pressure on operational managers to develop and meet tight schedules. The regulatory and operational needs make close communication essential between technology developers and technology users (CERCLA/RCRA Unit managers). At Fernald this cooperation and communication has led, not only to the development and demonstration of new technologies with applications at other sites, but also to application of new technologies directly to the Fernald clean up. New technologies have been applied to improve environmental safety and health, improve the effectiveness of restoration efforts, and to cut restoration costs. The paper will describe successful efforts to develop and apply new technologies at the FEMP and will emphasize those technologies that have been applied and are planned for use in the clean up of this former uranium production facility
-
Operator/contractor relationships
International Nuclear Information System (INIS)
Smith, J.R.; Kidwell, C.K.; Unger, V.E.; Fercho, E.; Helmer, C.M.
1992-01-01
In May 1988, Shell Western E and P Inc. (SWEPI) and partners Elf Aquitaine Petroleum and Conoco Inc. signed a letter of intent with Canadian Marine Drilling Ltd. (Canmar) for provision of exploratory drilling and marine services on leases in OCS Lease Sale 109 in the Chukchi Sea, Alaska. The 5450 blocks offered in the remote sale area west of Point Barrow ranged from 3 to 240 miles (5 to 380 km) offshore in water depths from 26 to 263 feet (8 to 80 m). The principal interest tracts were at least 75 miles (120 km) offshore and north of 70 degrees N latitude. The remoteness and total lack of any oilfield infrastructure required considerable planning and coordination between Operator and Contractor in order to carry out the three-year drilling program efficiently and safely in an environmentally harsh and, at the same time, sensitive area. SWEPI and Canmar developed a close working relationship from the start of the project through a number of participative approaches to the problems that had to be solved. This paper reports that these included strong reliance on operational planning meetings, post-season analyses, and an overall emphasis on the teamwork required of both parties to carry out the first-ever drilling program in the Chukchi Sea. This approach led to a very successful operation for both parties and emphasizes the positive benefits achievable when Operator and Contractor work as a team
-
Structured Transition of Wind Tunnel Operations Skills from Government-to Contractor-Managed
Dunn, Steven C.; Schlank, John J.
2010-01-01
In 2004, NASA awarded the Research, Operations, Maintenance, and Engineering (ROME) contract at NASA Langley Research Center to a team led by Jacobs Technology, Inc. A key component of the contract was the transitioning of the five large wind tunnel facilities from NASA managed and NASA or NASA/contractor workforces to fully contractor operated. The contractor would manage daily operations while NASA would continue to develop long-term strategies, make decisions regarding commitment of funds and commitment of facilities, and provide oversight of the contractor's performance. A major challenge would be the transition of knowledge of facility operations and maintenance from the incumbent civil servant workforce to the contractor workforce. While the contract has since been modified multiple times, resulting in a blended NASA/ROME workforce across the facilities, the processes developed and implemented to capture and document facility knowledge from the incumbent subject matter experts, build training and certification programs, and grow individual skills across subject areas and across facilities, are worthy of documentation. This is the purpose of this paper.
-
Blackley, David J.; Retzer, Kyla D.; Hubler, Warren G.; Hill, Ryan D.; Laney, A. Scott
2015-01-01
Background Occupational fatality rates among oil and gas extraction industry and specifically among drilling contractor workers are high compared to the U.S. all-industry average. There is scant literature focused on non-fatal injuries among drilling contractors, some of which have introduced engineering controls to improve rig efficiency and reduce injury risk. Methods We compared injury rates on new and old technology rigs operated by the largest U.S. drilling contractor during 2003–2012, stratifying by job type and grouping outcomes by injury severity and body part affected. Results Six hundred seventy-one injuries were recorded over 77.4 million person-hours. The rate on new rigs was 66% of that on old rigs. Roughnecks had lower injury rates on new rigs, largely through reduced limb injury rates. New rigs had lower rates in each non-fatal injury severity category. Conclusions For this company, new technology rigs appear to provide a safer environment for roughnecks. Future studies could include data from additional companies. PMID:25164118
-
Blackley, David J; Retzer, Kyla D; Hubler, Warren G; Hill, Ryan D; Laney, A Scott
2014-10-01
Occupational fatality rates among oil and gas extraction industry and specifically among drilling contractor workers are high compared to the U.S. all-industry average. There is scant literature focused on non-fatal injuries among drilling contractors, some of which have introduced engineering controls to improve rig efficiency and reduce injury risk. We compared injury rates on new and old technology rigs operated by the largest U.S. drilling contractor during 2003-2012, stratifying by job type and grouping outcomes by injury severity and body part affected. Six hundred seventy-one injuries were recorded over 77.4 million person-hours. The rate on new rigs was 66% of that on old rigs. Roughnecks had lower injury rates on new rigs, largely through reduced limb injury rates. New rigs had lower rates in each non-fatal injury severity category. For this company, new technology rigs appear to provide a safer environment for roughnecks. Future studies could include data from additional companies. © 2014 Wiley Periodicals, Inc.
-
Innovative Technology Development Program. Final summary report
International Nuclear Information System (INIS)
Beller, J.
1995-08-01
Through the Office of Technology Development (OTD), the U.S. Department of Energy (DOE) has initiated a national applied research, development, demonstration, testing, and evaluation program, whose goal has been to resolve the major technical issues and rapidly advance technologies for environmental restoration and waste management. The Innovative Technology Development (ITD) Program was established as a part of the DOE, Research, Development, Demonstration, Testing, and Evaluation (RDDT ampersand E) Program. The plan is part of the DOE's program to restore sites impacted by weapons production and to upgrade future waste management operations. On July 10, 1990, DOE issued a Program Research and Development Announcement (PRDA) through the Idaho Operations Office to solicit private sector help in developing innovative technologies to support DOE's clean-up goals. This report presents summaries of each of the seven projects, which developed and tested the technologies proposed by the seven private contractors selected through the PRDA process
-
Energy Technology Data Exchange (ETDEWEB)
Haji-Saeid, M. [International Atomic Energy Agency (IAEA), Wagramer Strasse 5, A-1400 Vienna (Austria)], E-mail: M.Haji-Saeid@iaea.org; Sampa, M.H.; Ramamoorthy, N. [International Atomic Energy Agency (IAEA), Wagramer Strasse 5, A-1400 Vienna (Austria); Gueven, O. [Hacettepe University, Department of Chemistry, Ankara (Turkey); Chmielewski, A.G. [Faculty of Chemical and Process Engineering, Warsaw University of Technology, Warsaw (Poland)
2007-12-15
The IAEA has been playing a significant role in fostering developments in radiation technology in general and radiation processing of polymers in particular, among its Member States (MS) and facilitate know-how/technology transfer to developing MS. The former is usually achieved through coordinated research projects (CRP) and thematic technical meetings, while the latter is mainly accomplished through technical cooperation (TC) projects. Coordinated research projects encourage research on, and development and practical application of, radiation technology to foster exchange of scientific and technical information. The technical cooperation (TC) programme helps Member States to realize their development priorities through the application of appropriate radiation technology. The IAEA has implemented several coordinated research projects (CRP) recently, including one on-going project, in the field of radiation processing of polymeric materials. The CRPs facilitated the acquisition and dissemination of know-how and technology for controlling of degradation effects in radiation processing of polymers, radiation synthesis of stimuli-responsive membranes, hydrogels and absorbents for separation purposes and the use of radiation processing to prepare biomaterials for applications in medicine. The IAEA extends cooperation to well-known international conferences dealing with radiation technology to facilitate participation of talented scientists from developing MS and building collaborations. The IAEA published technical documents, covering the findings of thematic technical meetings (TM) and coordinated research projects have been an important source of valuable practical information.
-
International Nuclear Information System (INIS)
Haji-Saeid, M.; Sampa, M.H.; Ramamoorthy, N.; Gueven, O.; Chmielewski, A.G.
2007-01-01
The IAEA has been playing a significant role in fostering developments in radiation technology in general and radiation processing of polymers in particular, among its Member States (MS) and facilitate know-how/technology transfer to developing MS. The former is usually achieved through coordinated research projects (CRP) and thematic technical meetings, while the latter is mainly accomplished through technical cooperation (TC) projects. Coordinated research projects encourage research on, and development and practical application of, radiation technology to foster exchange of scientific and technical information. The technical cooperation (TC) programme helps Member States to realize their development priorities through the application of appropriate radiation technology. The IAEA has implemented several coordinated research projects (CRP) recently, including one on-going project, in the field of radiation processing of polymeric materials. The CRPs facilitated the acquisition and dissemination of know-how and technology for controlling of degradation effects in radiation processing of polymers, radiation synthesis of stimuli-responsive membranes, hydrogels and absorbents for separation purposes and the use of radiation processing to prepare biomaterials for applications in medicine. The IAEA extends cooperation to well-known international conferences dealing with radiation technology to facilitate participation of talented scientists from developing MS and building collaborations. The IAEA published technical documents, covering the findings of thematic technical meetings (TM) and coordinated research projects have been an important source of valuable practical information
-
FY94 Office of Technology Development Mixed Waste Operations Robotics Demonstration
International Nuclear Information System (INIS)
Kriikku, E.M.
1994-01-01
The Department of Energy (DOE) Office of Technology Development (OTD) develops technologies to help solve waste management and environmental problems at DOE sites. The OTD includes the Robotics Technology Development Program (RTDP) and the Mixed Waste Integrated Program (MWIP). Together these programs will provide technologies for DOE mixed waste cleanup projects. Mixed waste contains both radioactive and hazardous constituents. DOE sites currently store over 240,000 cubic meters of low level mixed waste and cleanup activities will generate several hundred thousand more cubic meters. Federal and state regulations require that this waste must be processed before final disposal. The OTD RTDP Mixed Waste Operations (MWO) team held several robotic demonstrations at the Savannah River Site (SRS) during November of 1993. Over 330 representatives from DOE, Government Contractors, industry, and universities attended. The MWO team includes: Fernald Environmental Management Project (FEMP), Idaho National Engineering Laboratory (INEL), Lawrence Livermore National Laboratory (LLNL), Oak Ridge National Engineering Laboratory (ORNL), Sandia National Laboratory (SNL), and Savannah River Technology Center (SRTC). SRTC is the lead site for MWO and provides the technical coordinator. The primary demonstration objective was to show that robotic technologies can make DOE waste facilities run better, faster, more cost effective, and safer. To meet the primary objective, the demonstrations successfully showed the following remote waste drum processing activities: non-destructive drum examination, drum transportation, drum opening, removing waste from a drum, characterize and sort waste items, scarify metal waste, and inspect stored drums. To further meet the primary objective, the demonstrations successfully showed the following remote waste box processing activities: swing free crane control, workcell modeling, and torch standoff control
-
Energy Technology Data Exchange (ETDEWEB)
Durfee, Justin David [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States); Frazier, Christopher Rawls [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States); Bandlow, Alisa [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States); Gearhart, Jared Lee [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States); Jones, Katherine A. [Sandia National Lab. (SNL-NM), Albuquerque, NM (United States)
2016-06-01
Sandia National Laboratories (Sandia) is in Phase 3 Sustainment of development of a prototype tool, currently referred to as the Contingency Contractor Optimization Tool - Prototype (CCOTP), under the direction of OSD Program Support. CCOT-P is intended to help provide senior Department of Defense (DoD) leaders with comprehensive insight into the global availability, readiness and capabilities of the Total Force Mix. The CCOT-P will allow senior decision makers to quickly and accurately assess the impacts, risks and mitigating strategies for proposed changes to force/capabilities assignments, apportionments and allocations options, focusing specifically on contingency contractor planning. During Phase 2 of the program, conducted during fiscal year 2012, Sandia developed an electronic storyboard prototype of the Contingency Contractor Optimization Tool that can be used for communication with senior decision makers and other Operational Contract Support (OCS) stakeholders. Phase 3 used feedback from demonstrations of the electronic storyboard prototype to develop an engineering prototype for planners to evaluate. Sandia worked with the DoD and Joint Chiefs of Staff strategic planning community to get feedback and input to ensure that the engineering prototype was developed to closely align with future planning needs. The intended deployment environment was also a key consideration as this prototype was developed. Initial release of the engineering prototype was done on servers at Sandia in the middle of Phase 3. In 2013, the tool was installed on a production pilot server managed by the OUSD(AT&L) eBusiness Center. The purpose of this document is to specify the CCOT-P engineering prototype platform requirements as of May 2016. Sandia developed the CCOT-P engineering prototype using common technologies to minimize the likelihood of deployment issues. CCOT-P engineering prototype was architected and designed to be as independent as possible of the major deployment
-
The development of nuclear technology transfer
International Nuclear Information System (INIS)
Nack-chung Sung
1987-01-01
Korea, as a recipient of nuclear technology transfer, has good experience of progressively building up its indigeneous capability of nuclear technology through three stages of technology transfer, namely: technology transfer under the turnkey approach, component approach, and integrated technology transfer with a local prime contractor. Here, each stage of experience of technology transfer, with Korea as a recipient, is presented. (author)
-
Cask technology program activities
International Nuclear Information System (INIS)
Allen, G.C. Jr.
1986-01-01
The civilian waste cask technology program consists of five major activities: Technical issue resolution directed toward NRC and DOT concerns; system concept evaluations to determine the benefits of proposals made to DOE for transportation improvements; applied technology and technical data tasks that provide independent information and enhance technology transfer between cask contractors; standards development and code benchmarking that provide a service to DOE and cask contractors; and testing to ensure the adequacy of cask designs. This paper addresses broad issues that affect several cask development contractors and areas where independent technical input could enhance OCRWM goals
-
Romeo, James
2013-01-01
NASA is committed to finding solutions to agency cleanup problems that are better, cheaper, and more effective than the status quo. Unfortunately, some potential solutions involve innovative technologies for which NASA remediation managers may not have a high level of understanding or confidence. Since 2004, NASA's Stennis Space Center (SSC) in Mississippi has been pumping groundwater contaminated with trichloroethylene (TCE) and other halogenated volatile organic compounds (HVOC) from their cleanup location designated "Area G" through extraction wells to an aboveground treatment system. Over time, however, the effectiveness of this treatment strategy has diminished and an alternative approach is needed. In 2012, professionals from NASA's Principal Center for Technology Evaluation for Environmental Risk Mitigation (TEERM) introduced SSC managers to an innovative technology for enhancing the performance of SSC's existing pump and treat system. The technology, generally referred to as in situ chemical oxidation (ISCO), involves slowly and continuously injecting a strong but safe chemical oxidant into the groundwater. Treatment is enhanced by a "surfactant-type effect" which causes residual contamination from saturated soil to be released into the dissolved-phase where it can be readily oxidized. Any dissolved-phase contamination that was not oxidized can be collected by the extraction well network and treated aboveground. SSC was not familiar with the technology so to increase their confidence, TEERM identified a contractor who was willing to demonstrate their product and process at a significantly reduced price. An initial, small-scale demonstration of ISCO began at sse in March 2012 and completed in August 2012. This successful demonstration was followed by three larger-scale ISCO demonstrations between August and December 2012. The contractor's innovative Continuous Injection System (CIS) incorporated "green" and sustainable technologies and practices. A slow
-
Energy Technology Data Exchange (ETDEWEB)
Durfee, Justin David; Frazier, Christopher Rawls; Bandlow, Alisa; Jones, Katherine A
2016-05-01
This document describes the final software design of the Contingency Contractor Optimization Tool - Prototype. Its purpose is to provide the overall architecture of the software and the logic behind this architecture. Documentation for the individual classes is provided in the application Javadoc. The Contingency Contractor Optimization project is intended to address Department of Defense mandates by delivering a centralized strategic planning tool that allows senior decision makers to quickly and accurately assess the impacts, risks, and mitigation strategies associated with utilizing contract support. The Contingency Contractor Optimization Tool - Prototype was developed in Phase 3 of the OSD ATL Contingency Contractor Optimization project to support strategic planning for contingency contractors. The planning tool uses a model to optimize the Total Force mix by minimizing the combined total costs for selected mission scenarios. The model optimizes the match of personnel types (military, DoD civilian, and contractors) and capabilities to meet mission requirements as effectively as possible, based on risk, cost, and other requirements.
-
Contractor Performance Assessment Reporting System
US Agency for International Development — CPARS is a web-based system used to input data on contractor performance. Reports from the system are used as an aid in awarding contracts to contractors that...
-
Safeguards and Security Technology Development Directory. FY 1993
Energy Technology Data Exchange (ETDEWEB)
1993-06-01
The Safeguards and Security Technology Development Directory is published annually by the Office of Safeguards and Security (OSS) of the US Department of Energy (DOE), and is Intended to inform recipients of the full scope of the OSS R&D program. It is distributed for use by DOE headquarters personnel, DOE program offices, DOE field offices, DOE operating contractors, national laboratories, other federal agencies, and foreign governments. Chapters 1 through 7 of the Directory provide general information regarding the Technology Development Program, including the mission, program description, organizational roles and responsibilities, technology development lifecycle, requirements analysis, program formulation, the task selection process, technology development infrastructure, technology transfer activities, and current research and development tasks. These chapters are followed by a series of appendices which contain more specific information on aspects of the Program. Appendix A is a summary of major technology development accomplishments made during FY 1992. Appendix B lists S&S technology development reports issued during FY 1992 which reflect work accomplished through the OSS Technology Development Program and other relevant activities outside the Program. Finally, Appendix C summarizes the individual task statements which comprise the FY 1993 Technology Development Program.
-
2011-02-22
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access... policy framework for the development and adoption of a nationwide health information technology...
-
International Nuclear Information System (INIS)
Blanton, M.L.; Montgomery, E.W.
1991-01-01
The recent trend in the United States and Shell Oil Company EandP has been to increase use of contractors to do specialized work. Many companies now use contractors almost exclusively for operations such as drilling, well workovers, construction, and many specialty and routine maintenance tasks. Today, approximately 75% of Shell Oil Company's actual operating work force in EandP is contract. Clearly, HSandE considerations must become an increasingly important part of the contractor selection process. This paper reports on the Shell Oil Company's evolution from a bidder selection process to a program of Matching Owner and Contractor. Well has begun to expand efforts to make better assessments of contractor's HSandE capabilities and values in pre-bid considerations. Focus is on pre-bid evaluations to select contractors that have strong HSandE commitments and values. Contractor safety performance in this industry must be brought up to the same standards as operating companies. In Shell Oil EandP is only willing to contractors who can and are willing to do that
-
Cask technology program activities
International Nuclear Information System (INIS)
Allen, G.C. Jr.
1986-01-01
The civilian waste cask technology program consists of five major activities: (1) technical issue resolution directed toward NRC and DOT concerns, (2) system concept evaluations to determine the benefits of proposals made to DOE for transportation improvements, (3) applied technology and technical data tasks that provide independent information and enhance technology transfer between cask contractors, (4) standards development and code benchmarking that provide a service to DOE and cask contractors, and (5) testing to ensure the adequacy of cask designs. The program addresses broad issues that affect several cask development contractors and areas where independent technical input could enhance the Office of Civilian Radioactive Waste Management goals
-
2010-03-31
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health information technology infrastructure that...
-
2010-01-04
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health information technology infrastructure that...
-
2011-02-22
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health information technology infrastructure that...
-
2010-10-25
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health information technology infrastructure that...
-
2010-05-27
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health information technology infrastructure that...
-
2010-08-23
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health information technology infrastructure that...
-
2010-02-26
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... a policy framework for the development and adoption of a nationwide health information technology...
-
2011-01-25
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health information technology infrastructure that...
-
2010-02-03
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health information technology infrastructure that...
-
2010-09-17
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health information technology infrastructure that...
-
2010-07-20
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health information technology infrastructure that...
-
A Multi-Agent Framework for Coordination of Intelligent Assistive Technologies
DEFF Research Database (Denmark)
Valente, Pedro Ricardo da Nova; Hossain, S.; Groenbaek, B.
2010-01-01
Intelligent care for the future is the IntelliCare project's main priority. This paper describes the design of a generic multi-agent framework for coordination of intelligent assistive technologies. The paper overviews technologies and software systems suitable for context awareness...... and housekeeping tasks, especially for performing a multi-robot cleaning-task activity. It also describes conducted work in the design of a multi-agent platform for coordination of intelligent assistive technologies. Instead of using traditional robot odometry estimation methods, we have tested an independent...
-
Directory of Open Access Journals (Sweden)
Spillane, John P
2011-12-01
Full Text Available The aim of this paper is to identify the various managerial issues encountered by UK/Irish contractors in the management of materials in confined urban construction sites. Through extensive literature review, detailed interviews, case studies, cognitive mapping, causal loop diagrams, questionnaire survey and documenting severity indices, a comprehensive insight into the materials management concerns within a confined construction site environment is envisaged and portrayed. The leading issues highlighted are: that contractors’ material spatial requirements exceed available space, it is difficult to coordinate the storage of materials in line with the programme, location of the site entrance makes delivery of materials particularly difficult, it is difficult to store materials on-site due to the lack of space, and difficult to coordinate the storage requirements of the various sub-contractors. With the continued development of confined urban centres and the increasing high cost of materials, any marginal savings made on-site would translate into significant monetary savings at project completion. Such savings would give developers a distinct competitive advantage in this challenging economic climate. As on-site management professionals successfully identify, acknowledge and counteract the numerous issues illustrated, the successful management of materials on a confined urban construction site becomes attainable.
-
Cross-national research on contractor evaluation procedures in public works procurement
Kinoshita, Seiya; Sato, Naoyoshi; Matsumoto, Naoya
Contractor evaluation methods in Japan's public works procurement, beginning with construction business licensure, going through biennial preliminary firm rating, up to project-by-project prequalification and comprehensive point rating, were developed during the period when public works were mostly procured through designated competitive bidding. It is essential to focus attention on contractor evaluation methods for introducing different types of procurement procedures which enhance the use of technological capabilities held by private businesses. An overall review of contractor evaluation procedures should be conducted in view of the present situation, where the open competitive bidding has become mainly used in combination with comprehensive evaluation, as well as to allow for further diversification of procurement methods. In Western countries, improvements have been made for the past several years in contractor evaluation procedures with more emphasis on "Value for Money." Advanced efforts made by these countries will be useful as a reference for overhauling Japan's contractor evaluation system. This study conducts a comparative review of contractor evaluation procedures for public procurement in Western countries such as the United States, the United Kingdom and France by identifying similarities and differences between those of Japan and the above mentioned countries. This reveals that a contractor's technical or professional ability is looked at separately from its economic and financial standing in those countries studied, and there is no case like Japan in which those two factors are integrated into one for evaluation.
-
International Nuclear Information System (INIS)
Haji Saeid, M.
2006-01-01
The IAEA has been playing a significant role in fostering developments in radiation technology in general and radiation processing of polymers in particular, among its Member States (MS) and facilitate know-how/technology transfer to developing MS. The former is usually achieved through coordinated research projects (CRP) and thematic technical meetings, while the latter is mainly accomplished through Technical Cooperation (TC) projects. Coordinated research projects encourage research on, and development and practical application of, radiation technology to foster exchange of scientific and technical information. The CRP brings together typically 10 - 15 groups of participants to share and complement core competencies and work on specific areas of development needed to benefit from an emerging radiation technique and its applications. The technical cooperation (TC) programme helps Member States realize their development priorities through the application of appropriate radiation technology. TC builds national capacities through training, expert advice and delivery of equipment. The impact of the IAEA's efforts is visible by the progress noticeable in adoption of radiation technology and/or growth in the range of activities in several MS in different regions. The IAEA has implemented several coordinated research projects (CRP) recently, including one on-going project, in the field of radiation processing of polymeric materials. The CRPs facilitated the acquisition and dissemination of know-how and technology for controlling of degradation effects in radiation processing of polymers, radiation synthesis of stimuli-responsive membranes, hydrogels and absorbents for separation purposes and the use of radiation processing to prepare biomaterials for applications in medicine. A number of technical cooperation projects have been implemented in this field to strengthen the capability of developing Member States and to create awareness in the industries about the technical
-
Ustailieva, E.; Starren, A.
2013-01-01
Companies function more and more in networks (i.e. contractor chains with contractors, suppliers and/or other companies. This asks for several companies/parties to work together to get the work done. Working in contractor chains is very common in sectors like maintenance, construction, cleaning, and
-
2006 Fundamental Research Underlying Solid-State Lighting: Contractors Meeting
Energy Technology Data Exchange (ETDEWEB)
Fitzsimmons, Tim [Dept. of Energy (DOE), Washington, DC (United States). Office of Basic Energy Sciences. Division of Materials Sciences and Engineering; Kini, Arvind [Dept. of Energy (DOE), Washington, DC (United States). Office of Basic Energy Sciences. Division of Materials Sciences and Engineering; Kelley, Dick [Dept. of Energy (DOE), Washington, DC (United States). Office of Basic Energy Sciences. Division of Materials Sciences and Engineering
2006-02-01
This volume highlights the scientific content of the 2006 Fundamental Research Underlying Solid-State Lighting Contractors Meeting sponsored by the Division of Materials Sciences and Engineering (DMS&E) in the Office of Basic Energy Sciences (BES) of the U. S. Department of Energy (DOE). This meeting is the second in a series of research theme-based Contractors Meetings and will focus on BES/DMS&E-funded research that underpins solid-state lighting technology. The meeting will feature research that cuts across several DMS&E core research program areas. The major programmatic emphasis is on developing a fundamental scientific base, in terms of new concepts and new materials that could be used or mimicked in designing novel materials, processes or devices.
-
2010-08-23
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee... framework for the development and adoption of a nationwide health [[Page 51820
-
Critical Electronic Data Loss Perceptions of United States Military Contractors
Singletary, Tod J.
2017-01-01
The United States Military has become increasingly dependent upon technology to meet its mission objectives with a consequence being greater dependence on civilian defense contractors to provide specialized services in support of high-tech mission requirements. Modern military defense contractors have also become dependent upon reliable and secure…
-
2010-06-08
... Coordinator for Health Information Technology AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of committee recommendations and invitation for public input... Coordinator for Health Information Technology (ONC). Name of Committee: HIT Standards Committee. General...
-
A New Data Acquisition Portal for the Sacramento River Settlement Contractors
Narlesky, P. E., C. A.; Williams, P. E., A. M.
2017-12-01
In 1964, the United States Bureau of Reclamation (Reclamation) executed settlement contracts with the Sacramento River Settlement Contractors (SRSC), entities which hold water rights along the Sacramento River with area of origin protection or that are senior to Reclamation's water rights for Shasta Reservoir. Shasta is the cornerstone of the federal Central Valley Project (CVP), one of the nation's largest multi-purpose water conservation programs. In order to optimize CVP operations for multiple beneficial uses including water supply, fisheries, water quality, and waterfowl habitat, the SRSC voluntarily agreed to adaptively manage diversions throughout the year in close coordination with Reclamation. MBK Engineers assists the SRSC throughout this process by collecting, organizing, compiling, and distributing diversion data to Reclamation and others involved in operational decisions related to Shasta Reservoir and the CVP. To improve and expand participation in diversions reporting, we have developed the SRSC Web Portal, which launches a data-entry dashboard for members of the SRSC to facilitate recording and transmittal of both predicted and observed monthly and daily flow diversion data. This cloud-hosted system leverages a combination of Javascript interactive visualization libraries with a database-backed Python web framework to present streamlined data-entry forms and valuable SRSC program summary illustrations. SRSC program totals, which can now be aggregated through queries to the web-app's database backend, are used by Reclamation, SRSC, fish agencies, and others to inform operational decisions. By submitting diversion schedules and tracking actual diversions through the portal, contractors will also be directly contributing to the development of a richer and more consistently-formatted historical record for demand hydrology in the Sacramento River Watershed; this may be useful in future water supply studies. Adoption of this technology will foster an
-
2010-03-31
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Standards... and Coordination, Office of the National Coordinator for Health Information Technology. [FR Doc. 2010...
-
Syafiq Salim, Muhamad; Zakaria, Rozana; Aminuddin, Eeydzah; Hamid, Abdul Rahim Abdul; Abdullah, Redzuan; Shahzaib Khan, Jam
2018-04-01
Iskandar Malaysia is an advanced economic hub which is rapidly growing in the State of Johor. It has been an attractive place for Foreign Direct Investment (FDI) to invest. Many sectors are affected by the presence of FDI including the construction sector. This paper highlights the investigation on the effects of FDI to the local contractor in the Iskandar Malaysia Development. In this study, a questionnaire survey was carried out to gain the information on problems from internal factors and external factors that caused the limitation on involvement in FDI project by local contractors. 73 numbers of local contractor registered under CIDB in class G5, G6 and G7 are the respondents. Frequency analysis and Average Index Analysis are used for the results. This study provides the factors that impacted local construction players in Iskandar Malaysia Development. This study has portrayed that FDI plays a vital and significant role in spearheading the active involvement of local contractors in an urban sustainable development.
-
A proposed office of technology development education program
Energy Technology Data Exchange (ETDEWEB)
1992-12-31
The office of Environmental Restoration and Waste Management (EM) was formed within the US Department of Energy (DOE) to clean up radioactive and hazardous wastes on US government sites associated with the production and use of nuclear weapon materials In order to insure the development and demonstration of technologies necessary for the task, EM established an office of Technology Development (OTD). Furthermore, in order to accomplish this massive effort, DOE and its contractors will need large numbers of technically trained people. Because of the demands on the same pool of such individuals by other government agencies and the private sector, it is not clear that the supply will be sufficient to meet the competing demands.
-
2010-01-04
... Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Standards... Programs and Coordination Office of the National Coordinator for Health Information Technology. [FR Doc. E9...
-
Highlights of contractor initiatives in quality enhancement and productivity improvement
1986-01-01
The NASA/Contractor Team efforts are presented as part of NASA's continuing effort to facilitate the sharing of quality and productivity improvement ideas among its contractors. This complilation is not meant to be a comprehensive review of contractor initiative nor does it necessarily express NASA's views. The submissions represent samples from a general survey, and were not edited by NASA. The efforts are examples of quality and productivity programs in private industry, and as such, highlight company efforts in individual areas. Topics range from modernization of equipment, hardware, and technology to management of human resources. Of particular interest are contractor initiatives which deal with measurement and evaluation data pertaining to quality and productivity performance.
-
CSIR Research Space (South Africa)
Dlungwana, Sihle
2018-01-01
Full Text Available on skills development frameworks for small and medium-sized contractors in the green building sector Sihle Dlungwana Senior Researcher, CSIR Built Environment Unit Introduction In 2011 the Department of Public Works adopted a Green Building... of their characteristics. Thematic analysis was used to analyse a number of articles in order to develop an appropriate framework for supporting future skills development programmes and tools for the green building sector. Defining a green contractor Generally...
-
A practical due diligence strategy for managing the safety of contractors
International Nuclear Information System (INIS)
Catton, C.
1998-01-01
Ontario Hydro's Fossil Business has developed and implemented a practical program to ensure that the due diligence requirements for contractors are met, particularly in the health and safety area. Companies in the power generation business are hiring contractors to protect their competitive potential by having them perform specialty work outside the core business of generating electricity. The reasons behind this trend, and the need for companies to develop comprehensive contractor safety management systems to avoid legislative liability and cost overruns, and to have contractors work safely, are examined. The main elements of Ontario Hydro's Fossil Business Contractor Safety Management Program (contractor safety policy, contractor safety manual, contractor safety training, and a contractor safety performance database) are discussed. 2 figs., 2 appendices
-
48 CFR 252.229-7004 - Status of contractors as a direct contractor (Spain).
2010-10-01
... direct contractor (Spain). 252.229-7004 Section 252.229-7004 Federal Acquisition Regulations System... contractor (Spain). As prescribed in 229.402-70(d), use the following clause: Status of Contractor as a Director Contractor (Spain) (JUN 1997) (a) “Direct Contractor,” as used in this clause, means an individual...
-
Young, Roy M.; Adams, Charles L.
2010-01-01
The NASA In-Space Propulsion Technology (ISPT) Projects Office sponsored two separate, independent solar sail system design and development demonstration activities during 2002-2005. ATK Space Systems of Goleta, CA was the prime contractor for one development team and L' Garde, Inc. of Tustin, CA was the prime contractor for the other development team. The goal of these activities was to advance the technology readiness level (TRL) of solar sail propulsion from 3 towards 6 by the year 2006. Component and subsystem fabrication and testing were completed successfully, including the ground deployment of 10-meter and 20-meter demonstration hardware systems under vacuum conditions. The deployment and structural testing of the 20-meter solar sail systems was conducted in the 30 meter diameter Space Power Facility thermal-vacuum chamber at NASA Glenn Plum Brook in April though August, 2005. This paper will present the results of the TRL assessment following the solar sail technology development activities associated with the design, development, analysis and testing of the 20-meter system ground demonstrators.
-
Du, Bisheng; Liu, Qing; Li, Guiping
2017-11-08
Sustainable green technology innovation is essential in all the stages of the supply chain development. The members of the supply chain in each stage need to invest in sustainable green technology innovation research and development. However, whether the sustainable green technology innovation investments and profits for all the members are fairness concerned is a critical factor to motivate the supply chain members. Motivated by a real business investigation, in this study, a supply chain model with one supplier and one manufacturer is analyzed. We consider fairness concerns for the supplier and the manufacturer with sustainable green technology innovation development. We derive the optimal results in both with and without fairness concern. The results indicate that fairness concerns can promote and coordinate the supply chain members without advantage inequity averseness, to invest more on their sustainable green technology innovation development.
-
Accounting calculations problems with suppliers and contractors
Directory of Open Access Journals (Sweden)
Tikholaz I.A.
2016-12-01
Full Text Available in the article an order of accounting reflection of payments with suppliers and contractors are researched and ways of enhancement of accounting calculations process development with the purpose of management decisions optimization for their implementation are offered. Theoretical bases of intraeconomic control of settlings with suppliers and contractors are developed.
-
Development of nuclear technology transfer - Korea as a recipient
International Nuclear Information System (INIS)
Sung, N.C.
1988-01-01
Korea, as a recipient of nuclear technology transfer, has good experience of progressively building up its indigenous capability of nuclear technology through three stages of technology transfer, namely: technology transfer under the turn-key approach, component approach, and integrated technology transfer with a local prime contractor. Here, each stage of experience of technology transfer, with Korea as a recipient, is presented
-
Modular, Reconfigurable, High-Energy Technology Development
Carrington, Connie; Howell, Joe
2006-01-01
The Modular, Reconfigurable High-Energy (MRHE) Technology Demonstrator project was to have been a series of ground-based demonstrations to mature critical technologies needed for in-space assembly of a highpower high-voltage modular spacecraft in low Earth orbit, enabling the development of future modular solar-powered exploration cargo-transport vehicles and infrastructure. MRHE was a project in the High Energy Space Systems (HESS) Program, within NASA's Exploration Systems Research and Technology (ESR&T) Program. NASA participants included Marshall Space Flight Center (MSFC), the Jet Propulsion Laboratory (JPL), and Glenn Research Center (GRC). Contractor participants were the Boeing Phantom Works in Huntsville, AL, Lockheed Martin Advanced Technology Center in Palo Alto, CA, ENTECH, Inc. in Keller, TX, and the University of AL Huntsville (UAH). MRHE's technical objectives were to mature: (a) lightweight, efficient, high-voltage, radiation-resistant solar power generation (SPG) technologies; (b) innovative, lightweight, efficient thermal management systems; (c) efficient, 100kW-class, high-voltage power delivery systems from an SPG to an electric thruster system; (d) autonomous rendezvous and docking technology for in-space assembly of modular, reconfigurable spacecraft; (e) robotic assembly of modular space systems; and (f) modular, reconfigurable distributed avionics technologies. Maturation of these technologies was to be implemented through a series of increasingly-inclusive laboratory demonstrations that would have integrated and demonstrated two systems-of-systems: (a) the autonomous rendezvous and docking of modular spacecraft with deployable structures, robotic assembly, reconfiguration both during assembly and (b) the development and integration of an advanced thermal heat pipe and a high-voltage power delivery system with a representative lightweight high-voltage SPG array. In addition, an integrated simulation testbed would have been developed
-
2010-06-02
... OFFICE OF SCIENCE AND TECHNOLOGY POLICY National Nanotechnology Coordination Office, Nanoscale Science, Engineering and Technology Subcommittee, National Science and Technology Council, Committee on Technology; The National Nanotechnology Initiative (NNI) Strategic Planning Stakeholder Workshop: Public...
-
Global petroleum fiscal systems compared by contractor take
International Nuclear Information System (INIS)
Johnston, D.
1994-01-01
Petroleum fiscal terms in most countries are tougher than in the US, but these countries have more geological potential and still may be economically attractive. The market for exploration capital and technology is super competitive and getting more sophisticated. Governments are increasingly aware of the global market for exploration acreage or rehabilitation projects. For many oil companies, an important part of the negotiations is to secure terms acceptable to the potential partner. Knowing the market and what terms are realistic depends on a region's potential and other factors. Most countries developing petroleum fiscal systems are opting for the production sharing contract (PSC). This trend began in the 1960s. Now, nearly half of the countries with petroleum potential have a system based on the PSC. However, financial results could be the same in a royalty/tax arrangement. Economics depend primarily on division of profits or what is known as government/contractor take. The paper discusses contractor take, estimating take, Indonesian split, and take implications
-
Contractor firm strategies in delivering green project: A review
Powmya, Ayisha; Abidin, Nazirah Zainul; Azizi, Nurul Sakina Mokhtar
2017-10-01
Building green requires effort from various parties, from those who plan, design, manage and construct the building. Contractors are responsible for converting the design on paper into a real building and their role at the construction site support environmental sustainability by implementing responsible construction practices. Inefficient or inexperienced contractor in green construction project may find that delivering this type of project is not an easy task due to added requirement in design, stringent practices at site and the use of green technology and materials. Adopting suitable strategies at firm level will assist in preparatory process and readiness of delivering the green project. This paper reviews the strategies at firm level to deliver green construction project. From extensive literature review, it was discovered that there are six strategies to be adopted by the contractor. Understanding these strategies is expected to promote more contractors to be proactive in delivering green projects.
-
Waring, Scott M.
2010-01-01
As it has been shown that teachers of social studies content are less likely than teachers of other content areas to utilize technology in their classroom, this study focuses on one instructional technology coordinators' beliefs towards technology, instruction, and students and how these beliefs impacted how technology was utilized during a…
-
Institute of Scientific and Technical Information of China (English)
Deng Aimin; Tian Feng; Haasis H.D; Mao Lang; Cai Jia
2012-01-01
The coordinated development is the core of sustainable development and the hot issue of international research. Inland water transport (IWT) is an important part of the water resources exploiting system and comprehensive transport system under socio-economic context of river basin, and also the country' s sustainable development priorities to achieve resource-conserving and environment-friendly strategy. Based on the coordinated development content, the paper combined Germany' s successful development experience, explored the elements and problem of the coordinated development of IWT system of China' s national economic strategy and basin economy, water resourse system, comprehensive transport system, and system itself, and their countermeasures and suggestions, in order to facilitate rapid and coordinated development of China' s inland water transport.
-
Directory of Open Access Journals (Sweden)
Azlan Shah Ali
2010-12-01
Full Text Available Delay in construction projects is a situation where the project cannot be completed under the planned time. It is a common issue faced in the construction industry all over the world especially in developing countries. In the Malaysian construction industry, 17.3% of construction projects experience more than 3 months delay and some of them are abandoned. Hence, the study of factors contributing to delay is very important in order to reduce the number of projects that experience delay in project delivery. Three objectives of the research have been formulated, namely (1 to identify factors that contribute to delay in construction projects; (2 to analyse and rank the causes of delay rated by contractors; and (3 to study the effects of delay in construction projects. One hundred questionnaires were distributed during data collection stage and only 36 responses received. The respondents only consist of contractors and sub-contractors because the scope of the research focuses on contractors' perception. The data collected was analysed using SPSS software. Seven factors that contribute to delay were identified through literature review, namely contractors' financial difficulties, construction mistakes and defective work, labour shortage, coordination problems, shortage of tools and equipment, material shortage and poor site management. Of those factors, the three most important factors were found to be labour shortage, contractors' financial difficulties and construction mistakes and defective works. Besides project delay, the research shows that cost overrun and extension of time (EOT are the most common effects of delay in construction projects.
-
Technology development activities supporting tank waste remediation
International Nuclear Information System (INIS)
Bonner, W.F.; Beeman, G.H.
1994-06-01
This document summarizes work being conducted under the U.S. Department of Energy's Office of Technology Development (EM-50) in support of the Tank Waste Remediation System (TWRS) Program. The specific work activities are organized by the following categories: safety, characterization, retrieval, barriers, pretreatment, low-level waste, and high-level waste. In most cases, the activities presented here were identified as supporting tank remediation by EM-50 integrated program or integrated demonstration lead staff and the selections were further refined by contractor staff. Data sheets were prepared from DOE-HQ guidance to the field issued in September 1993. Activities were included if a significant portion of the work described provides technology potentially needed by TWRS; consequently, not all parts of each description necessarily support tank remediation
-
2011-09-19
... for Health Information Technology; Delegation of Authority Notice is hereby given that I have delegated to the National Coordinator for Health Information Technology (National Coordinator), or his or... information technology as it relates to health information and health promotion, preventive health services...
-
Co-ordinating Product Developing Activities
DEFF Research Database (Denmark)
Terkelsen, Søren Bendix
1996-01-01
The paper contains a presentation of research methods to be used in case studies in product development and a presentation on how to deal with Design Co-ordination according to litterature......The paper contains a presentation of research methods to be used in case studies in product development and a presentation on how to deal with Design Co-ordination according to litterature...
-
2010-04-07
... Coordinator for Health Information Technology, HHS. ACTION: Notice of change of location for meetings. This... Coordinator for Health Information Technology (ONC). The meeting will be open to the public. Name of Committee... health information technology infrastructure that permits the electronic exchange and use of health...
-
2010-06-15
... Technology; HIT Policy Committee's Privacy & Security Tiger Team Meeting; Notice of Meeting AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This... National Coordinator for Health Information Technology (ONC). The meeting will be open to the public. Name...
-
International Nuclear Information System (INIS)
Horky, F.
2000-01-01
In this paper the history of delivery of technological part for NPP V-1 Mochovce as well as of reconstruction and safety improvements by the Skoda Praha a.s. is presented. Primary contractor of technological part Skoda Praha together with its final suppliers proved ability to realize under hard conditions such a complicated work what was indisputedly Units 1 and 2 finishing. Company proved capability to conform itself flexibly in the course of work to requirements of customer for realization of safety measures which means that Units 1 and 2 fully satisfy international standards. By fulfilment of primary contractor of technology obligations and above all by takeover of complex responsibility for both Units putting in operation including responsibility for 'past' Skoda Praha put away one of basic problems which occurred in decision making to whom will be assigned construction finishing contract. These facts fully qualify Skoda Praha to be selected for possible Units 3 and 4 construction finishing as one of chief construction finishing participant
-
Working towards coordination of detector development in Europe
AIDA-2020 collaboration
2015-01-01
AIDA-2020, the largest EU-funded detector R&D project, kicked off at the beginning of June with a meeting at CERN (see here). The aim of the project is to advance detector technologies beyond current limits by sharing the high-quality infrastructure provided by 52 partners from 19 countries. Knowledge exchange between the various groups who are involved in developing innovative technological solutions for the next generation of detectors is the emphasis of the AIDA-2020 EU-funded project, which started on 1 May and will run for four years. AIDA-2020 is the successor to AIDA, a four-year EU-funded programme that concluded at the end of January 2015, which successfully coordinated a joint European effort in detector R&D and significantly improved various key European research infrastructures, enabling advanced detector development for the high-energy physics community. Highlights of AIDA’s networking activities were the development of generic toolkits for detector description ...
-
FY-95 technology catalog. Technology development for buried waste remediation
International Nuclear Information System (INIS)
1995-01-01
The US Department of Energy's (DOE) Buried Waste Integrated Demonstration (BWID) program, which is now part of the Landfill Stabilization Focus Area (LSFA), supports applied research, development, demonstration, and evaluation of a multitude of advanced technologies dealing with underground radioactive and hazardous waste remediation. These innovative technologies are being developed as part of integrated comprehensive remediation systems for the effective and efficient remediation of buried waste sites throughout the DOE complex. These efforts are identified and coordinated in support of Environmental Restoration (EM-40) and Waste Management (EM-30) needs and objectives. Sponsored by the DOE Office of Technology Development (EM-50), BWID and LSFA work with universities and private industry to develop technologies that are being transferred to the private sector for use nationally and internationally. This report contains the details of the purpose, logic, and methodology used to develop and demonstrate DOE buried waste remediation technologies. It also provides a catalog of technologies and capabilities with development status for potential users. Past FY-92 through FY-94 technology testing, field trials, and demonstrations are summarized. Continuing and new FY-95 technology demonstrations also are described
-
FY-95 technology catalog. Technology development for buried waste remediation
Energy Technology Data Exchange (ETDEWEB)
NONE
1995-10-01
The US Department of Energy`s (DOE) Buried Waste Integrated Demonstration (BWID) program, which is now part of the Landfill Stabilization Focus Area (LSFA), supports applied research, development, demonstration, and evaluation of a multitude of advanced technologies dealing with underground radioactive and hazardous waste remediation. These innovative technologies are being developed as part of integrated comprehensive remediation systems for the effective and efficient remediation of buried waste sites throughout the DOE complex. These efforts are identified and coordinated in support of Environmental Restoration (EM-40) and Waste Management (EM-30) needs and objectives. Sponsored by the DOE Office of Technology Development (EM-50), BWID and LSFA work with universities and private industry to develop technologies that are being transferred to the private sector for use nationally and internationally. This report contains the details of the purpose, logic, and methodology used to develop and demonstrate DOE buried waste remediation technologies. It also provides a catalog of technologies and capabilities with development status for potential users. Past FY-92 through FY-94 technology testing, field trials, and demonstrations are summarized. Continuing and new FY-95 technology demonstrations also are described.
-
Advantages of the production contractor concept
Energy Technology Data Exchange (ETDEWEB)
Gisvold, K.M. [Golar-Nor Offshore, Trondheim (Norway)
1994-12-31
This paper presents some thoughts on the Production Contractor concept. It starts with an attempt to define the prerequisites for such contractorship to exist and develop, going on to examine the considerations that the oil company and the contractor respectively have to go through, and finally trying to summarize what emerges as the advantages of production contracting. Examples are given to emphasize particular points
-
Advantages of the production contractor concept
International Nuclear Information System (INIS)
Gisvold, K.M.
1994-01-01
This paper presents some thoughts on the Production Contractor concept. It starts with an attempt to define the prerequisites for such contractorship to exist and develop, going on to examine the considerations that the oil company and the contractor respectively have to go through, and finally trying to summarize what emerges as the advantages of production contracting. Examples are given to emphasize particular points
-
Contractor-style tunnel cost estimating
International Nuclear Information System (INIS)
Scapuzzi, D.
1990-06-01
Keeping pace with recent advances in construction technology is a challenge for the cost estimating engineer. Using an estimating style that simulates the actual construction process and is similar in style to the contractor's estimate will give a realistic view of underground construction costs. For a contractor-style estimate, a mining method is chosen; labor crews, plant and equipment are selected, and advance rates are calculated for the various phases of work which are used to determine the length of time necessary to complete each phase of work. The durations are multiplied by the cost or labor and equipment per unit of time and, along with the costs for materials and supplies, combine to complete the estimate. Variations in advance rates, ground support, labor crew size, or other areas are more easily analyzed for their overall effect on the cost and schedule of a project. 14 figs
-
Eleventh annual report of radiation exposures for DOE and DOE contractor employees
International Nuclear Information System (INIS)
1978-01-01
In 1968, the US Atomic Energy Commission (AEC) established a program for reporting certain occupationa radiation exposure information to a central radiation records repository maintained at the Union Carbide Computing Technology Center, Oak Ridge, Tennessee. Annual summaries (WASH-1350-R1 through WASH-1350-R6) were reported for the years 1968-1973 and included data on AEC contracter employees as well as employees of companies in the private sector licensed by the AEC. In January 1975, the operational functions of the AEC, including the maintenance of records on the occupational radiation exposure on contractor employees, were transferred to the Energy Research and Development Administration (ERDA) and the AEC's regulatory functions, including the reporting of information on the occupational radiation exposure of licenses, were transferred to the Nuclear Regulatory Commission (NRC). Previous AEC licenses then reported to NRC while the contractors reported to ERDA. On October 1, 1977, the Department of Energy (DOE) was formed and assumed the responsibilities of ERDA. This report contains the 1978 radiation exposure data for DOE and DOE contractors
-
CSIR Research Space (South Africa)
Hauptfleisch, Dries
2007-05-01
Full Text Available , in the shortest possible time. An empowered model has thus been created to ensure the rapid development of emerging construction contractors. This model has a sound theoretical base, is supported by extensive filed research and has been introduced in practice...
-
From demand driven contractor selection towards value driven contractor selection
Walraven, A.R.; Vries, de B.
2009-01-01
The procurement of a construction contractor should consider more aspects than only cost or price. Taking value and price into account to select the ‘best value for money’ bid results in adopting a structured multicriteria approach. An alternative contractor selection method is presented, which
-
The importance of health information technology in care coordination and transitional care.
Cipriano, Pamela F; Bowles, Kathryn; Dailey, Maureen; Dykes, Patricia; Lamb, Gerri; Naylor, Mary
2013-01-01
Care coordination and transitional care services are strategically important for achieving the priorities of better care, better health, and reduced costs embodied in the National Strategy for Quality Improvement in Health Care (National Quality Strategy [NQS]). Some of the most vulnerable times in a person’s care occur with changes in condition as well as movement within and between settings of care. The American Academy of Nursing (AAN) believes it is essential to facilitate the coordination of care and transitions by using health information technology (HIT) to collect, share, and analyze data that communicate patient-centered information among patients, families, and care providers across communities. HIT makes information accessible, actionable, timely, customizable, and portable. Rapid access to information also creates efficiencies in care by eliminating redundancies and illuminating health history and prior care. The adoption of electronic health records (EHRs) and information systems can enable care coordination to be more effective but only when a number of essential elements are addressed to reflect the team-based nature of care coordination as well as a focus on the individual’s needs and preferences. To that end, the AAN offers a set of recommendations to guide the development of the infrastructure, standards, content, and measures for electronically enabled care coordination and transitions in care as well as research needed to build the evidence base to assess outcomes of the associated interventions.
-
Modelling Client Satisfaction Levels: The Impact of Contractor Performance
Directory of Open Access Journals (Sweden)
Robby Soetanto
2012-11-01
Full Text Available The performance of contractors is known to be a key determinant of client satisfaction.Here, using factor analysis, clients’ satisfaction is defined in several dimensions. Based onclients’ assessment of contractor performance, a number of satisfaction models developedusing the multiple regression (MR technique are presented. The models identify arange of variables encompassing contractor performance, project performance and respondent(i.e. client attributes as useful predictors of satisfaction levels. Contractor performanceattributes were found to be of utmost importance indicating that clientsatisfaction levels are mainly dependent on the performance of the contractor. Furthermore,findings suggest that subjectivity is to some extent prevalent in clients’ performanceassessment. The models demonstrate accurate and reliable predictive power as confirmedby validation tests. Contractors could use the models to help improve their performanceleading to more satisfied clients. This would also promote the development ofharmonious working relationships within the construction project coalition.
-
International Nuclear Information System (INIS)
Cheng Shouyu; Peng Minjun; Liu Xinkai; Zhao Qiang; Deng Xiangxin
2014-01-01
Nuclear power plant (NPP) is a multi-input and multi-output, no-linear and time-varying complex system. The conventional PID controller is usually used in NPP control system which is based on analog instrument. The system parameters are easy to overshoot and the response time is longer in the control mode of the conventional PID. In order to improve this condition, a new coordinated control strategy which is based on expert system and the original controllers in the digital instrument and control technology was presented. In order to verify and validate it, the proposed coordinated control technology was tested by the full-scope real-time simulation system. The results prove that using digital instrument and control technology to achieve coordinated controller is feasible, the coordinated controller can effectively improve the dynamic operating characteristics of the system, and the coordinated controller is superior to the conventional PID controller in control performance. (authors)
-
Nuclear Safety Co-Ordination within Oak Ridge Operations Facilities
Energy Technology Data Exchange (ETDEWEB)
Johnson, W. A.; Pryor, W. A. [Research and Development Division, United States Atomic Energy Commission, Oak Ridge, TN (United States)
1966-05-15
The Oak Ridge Operations Office of the USAEC has within its jurisdiction multiple contractors and facilities for research and for the production of fissile materials for the atomic energy programme. Among these facilities are gaseous diffusion plants for the production of {sup 235}U-enriched uranium hexafluoride, plants for the fabrication of special components and fuel for research and production reactors, and laboratories for pilot plant studies and basic research in nuclear technology. One research laboratory is also actively engaged in criticality experimental programmes and has been a major contributor of criticality data for safety applications. These diversified programmes include the processing, fabrication and transport of practically all forms and isotopic enrichments of uranium in quantities commensurate with both laboratory and volume production requirements. Consequently, adequate nuclear safety control with reasonable economy for operations of this magnitude demands not only co-ordination and liaison between contractor and USAEC staffs, but a continuing reappraisal of safety applications in light of the most advanced information. This report outlines the role of the Oak Ridge Operations Office in these pursuits and describes as examples some specific problems in which this office co-ordinated actions necessary for their resolution. Other examples are given of parametric and procedural applications in plant processes and fissile shipments emphasizing the use of recent experimental or calculated data. These examples involve the use of mass and geometric variables, neutron absorbers and moderation control. Departures from limits specified in existing nuclear safety guides are made to advantage in light of new data, special equipment design, contingencies and acceptable risks. (author)
-
Alberta Office of Coal Research and Technology: Annual review 1991-1992
Energy Technology Data Exchange (ETDEWEB)
1992-01-01
Annual report of the Office, established in 1984 to coordinate the government funding needed to identify, investigate and develop coal-related technologies. Background is given along with coal research strategy and research priorities. Short explanations are given of the various research projects being undertaken in mining, preparation and upgrading, combustion, liquefaction/co-processing, gasification, environment, enhanced oil recovery, the Western Canadian Low-Sulfur to Coal Program, and the Coal Research Contractor's Conference. Project expenditures are then listed by title and year, along with other statistics. A listing of the status of projects supported by the Office is also included, along with a list of publications currently available.
-
Directory of Open Access Journals (Sweden)
Mariëlle den Hengst
2001-01-01
Full Text Available It is widely believed that information and communication technology (ICT enables organizations to decrease costs and increase capabilities and thus enables to shape interorganizational coordination. This paper describes guidelines with which the impact of ICT on interorganizational coordination structures can be predicted. The framework used consists of three perspectives: interorganizational coordination structures, ICT, and aspects of goods and services for the processing of which coordination is required. Interorganizational coordination structures are defined and the impact of ICT on coordination structures is indicated. So far, ICT is considered to be a driving force. There are, however, other aspects that have an influencing impact on interorganizational coordination. Those aspects are described and by combining those with the possibilities of ICT, the guidelines are presented.
-
Constraints to 3R construction waste reduction among contractors in Penang
Ng, L. S.; Tan, L. W.; Seow, T. W.
2018-04-01
Rapid development of construction industry increases construction waste on landfill leading to shorter life span of the landfill. Waste reduction through Reduce, Reuse and Recycle (3R) practice has been encouraged in construction industry towards sustainable waste management since couple of decades ago. However, waste reduction through 3R is still at its infancy in construction industry in Penang, Malaysia. The aim of this paper is to determinate the constraints to construction waste reduction through 3R among contractors in Penang. The findings reported herein is based on feedbacks from 143 construction contractors of grade CIDB G7, G6 and G5 based in Penang, experts from Penang Local Authority, CIDB in Penang and its headquarters, National Solid Waste Management Department, and headquarters of Solid Waste and Public Cleansing Management Corporation (SWCorp). Based on interviews and questionnaire surveys, constraints identified are Time and cost, Contractor’s attitude and low participation, Lack of enforcement law and regulation, Lack of awareness and knowledge, Lack of coordination, and Lack of space. Awareness and knowledge, and enforcement law and regulation are the major barriers which influence others constraints as well. Therefore, these constraints should be emphasized by the authorities in order to improve the implementation of 3R construction waste reduction.
-
76 FR 39015 - Contractor Performance Information
2011-07-05
...] Contractor Performance Information AGENCY: Environmental Protection Agency (EPA), ACTION: Direct final rule... contractor performance information. EPA is issuing a final rule because the changes are procedural in nature... Institutes of Health's Contractor Performance System (CPS) to the Department of Defense's Contractor...
-
Contractor Selection in Saudi Arabia
M. A. Bajaber; M. A. Taha
2012-01-01
Contractor selection in Saudi Arabia is very important due to the large construction boom and the contractor role to get over construction risks. The need for investigating contractor selection is due to the following reasons; large number of defaulted or failed projects (18%), large number of disputes attributed to contractor during the project execution stage (almost twofold), the extension of the General Agreement on Tariffs and Trade (GATT) into construction industry, and finally the few ...
-
48 CFR 46.105 - Contractor responsibilities.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor... CONTRACT MANAGEMENT QUALITY ASSURANCE General 46.105 Contractor responsibilities. (a) The contractor is..., and furnishing such information to the Government as required. (b) The contractor may be required to...
-
Transfer of nuclear technology: A designer-contractor's perspective
International Nuclear Information System (INIS)
See Hoye, D.; Hedges, K.R.; Hink, A.D.
2000-01-01
The paper presents the successful Canadian experience in developing a nuclear power technology - CANDU - and exporting it. Consideration is paid to technology that has to be transferred, receiver country objectives and mechanisms and organizational framework. (author)
-
Construction Manager or General Contractor?
McKinley, John
1991-01-01
Unlike the general contractor approach, the construction management firm acts on behalf of the school district in school construction. Examines the development and nature of construction management, and cites its advantages and disadvantages. (MLF)
-
2010-12-10
... Technology; Health Information Technology; Request for Information Regarding the President's Council of... Information Technology To Improve Healthcare for Americans: The Path Forward'' AGENCY: Office of the National Coordinator for Health Information Technology (ONC), Department of Health and Human Services (HHS). ACTION...
-
2012-11-26
... Technology; Health Information Technology; HIT Policy Committee: Request for Comment Regarding the Stage 3 Definition of Meaningful Use of Electronic Health Records (EHRs) AGENCY: Health Information Technology (HIT) Policy Committee, Office of the National Coordinator for Health Information Technology (ONC), Department...
-
Gulf of Mexico Helicopter Offshore System Technologies Recommended Development Path
Koenke, Edmund J.; Williams, Larry; Calafa, Caesar
1999-01-01
The National Aeronautics and Space Administration (NASA) Advanced Air Transportation Technologies (AATT) project in cooperation with the Department of Transportation (DOT) Volpe National Transportation Systems Center (VNTSC) contracted with the System Resources Corporation (SRC) for the evaluation of the existing environment and the identification of user and service provider needs in the Gulf of Mexico low-altitude Offshore Sector. The results of this contractor activity are reported in the Gulf of Mexico Helicopter Offshore System Technologies Engineering Needs Assessment. A recommended system design and transition strategy was then developed to satisfy the identified needs within the constraints of the environment. This work, also performed under contract to NASA, is the subject of this report.
-
75 FR 60452 - Clean Water Act; Contractor Access to Confidential Business Information
2010-09-30
... ENVIRONMENTAL PROTECTION AGENCY [FRL-9208-9] Clean Water Act; Contractor Access to Confidential... electric industry to a new subcontractor of a contractor, Eastern Research Group (ERG). EPA previously... contractors and subcontractors to access information necessary to support EPA in the planning, development...
-
49 CFR 199.245 - Contractor employees.
2010-10-01
... 49 Transportation 3 2010-10-01 2010-10-01 false Contractor employees. 199.245 Section 199.245... Prevention Program § 199.245 Contractor employees. (a) With respect to those covered employees who are contractors or employed by a contractor, an operator may provide by contract that the alcohol testing...
-
Current information technology needs of small to medium sized apparel manufacturers and contractors
Energy Technology Data Exchange (ETDEWEB)
Wimple, C., LLNL
1998-04-01
This report documents recent efforts of the American Textile Partnership (AMTEX{sup TM}) Demand Activated Manufacturing Architecture (DAMA) Project to identify opportunities for cost effective enhanced information technology use by small to medium sized apparel manufacturers and contractors. Background on the AMTEX/DAMA project and objectives for the specific DAMA Small and Medium Enterprise (SME) effort are discussed in this section. The approach used to gather information about current opportunities or needs is outlined in Section 2 Approach, and relevant findings are identified and a brief analysis of the information gathered is presented in Section 3 Findings. Recommendations based on the analysis, are offered in Section 4 Recommendations, and plans are suggested for DAMA follow-on in Section 5 Future Plans. Trip reports for each of the companies visited are contained in Appendix E - Company Trip Reports. These individual reports contain the data upon which the analysis presented in Section 3 Findings is based.
-
National Radon Contractor Proficiency (RCP) Program. Proficiency report, June 1991
International Nuclear Information System (INIS)
1991-06-01
The primary objective of the U.S. Environmental Protection Agency's (EPA) efforts to address the indoor radon problem is to reduce radon levels in buildings throughout the country. Achieving the objective requires a nationwide supply of capable radon mitigation contractors. In the Indoor Radon Abatement Act of 1988, Congress authorized EPA to establish a program to evaluate radon mitigation contractors and to provide the information to the public in cooperation with the States. The Radon Contractor Proficiency (RCP) Program was developed to assist States, EPA Regions, local government officials, and the public in selecting contractors who have demonstrated their proficiency in reducing indoor radon levels. The program is managed by the EPA Office of Radiation Programs' Radon Division. Under the voluntary program, radon contractors demonstrate their proficiency by meeting specific Program requirements. Individual contractors who meet these requirements are then listed in periodic RCP Proficiency Reports
-
National Radon Contractor Proficiency (RCP) program. Proficiency report, September 1991
International Nuclear Information System (INIS)
1991-09-01
The primary objective of the U.S. Environmental Protection Agency's (EPA) efforts to address the indoor radon problem is to reduce radon levels in buildings throughout the country. Achieving this objective requires a nationwide supply of capable radon mitigation contractors. In the Indoor Radon Abatement Act of 1988, Congress authorized EPA to establish a program to evaluate radon mitigation contractors and to provide this information to the public in cooperation with the States. The Radon Contractor Proficiency (RCP) Program was developed to assist States, EPA Regions, local government officials, and the public in selecting contractors who have demonstrated their proficiency in reducing indoor radon levels. The program is managed by the EPA Office of Radiation Programs' Radon Division. Under this voluntary program, radon contractors demonstrate their proficiency by meeting specific Program requirements. Individual contractors who meet these requirements are then listed in the Report
-
National Radon Contractor Proficiency (RCP) Program. Proficiency report, January 1992
International Nuclear Information System (INIS)
1992-01-01
The primary objective of the U.S. Environmental Protection Agency's (EPA) efforts to address the indoor radon problem is to reduce radon levels in buildings throughout the country. Achieving the objective requires a nationwide supply of capable radon mitigation contractors. In the Indoor Radon Abatement Act of 1988, Congress authorized EPA to establish a program to evaluate radon mitigation contractors and to provide the information to the public in cooperation with the States. The Radon Contractor Proficiency (RCP) Program was developed to assist States, EPA Regions, local government officials, and the public in selecting contractors who have demonstrated their proficiency in reducing indoor radon levels. The program is managed by the EPA Office of Radiation Programs' Radon Division. Under the voluntary program, radon contractors demonstrate their proficiency by meeting specific Program requirements. Individual contractors who meet these requirements are then listed in the Report
-
49 CFR 199.115 - Contractor employees.
2010-10-01
... 49 Transportation 3 2010-10-01 2010-10-01 false Contractor employees. 199.115 Section 199.115... § 199.115 Contractor employees. With respect to those employees who are contractors or employed by a contractor, an operator may provide by contract that the drug testing, education, and training required by...
-
7 CFR 1726.27 - Contractor's bonds.
2010-01-01
... 7 Agriculture 11 2010-01-01 2010-01-01 false Contractor's bonds. 1726.27 Section 1726.27... AGRICULTURE ELECTRIC SYSTEM CONSTRUCTION POLICIES AND PROCEDURES General § 1726.27 Contractor's bonds. (a) RUS Form 168b, Contractor's Bond, shall be used when a contractor's bond is required by RUS Forms 200, 257...
-
2010-09-10
... NATIONAL SCIENCE FOUNDATION Networking and Information Technology Research and Development (NITRD... Information Technology Research and Development (NITRD). ACTION: Notice, request for public comment. FOR..., the National Coordination Office for Networking and Information Technology Research and Development...
-
48 CFR 47.207-5 - Contractor responsibilities.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor....207-5 Contractor responsibilities. Contractor responsibilities vary with the kinds of freight to be... furnished by the contractor. Otherwise, state that the contractor shall furnish clean and sound closed-type...
-
International Nuclear Information System (INIS)
Colburn, S.J.; Wilkenson, W.J.; Stitt, D.H.; Snipes, R.L.
1993-01-01
Oak Ridge National Laboratory (ORNL) investigated foreign technologies for the International Technology Exchange Division (ITED) that could be matched with possible hosts for demonstrations. At least one international technology demonstration at a Department of Defense (DoD) site in European country was planned. Efforts were made to coordinate cooperative technology demonstrations between the Department of Energy (DOE) and Taiwan
-
DOE Low-Level Waste Management Program
International Nuclear Information System (INIS)
Mezga, L.J.
1983-01-01
The Oak Ridge National Laboratory (ORNL) in its role as associate lead contractor of the DOE LLWMP has responsibility for the management of program-funded technology development activities. In this role with general guidance provided by DOE and the lead contractor (EG and G Idaho), the ORNL program office is charged with the responsibility to (1) develop program plans for the major technology areas, (2) recommend allocations for the program resources, (3) review the technology development tasks to ensure that program objectives are being met, and (4) to assist the lead contractor in coordinating the DOE LLWMP with other on-going US and foreign waste technology programs. Although the ORNL office generally assists the lead laboratory in management of the total program, our emphasis is on management of R and D for development of basic technology and to assess concepts for alternative systems of processing and disposal of LLW. Technical progress for each of the tasks of this program for FY 1982 is summarized
-
48 CFR 18.102 - Central contractor registration.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Central contractor... Central contractor registration. Contractors are not required to be registered in the Central Contractor.... (See 4.1102). However, contractors are required to register with CCR in order to gain access to the...
-
New developments in coordinate measuring machines for manufacturing industries
Directory of Open Access Journals (Sweden)
Hammad Mian S.
2014-01-01
Full Text Available There have been substantial improvements in measurement systems in order to meet fluctuating market demands. This rapid change and development in measurement technology has primarily been governed by demands of accuracy and precision from aerospace, automotive and other manufacturing industries. Coordinate measuring machines (CMMs available with different technologies and configurations has efficiently been fulfilling customer demands for more than a decade. Though, current CMMs can meet needs of rapid and increased demands of customers to a greater extent but still there is lot of scope for improvement and development in CMMs. The globalization of manufacturing has resulted in development of variety of complex products and miniaturization of mechanical components. The technology of micro/nano-scale 3D measurement is still a bottleneck for industries. Therefore, precise and accurate system which is flexible enough to deal with complexities of parts and micro & nano range products has to be investigated. In this paper, comprehensive review concerning CMMs with capabilities to measure micro/nano features has been presented. This work has also discussed different methods to estimate measurement uncertainty, as well as performance evaluation of CMMs. Moreover, novel concepts such as intelligent CMM, multi-sensor CMM, virtual CMM have been presented.
-
Transfer of radiation technology to developing countries
Markovic, Vitomir; Ridwan, Mohammad
1993-10-01
Transfer of technology is a complex process with many facets, options and constraints. While the concept is an important step in bringing industrialization process to agricultural based countries, it is clear, however, that a country will only benefit from a new technology if it addresses a real need, and if it can be absorbed and adapted to suit the existing cultural and technological base. International Atomic Energy Agency, as UN body, has a mandate to promote nuclear applicationsand assist Member States in transfer of technology for peaceful applications. This mandate has been pursued by many different mechanisms developed in the past years: technical assistance, coordinated research programmes, scientific and technical meetings, publications, etc. In all these activities the Agency is the organizer and initiator, but main contributions come from expert services from developed countries and, increasingly, from developing countries themselves. The technical cooperation among developing coutries more and more becomes part of different programmes. In particular, regional cooperation has been demonstrated as an effective instrument for transfer of technology from developed and among developing countries. Some examples of actual programmes are given.
-
[Coupling coordinated development of ecological-economic system in Loess Plateau].
Zhang, Qing-Feng; Wu, Fa-Qi; Wang, Li; Wang, Jian
2011-06-01
Based on system theory, a coupling coordinated development model of ecological-economic system in Loess Plateau was established, and the evaluation criteria and basic types of the coordinated development of the ecological-economic system were proposed. The county-level coupling coordinated development of the ecological-economic system was also discussed, based on the local characteristics. The interactions between the ecological and economic systems in Loess Plateau could be divided into four stages, i.e., seriously disordered development stage, mild-disordered development stage, low-level coordinated development stage, and high level well-coordinated development stage. At each stage, there existed a cyclic process of profit and loss-antagonist-running-dominant-synchronous development. The coupling development degree of the ecological-economic system in Loess Plateau was overall at a lower level, being about 62.7% of the counties at serious disorder, 30.1% of the counties at mild disorder, and 7.1% of the counties at low but coordinated level. The coupling development degree based on the model established in this study could better reflect the current social-economic and ecological environment situations, especially the status of coordination. To fully understand the coupling of ecological-economic system and to adopt appropriate development mode would be of significance to promote the county-level coordinated development in Loess Plateau.
-
Roohani, Behnam
2014-01-01
This study focused on exploring Illinois community college faculty development coordinators' perceptions about how they are implementing faculty technology professional development programs and providing technical support for part-time faculty in the Illinois community college systems. Also examined were part-time faculty perceptions of the degree…
-
Private Military and Security Contractors
DEFF Research Database (Denmark)
In Private Military and Security Contractors: Controlling the Corporate Warrior a multinational team of 16 scholars and a practitioner from political science, sociology, and law address a developing phenomenon: controlling the use of privatized force by states in international politics. Robust...
-
The Accelerating And Constraining Factors Of The Coordinated And Balanced Development Of Regions
Directory of Open Access Journals (Sweden)
Vladimir Stepanovich Bochko
2015-03-01
Full Text Available In the article, the hypothesis that the modern industrial-technological process causes complication of socio-economic space and conducts to amplification its integrity, which, in turn, causes the need for the coordinated and balanced development, is proved. The process of complication of economic space is revealed as a result of number growth of communications caused by creation of the enterprises and organizations, by the change of structure of manufacture and increase of an educational level of the population. The characteristics of a new quality of economic space are given. The factors of the coordinated and balanced development of territories are allocated. The contents «a commercial combination» is shown. The necessity of transition to the system innovation thinking in conditions of becoming complicated economic space is proved. The idea of use «rebalancing of the economy « as a new vision of equation in conditions of crisis situations is offered. The conclusion is made that the result of theoretical and practical searches should become formation vital stability of development of territories, which is provided with intelligence — technological and moral — ethical level of the population, living on it
-
48 CFR 1845.502 - Contractor responsibility.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor responsibility. 1845.502 Section 1845.502 Federal Acquisition Regulations System NATIONAL AERONAUTICS AND SPACE... Contractors 1845.502 Contractor responsibility. ...
-
Operator and contractor benefit from incentive contracts
International Nuclear Information System (INIS)
Brandon, B.
1991-01-01
This book reports that with incentive contracts, drilling and service contractors assume greater responsibility for operations. That helps them to align their goals more closely with those of the operator. This achieves a more equitable division of the risks. Many operators and contractors believe this is a more appropriate approach to contracting drilling services. As they assume manageable responsibility, each party also has opportunities for greater reward. Innovations in cooperation can create a win-win situation. In a win-win contract all parties benefit from the new relationships between operator, contractor, and service company. The win-win situation can only be achieved by allowing the contracting parties to become much more closely involved in drilling operations. This is the primary motivation behind development of more productive contracting strategies
-
2010-09-21
... NATIONAL SCIENCE FOUNDATION Networking and Information Technology Research and Development (NITRD...) for Networking and Information Technology Research and Development (NITRD). ACTION: Notice, request.... SUMMARY: With this notice, the National Coordination Office for Networking and Information Technology...
-
First year evaluation of EPA's radon contractor proficiency (RCP) program
International Nuclear Information System (INIS)
Salmon, G.L.
1990-01-01
This paper reports that the Environmental Protection Agency (EPA) has developed a voluntary program to evaluate radon reduction contractors and provide this information to the public, as part of activities mandated by the Indoor Radon Abatement Act (IRAA) of 1988. The Radon Contractor Proficiency Program consists of several elements that collectively help to ensure the proficiency of radon mitigators and give the public greater confidence in their capability. Contractors who participate in the program must pass a written examination, adhere to mitigation guidelines, keep records of work, meet continuing education requirements and pass a re-examination every two years. Upon meeting the program's requirements, mitigators are listed in EPA's National RCP Proficiency Report. The first Report released on May 15, 1990 listed 636 contractors. The second Report, to be release in August, will list 895 contractors, representing an increase of 40 per cent
-
The fourth UNDP/RCA/IAEA/meeting of national co-ordinators for radiation technology. Report
International Nuclear Information System (INIS)
1996-01-01
The objectives of the Meeting were to provide information for the Terminal Report of the joint UNDP/RCA/IAEA project RAS/92/073 and to look into future activities under the Radiation Technology project. The main achievements of this Meeting are: The Meeting reviewed the implementation of all radiation technology sub-projects and agreed that all of them were successful but not yet equally developed among RCA Member States. The Meeting recommended to have three projects carried out in the form of Co-ordinated Research Programs and requested the IAEA to find new ways to implement the organized in RCA Member States to carry these CRPs out. Figs, tabs
-
48 CFR 1609.471 - Contractor certification.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor certification... EMPLOYEES HEALTH BENEFITS ACQUISITION REGULATION ACQUISITION PLANNING CONTRACTOR QUALIFICATIONS Debarment, Suspension, and Ineligibility 1609.471 Contractor certification. All FEHBP carriers and applicant carriers...
-
48 CFR 1602.170-4 - Contractor.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor. 1602.170-4 Section 1602.170-4 Federal Acquisition Regulations System OFFICE OF PERSONNEL MANAGEMENT FEDERAL EMPLOYEES... 1602.170-4 Contractor. Contractor means carrier. ...
-
International Nuclear Information System (INIS)
Ebadian, M.A.
1998-01-01
In 1989, the US Department of Energy (DOE) established the Office of Environmental Management (EM) and delegated to the office the responsibility of cleaning up the US nuclear weapons complex. EM's mission has three primary activities: (1) to assess, remediate, and monitor contaminated sites and facilities; (2) to store, treat, and dispose of wastes from past and current operations; and (3) to develop and implement innovative technologies for environmental remediation. To this end, EM has established domestic and international cooperative technology development programs, including one with the Republic of Argentina. Cooperating with Argentine scientific institutes and industry meets US cleanup objectives by: (1) identifying and accessing Argentine EM-related technologies, thereby leveraging investments and providing cost-savings; (2) improving access to technical information, scientific expertise, and technologies applicable to EM needs; and (3) fostering the development of innovative environmental technologies by increasing US private sector opportunities in Argentina in EM-related areas. Florida International University's Hemispheric Center for Environmental Technology (FIU-HCET) serves as DOE-OST's primary technology transfer agent. FIU-HCET acts as the coordinating and managing body for the Department of Energy (DOE)-Argentina National Atomic Energy Commission (CNEA) Arrangement. Activities include implementing standard operating procedures, tracking various technical projects, hosting visiting scientists, advising DOE of potential joint projects based on previous studies, and demonstrating/transferring desired technology. HCET hosts and directs the annual Joint Coordinating Committee for Radioactive and Mixed Waste Management meeting between the DOE and CNEA representatives. Additionally, HCET is evaluating the possibility of establishing similar arrangements with other Latin American countries
-
Dry rod consolidation technology development
International Nuclear Information System (INIS)
Rasmussen, T.L.; Schoonen, D.H.; Feldman, E.M.; Fisher, M.W.
1987-01-01
The Department of Energy's (DOE) Office of Civilian Radioactive Waste Management (OCRWM) is funding a program to consolidate commercial spent fuel for testing in dry storage casks and to develop technology that will be fed into other OCRWM programs, e.g., Prototypical Consolidation Demonstration Program (PCDP). The program is being conducted at the Idaho National Engineering Laboratory (INEL) by the INEL Operating Contractor EG and G Idaho, Inc. Hardware and software have been designed and fabricated for installation in a hot cell adjacent to the Test Area North (TAN) Hot Shop Facility. This equipment is used to perform dry consolidation of commercial spent fuel from the Virginia Power (VP) Cooperative Agreement Spent Fuel Storage Cask (SFSC) Demonstration Program and assemblies that had previously been stored at the Engine Maintenance and Disassembly (EMAD) facility in Nevada. Consolidation is accomplished by individual, horizontal rod pulling. A computerized semiautomatic control system with operator involvement is utilized to conduct consolidation operations. During consolidation operations, data is taken to characterize this technology. Still photo, video tape, and other documentation will be generated to make developed information available to interested parties. Cold checkout of the hardware and software was completed in September of 1986. Following installation in the hot cell, consolidation operations begins in May 1987. Resulting consolidated fuel will be utilized in the VP Cooperative Agreement SFSC Program
-
48 CFR 752.7013 - Contractor-mission relationships.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor-mission....7013 Contractor-mission relationships. For use in all USAID contracts involving performance overseas.... Contractor-Mission Relationships (OCT 1989) (a) The Contractor acknowledges that this contract is an...
-
30 CFR 45.4 - Independent contractor register.
2010-07-01
... 30 Mineral Resources 1 2010-07-01 2010-07-01 false Independent contractor register. 45.4 Section... ADMINISTRATIVE REQUIREMENTS INDEPENDENT CONTRACTORS § 45.4 Independent contractor register. (a) Each independent contractor shall provide the production-operator in writing the following information: (1) The independent...
-
48 CFR 852.237-70 - Contractor responsibilities.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor....237-70 Contractor responsibilities. As prescribed in 837.110, insert the following clause: Contractor Responsibilities (APR 1984) The contractor shall obtain all necessary licenses and/or permits required to perform...
-
2010-10-01
... affiliates, if any, within the corporate structure of which the Contractor is a party and includes the right... benefits are, to the extent permitted by law or Government regulations, available to the public on... rights—(1) Assignment to the Government. Except to the extent that rights are retained by the Contractor...
-
48 CFR 1509.170-8 - Contractor Performance Report.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor Performance... AGENCY ACQUISITION PLANNING CONTRACTOR QUALIFICATIONS Contractor Performance Evaluations 1509.170-8 Contractor Performance Report. (a) Contractor Performance Reports (interim and final) must be prepared...
-
International Nuclear Information System (INIS)
1994-01-01
In December 1992, western governors and four federal agencies established a Federal Advisory Committee to Develop On-site Innovative Technologies for Environmental Restoration and Waste Management (the DOIT Committee). The purpose of the Committee is to advise the federal government on ways to improve waste cleanup technology development and the cleanup of federal sites in the West. The Committee directed in January 1993 that information be collected from a wide range of potential stakeholders and that innovative technology candidate projects be identified, organized, set in motion, and evaluated to test new partnerships, regulatory approaches, and technologies which will lead to improve site cleanup. Five working groups were organized, one to develop broad project selection and evaluation criteria and four to focus on specific contaminant problems. A Coordinating Group comprised of working group spokesmen and federal and state representatives, was set up to plan and organize the routine functioning of these working groups. The working groups were charged with defining particular contaminant problems; identifying shortcomings in technology development, stakeholder involvement, regulatory review, and commercialization which impede the resolution of these problems; and identifying candidate sites or technologies which could serve as regional innovative demonstration projects to test new approaches to overcome the shortcomings. This report from the Coordinating Group to the DOIT Committee highlights the key findings and opportunities uncovered by these fact-finding working groups. It provides a basis from which recommendations from the DOIT Committee to the federal government can be made. It also includes observations from two public roundtables, one on commercialization and another on regulatory and institutional barriers impeding technology development and cleanup
-
48 CFR 52.241-5 - Contractor's Facilities.
2010-10-01
... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Contractor's Facilities....241-5 Contractor's Facilities. As prescribed in 41.501(c)(4), insert a clause substantially the same as the following: Contractor's Facilities (FEB 1995) (a) The Contractor, at its expense, unless...
-
48 CFR 52.247-28 - Contractor's Invoices.
2010-10-01
... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Contractor's Invoices. 52....247-28 Contractor's Invoices. As prescribed in 47.207-9(c), insert the following clause in... services: Contractor's Invoices (APR 1984) The Contractor shall submit itemized invoices as instructed by...
-
14 CFR 1245.108 - License to contractor.
2010-01-01
... 14 Aeronautics and Space 5 2010-01-01 2010-01-01 false License to contractor. 1245.108 Section... INTELLECTUAL PROPERTY RIGHTS Patent Waiver Regulations § 1245.108 License to contractor. (a) Each contractor.... The license extends to the contractor's domestic subsidiaries and affiliates, if any, within the...
-
48 CFR 725.703 - Contractor employees.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor employees. 725... SOCIOECONOMIC PROGRAMS FOREIGN ACQUISITION Source, Origin, and Nationality 725.703 Contractor employees. (a... on employees or consultants of either contractors or subcontractors providing services under an USAID...
-
48 CFR 33.207 - Contractor certification.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor certification... CONTRACTING REQUIREMENTS PROTESTS, DISPUTES, AND APPEALS Disputes and Appeals 33.207 Contractor certification. (a) Contractors shall provide the certification specified in paragraph (c) of this section when...
-
Optimal Contractor Selection in Construction Industry: The Fuzzy Way
Krishna Rao, M. V.; Kumar, V. S. S.; Rathish Kumar, P.
2018-02-01
A purely price-based approach to contractor selection has been identified as the root cause for many serious project delivery problems. Therefore, the capability of the contractor to execute the project should be evaluated using a multiple set of selection criteria including reputation, past performance, performance potential, financial soundness and other project specific criteria. An industry-wide questionnaire survey was conducted with the objective of identifying the important criteria for adoption in the selection process. In this work, a fuzzy set based model was developed for contractor prequalification/evaluation, by using effective criteria obtained from the percept of construction professionals, taking subjective judgments of decision makers also into consideration. A case study consisting of four alternatives (contractors in the present case) solicited from a public works department of Pondicherry in India, is used to illustrate the effectiveness of the proposed approach. The final selection of contractor is made based on the integrated score or Overall Evaluation Score of the decision alternative in prequalification as well as bid evaluation stages.
-
Breakdowns in Coordination Between Air Traffic Controllers
Bearman, Chris; Orasanu, Judith; Miller, Ronald C.
2011-01-01
This talk outlines the complexity of coordination in air traffic control, introduces the NextGen technologies, identifies common causes for coordination breakdowns in air traffic control and examines whether these causes are likely to be reduced with the introduction of NextGen technologies. While some of the common causes of breakdowns will be reduced in a NextGen environment this conclusion should be drawn carefully given the current stage of development of the technologies and the observation that new technologies often shift problems rather than reduce them.
-
International Nuclear Information System (INIS)
Honeyman, J.O.
1998-01-01
This Management Assessment of Tank Waste Remediation System (TWRS) Contractor Readiness to Proceed With Phase 1B Privatization documents the processes used to determine readiness to proceed with tank waste treatment technologies from private industry, now known as TWRS privatization. An overall systems approach was applied to develop action plans to support the retrieval and disposal mission of the TWRS Project. The systems and infrastructure required to support the mission are known. Required systems are either in place or plans have been developed to ensure they exist when needed. Since October 1996 a robust system engineering approach to establishing integrated Technical Baselines, work breakdown structures, tank farms organizational structure and configurations, work scope, and costs has become part of the culture within the TWRS Project. An analysis of the programmatic, management, and technical activities necessary to declare readiness to proceed with execution of the mission demonstrates that the system, personnel, and hardware will be on-line and ready to support the private contractors. The systems approach included defining the retrieval and disposal mission requirements and evaluating the readiness of the Project Hanford Management Contract (PHMC) team to support initiation of waste processing by the private contractors in June 2002 and to receive immobilized waste shortly thereafter. The Phase 1 feed delivery requirements from the private contractor Requests for Proposal were reviewed. Transfer piping routes were mapped, existing systems were evaluated, and upgrade requirements were defined
-
48 CFR 1845.502-70 - Contractor-acquired property.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor-acquired... Possession of Contractors 1845.502-70 Contractor-acquired property. All contractor-acquired property must be... contractor-acquired. (2) Submission of DD Form 1419, DOD Industrial Plant Requisition, or equivalent format...
-
Status of NASA's Advanced Radioisotope Power Conversion Technology Research and Development
Wong, Wayne A.; Anderson, David J.; Tuttle, Karen L.; Tew, Roy C.
2006-01-01
NASA s Advanced Radioisotope Power Systems (RPS) development program is funding the advancement of next generation power conversion technologies that will enable future missions that have requirements that can not be met by either the ubiquitous photovoltaic systems or by current Radioisotope Power Systems (RPS). Requirements of advanced radioisotope power systems include high efficiency and high specific power (watts/kilogram) in order to meet mission requirements with less radioisotope fuel and lower mass. Other Advanced RPS development goals include long-life, reliability, and scalability so that these systems can meet requirements for a variety of future space applications including continual operation surface missions, outer-planetary missions, and solar probe. This paper provides an update on the Radioisotope Power Conversion Technology Project which awarded ten Phase I contracts for research and development of a variety of power conversion technologies consisting of Brayton, Stirling, thermoelectrics, and thermophotovoltaics. Three of the contracts continue during the current Phase II in the areas of thermoelectric and Stirling power conversion. The accomplishments to date of the contractors, project plans, and status will be summarized.
-
Photovoltaic concentrator technology development project. Sixth project integration meeting
Energy Technology Data Exchange (ETDEWEB)
None
1980-10-01
Thirty-three abstracts and short papers are presented which describe the current status of research, development, and demonstration of concentrator solar cell technology. Solar concentrators discussed include the parabolic trough, linear focus Fresnel lens, point focus Fresnel lens, and the parabolic dish. Solar cells studied include silicon, GaAs, and AlGaAs. Research on multiple junction cells, combined photovoltaic/thermal collectors, back contact solar cells, and beam splitter modules is described. Concentrator solar cell demonstration programs are reported. Contractor status summaries are given for 33 US DOE concentrator solar cell contracts; a description of the project, project status, and key results to date is included. (WHK)
-
48 CFR 1252.242-71 - Contractor testimony.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor testimony. 1252... Contractor testimony. As prescribed in (TAR) 48 CFR 1242.7000(b), insert the following clause: Contractor Testimony (OCT 1994) All requests for the testimony of the Contractor or its employees, and any intention to...
-
Energy Technology Data Exchange (ETDEWEB)
NONE
2006-07-01
The story about oil extraction from the Troll petroleum reservoirs in the Troll petroleum project, is the story about a very large petroleum reservoir, but very difficult to access. A project that despite vast, technological challenges created a foundation for one of the genuine pioneer projects on Norwegian continental shelf. The social impact of Troll Oil is substantial. The project has generated big, economic profits, strengthened Norwegian and international contractor companies, and contributed to important technological improvements in both drilling- and completion technology, as well as sub sea production. Many of the technological solutions that have been developed in relation to the Troll Oil project have been further developed and used in new fields both in Norway and in other countries. Troll Oil is an excellent example that much of the added value on Norwegian shelf is inextricably connected to technology and competency developments. The project has become a very important point of reference for Norwegian petroleum industry in international markets, and has been an essential factor in the efforts to demonstrate the possibilities of enhanced oil recovery. The success for Troll Oil has contributed to the authorities - and the oil companies - constantly setting higher extraction goals.
-
40 CFR 35.6600 - Contractor claims.
2010-07-01
... 40 Protection of Environment 1 2010-07-01 2010-07-01 false Contractor claims. 35.6600 Section 35... Actions Procurement Requirements Under A Cooperative Agreement § 35.6600 Contractor claims. (a) General... prepared by the contractor to support a claim against the recipient; and (4) The award official determines...
-
International Nuclear Information System (INIS)
1999-06-01
The Joint FAO/IAEA Division of Nuclear Techniques in Food and Agriculture through its Co-ordinated Research Projects (CRPs), has been assisting national agricultural research systems in Member States to develop and apply nuclear and related techniques for improving livestock productivity. The programmes have focused on animal nutrition, animal reproduction and more recently on animal nutrition/reproduction interactions with emphasis on smallholder farming systems. The measurement of microbial protein supply to ruminant livestock has been an important area of research in ruminant nutrition. An estimate of microbial protein contribution to the intestinal protein flow is important for estimating the protein requirement of ruminant animals. Understanding the process of microbial protein synthesis has been difficult however, and due to the lack of simple and accurate methods for measuring microbial protein production in vivo, the methods used are based on complex microbial markers which require surgically prepared animals. As a result of a consultants meeting held in May 1995 to advise the Joint FAO/IAEA Division on the feasibility of using nuclear and related techniques for the development and validation of techniques for measuring microbial protein supply in ruminant animals, an FAO/IAEA Co-ordinated Research Project on Development, Standardization and Validation of Nuclear Based Technologies for Measuring Microbial Protein Supply in Ruminant Livestock for Improving Productivity was initiated in 1996, with a view to validating and adapting this technology for use in developing countries. To assist scientists participating in the CRP, a laboratory manual containing experimental protocols and methodologies for standardization and validation of the urine purine derivative technique and the development of models to suit local conditions, was published as IAEA-TECDOC-945. The present publication contains the final reports from participants in Phase 1 of the project
-
Energy Technology Data Exchange (ETDEWEB)
NONE
1999-06-01
The Joint FAO/IAEA Division of Nuclear Techniques in Food and Agriculture through its Co-ordinated Research Projects (CRPs), has been assisting national agricultural research systems in Member States to develop and apply nuclear and related techniques for improving livestock productivity. The programmes have focused on animal nutrition, animal reproduction and more recently on animal nutrition/reproduction interactions with emphasis on smallholder farming systems. The measurement of microbial protein supply to ruminant livestock has been an important area of research in ruminant nutrition. An estimate of microbial protein contribution to the intestinal protein flow is important for estimating the protein requirement of ruminant animals. Understanding the process of microbial protein synthesis has been difficult however, and due to the lack of simple and accurate methods for measuring microbial protein production in vivo, the methods used are based on complex microbial markers which require surgically prepared animals. As a result of a consultants meeting held in May 1995 to advise the Joint FAO/IAEA Division on the feasibility of using nuclear and related techniques for the development and validation of techniques for measuring microbial protein supply in ruminant animals, an FAO/IAEA Co-ordinated Research Project on Development, Standardization and Validation of Nuclear Based Technologies for Measuring Microbial Protein Supply in Ruminant Livestock for Improving Productivity was initiated in 1996, with a view to validating and adapting this technology for use in developing countries. To assist scientists participating in the CRP, a laboratory manual containing experimental protocols and methodologies for standardization and validation of the urine purine derivative technique and the development of models to suit local conditions, was published as IAEA-TECDOC-945. The present publication contains the final reports from participants in Phase 1 of the project
-
2010-07-01
..., prior to such employee's engagement in any activity enumerated in section 3(6) of the Act. A farm labor... farm labor contractor employee. 500.41 Section 500.41 Labor Regulations Relating to Labor (Continued... PROTECTION Registration of Farm Labor Contractors and Employees of Farm Labor Contractors Engaged in Farm...
-
Repository Technology Program: Technical progress report for the period May 29, 1986--June 30, 1987
International Nuclear Information System (INIS)
1988-10-01
This document reports the progress made in the 13-month period from May 29, 1986--June 30, 1987, on the development of a second geologic repository in rocks other than those being considered for a first repository. Subsequent periods will be covered in reports to be issued on a semiannual basis. The reporting elements are arranged by the work breakdown structure so that related studies are presented together. The studies are reported by the Office of Waste Technology Development (OWTD), a prime contractor of the US. Department of Energy (DOE) Repository Technology Program (RTP) Office in the Repository Technology and Transportation Division (RTTD) of the Office of Geologic Repositories (OGR). The studies include work by other DOE prime contractors and by contractors to the OWTD. 50 refs
-
Energy Technology Data Exchange (ETDEWEB)
Baechler, Michael C. [Pacific Northwest National Lab. (PNNL), Richland, WA (United States); Adams, K. T. [Pacific Northwest National Lab. (PNNL), Richland, WA (United States); Hefty, M. G. [Pacific Northwest National Lab. (PNNL), Richland, WA (United States); Gilbride, T. L. [Pacific Northwest National Lab. (PNNL), Richland, WA (United States); Love, Pat M. [Oak Ridge National Lab. (ORNL), Oak Ridge, TN (United States)
2012-05-01
This guide will help contractors and homeowners identify ways to make their homes more comfortable, more energy efficient, and healthier to live in. It also identifies the steps to take, with the help of a qualified home performance contractor, to increase their home’s insulation, ensure healthy levels of ventilation, and prevent moisture problems. Contractors can use this document to explain the value of these insulation measures to their customers. The references in this document provide further explanation of insulation techniques and technologies.
-
2011-01-10
... Technology; HIT Standards Committee Advisory Meeting; Notice of Meeting AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of Meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Standards...
-
2010-02-23
... Technology; HIT Policy Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2011-01-10
... Technology; HIT Policy Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-02-26
... Technology; HIT Standards Committee Advisory Meeting; Notice of Meeting AGENCY: Office of the National Coordinator for Health Information Technology, HHS ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Standards...
-
2010-01-05
... Technology; HIT Policy Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-08-23
... Technology; HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-03-17
... Technology; HIT Policy Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of Meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-10-25
... Technology; HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-11-19
... Technology; HIT Policy Committee Advisory Meeting; Notice of Meeting AGENCY: Office of the National Coordinator for Health Information Technology, HHS ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Policy Committee...
-
2010-04-26
... Technology; HIT Policy Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-11-19
... Technology; HIT Standards Committee Advisory Meeting; Notice of Meeting AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Standards...
-
2010-05-27
... Technology: HIT Standards Committee Advisory Meeting; Notice of Meeting AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Standards...
-
2010-09-17
... Technology; HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-06-28
... Technology; HIT Policy Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-02-23
... Technology; HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2011-01-25
... Technology; HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-03-17
... Technology; HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-06-28
... Technology; HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2011-01-10
... Technology HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-11-19
... Technology; HIT; Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-05-27
... Technology; HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-01-05
... Technology; HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-01-25
... Technology; HIT Standards Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2010-11-19
... Technology; HIT Policy Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
2011-01-25
... Technology; HIT Standards Committee Advisory Meeting; Notice of Meeting AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meeting. This notice announces a... Information Technology (ONC). The meeting will be open to the public. Name of Committee: HIT Standards...
-
2010-06-16
... Technology; HIT Policy Committee's Workgroup Meetings; Notice of Meetings AGENCY: Office of the National Coordinator for Health Information Technology, HHS. ACTION: Notice of meetings. This notice announces... for Health Information Technology (ONC). The meetings will be open to the public via dial-in access...
-
Golovashchenko, V. A.; Kolomiyets, S. V.
As a result of dynamic evolution of IT industry and astronomical research in the XXI century, which have resulted in obtaining large and complex data sets known as Big Data (e.g. data from the European Space Agency missions, such as GAIA mission, etc.), as well as due to rapid development of computer technologies, astronomy and computer science have become closely linked to each other. In the XXI century, Information technology has become an essential part of understanding the world around. This paper presents a solution to the problem of meteor data representation in the second equatorial coordinate (RA-Dec) system using Information Technology. Such a visualisation solution is needed to analyse the results of experiments based on the radar observations conducted in 1972-1978 (stage 1 - the data obtained in 1972 comprise 10,247 meteor orbits), which have been accumulated and stored in the Meteor Database of the Kharkiv National University of Radio Electronics (KNURE). A sample set of data with their characteristics and details about their delivery has been presented by (Kashcheyev & Tkachuk, 1980). An electronic calculator application was developed by employing the model of data visualisation in the form of celestial hemispheres using the object-oriented programming language C#.
-
48 CFR 970.4402 - Contractor purchasing system.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor purchasing... SUPPLEMENTARY REGULATIONS DOE MANAGEMENT AND OPERATING CONTRACTS Management and Operating Contractor Purchasing 970.4402 Contractor purchasing system. ...
-
National Research Council Canada - National Science Library
Gorodetski, Vladimir
2001-01-01
The contractor will research and further develop the technology supporting an agent-based architecture for an information security system and a formal framework to specify a model of distributed knowledge...
-
International Nuclear Information System (INIS)
2013-04-01
Through its coordinated research activities, the IAEA promotes the development and application of nuclear technologies in Member States. The scientific and technical knowledge required for the construction and operation of large nuclear fusion research facilities, including ITER and the Laser Megajoule in France, and the Z machine and the National Ignition Facility in the United States of America, necessitates several accompanying research and development programmes in physics and technology. This is particularly true in the areas of materials science and fusion technology. Hence, the long standing IAEA effort to conduct coordinated research projects (CRPs) in these areas is aimed at: (i) the development of appropriate technical tools to investigate the issue of materials damage and degradation in a fusion plasma environment; and (ii) the emergence of a knowledge based understanding of the various processes underlying materials damage and degradation, thereby leading to the identification of suitable candidate materials fulfilling the stringent requirements of a fusion environment in any next step facility. Dense magnetized plasma (DMP) devices serve as a first test bench for testing of fusion relevant plasma facing materials, diagnostic development and calibration, technologies and scaling to conceptual principles of larger devices while sophisticated testing facilities such as the International Fusion Materials Irradiation Facility (IFMIF) are being designed. The CRP on Integrated Approach to Dense Magnetized Plasmas Applications in Nuclear Fusion Technology described herein was initiated in 2007 with the participation of 12 research institutions in 8 Member States and was concluded in 2011. It was designed with specific research objectives falling into two main categories: support to mainstream fusion research and development of DMP technology. This publication is a compilation of the individual reports submitted by the 12 CRP participants. These reports discuss
-
Dry rod consolidation technology development
International Nuclear Information System (INIS)
Rasmussen, T.L.; Schoonen, D.H.; Fisher, M.W.
1986-01-01
The Department of Energy's (DOE) Office of Civilian Radioactive Waste Management (OCRWM) is funding a Program to consolidate commercial spent fuel for testing in dry storage casks and to develop technology that will be fed into other OCRWM Programs, e.g., Prototypical Consolidation Demonstration Program. The Program is being conducted at the Idaho National Engineering Laboratory (INEL) by the Operating Contractor, EGandG Idaho, Inc. Hardware and software have been designed and fabricated for installation in a hot cell adjacent to the Test Area North (TAN) Hot Shop Facility. This equipment will be used to perform dry consolidation of commercial spent fuel from the Virginia Power (VP) Cooperative Agreement Spent Fuel Storage Cask (SPSC) Demonstration Program and assemblies that had previously been stored at the Engine Maintenance and Disassembly (EMAD) facility in Nevada. Consolidation will be accomplished by individual, horizontal rod pulling. A computerized semi-automatic control system with operator involvement will be utilized to conduct consolidation operations. Special features have been incorporated in the design to allow crud collection and measurement of rod pulling forces. During consolidation operations, data will be taken to characterize this technology. Still photo, video tape, and other documentation will be generated to make developed information available to interested parties. Cold checkout of the hardware and software will complete in September of 1986. Following installation in the hot cell, consolidation operations will begin in January 1987. Resulting consolidated fuel will be utilized in the VP Cooperative Agreement SFSC Program
-
Energy Technology Data Exchange (ETDEWEB)
Burdick, A.
2011-10-01
This report outlines findings resulting from a U.S. Department of Energy Building America expert meeting to determine how HVAC companies can transition from a traditional contractor status to a service provider for whole house energy upgrade contracting. IBACOS has embarked upon a research effort under the Building America Program to understand business impacts and change management strategies for HVAC companies. HVAC companies can implement these strategies in order to quickly transition from a 'traditional' heating and cooling contractor to a service provider for whole house energy upgrade contracting. Due to HVAC service contracts, which allow repeat interaction with homeowners, HVAC companies are ideally positioned in the marketplace to resolve homeowner comfort issues through whole house energy upgrades. There are essentially two primary ways to define the routes of transition for an HVAC contractor taking on whole house performance contracting: (1) Sub-contracting out the shell repair/upgrade work; and (2) Integrating the shell repair/upgrade work into their existing business. IBACOS held an Expert Meeting on the topic of Transitioning Traditional HVAC Contractors to Whole House Performance Contractors on March 29, 2011 in San Francisco, CA. The major objectives of the meeting were to: Review and validate the general business models for traditional HVAC companies and whole house energy upgrade companies Review preliminary findings on the differences between the structure of traditional HVAC Companies and whole house energy upgrade companies Seek industry input on how to structure information so it is relevant and useful for traditional HVAC contractors who are transitioning to becoming whole house energy upgrade contractors Seven industry experts identified by IBACOS participated in the session along with one representative from the National Renewable Energy Laboratory (NREL). The objective of the meeting was to validate the general operational
-
Directory of Open Access Journals (Sweden)
I. O. Zharinov
2015-05-01
Full Text Available Subject of research. The problem of software-based compensation of technological variation in chromaticity coordinates of liquid crystal panels is considered. A method of software-based compensation of technological variation in chromaticity coordinates is proposed. The method provides the color reproduction characteristics of the series-produced samples on-board indication equipment corresponding to the sample equipment, which is taken as the standard. Method. Mathematical calculation of the profile is performed for the given model of the liquid crystal panel. The coefficients that correspond to the typical values of the chromaticity coordinates for the vertices of the triangle color coverage constitute a reference mathematical model of the plate LCD panel from a specific manufacturer. At the stage of incoming inspection the sample of the liquid crystal panel, that is to be implemented within indication equipment, is mounted on the lighting test unit, where Nokia-Test control is provided by the formation of the RGB codes for display the image of a homogeneous field in the red, green, blue and white. The measurement of the (x,y-chromaticity coordinates in red, green, blue and white colors is performed using a colorimeter with the known value of absolute error. Instead of using lighting equipment, such measurements may be carried out immediately on the sample indication equipment during customizing procedure. The measured values are used to calculate individual LCD-panel profile coefficients through the use of Grassman's transformation, establishing mutual relations between the XYZ-color coordinates and RGB codes to be used for displaying the image on the liquid crystal panel. The obtained coefficients are to be set into the memory of the graphics controller together with the functional software and then used for image displaying. Main results. The efficiency of the proposed method of software-based compensation for technological variation of
-
Assuring the competence of nuclear power plant contractor personnel
International Nuclear Information System (INIS)
2001-07-01
This report was prepared in response to a recommendation by the IAEA International Working Group on Training and Qualification of NPP Personnel (JWG-T and Q) and supported by a number of IAEA meetings on NPP personnel training. IAEA publications on NPP training are the only international documents available to all Member States with nuclear programmes. This report complements the following IAEA publications on NPP personnel training: Technical Reports Series No. 380, Nuclear Power Plant Personnel Training and its Evaluation, A Guidebook; IAEA-TECDOC-1057, Experience in the Use of Systematic Approach to Training (SAT) for Nuclear Power Plant Personnel and IAEA-TECDOC-1063, IAEA World Survey on Nuclear Power Plant Personnel Training. This TECDOC also supplements the IAEA Safety Guide 50-SG-O1 (Rev. 1), Staffing of Nuclear Power Plants and the Recruitment Training and Authorization of Operating Personnel and Safety Standards Series No. NS-R-2, Safety of Nuclear Power Plants. Operation. Within the context of this report NPP contractors are defined as any personnel working for a nuclear power plant who are not directly employed by the nuclear power plant. Competence is the ability to perform to identified standards; it comprises skills, knowledge and attitudes and may be developed through education, experience and training. Qualification is a formal statement of achievement, resulting from an auditable assessment; if competence is assessed, the qualification becomes a formal statement of competence and may be shown on a certificate, diploma, etc. It is recognized that personnel are used to perform tasks that are of a specialised or temporary nature where it is not feasible to hire or maintain a full-time NPP employee. Accordingly, contractors may be used in a variety of situations to support NPPs. Typical situations include: supplies and services being delivered by the contractors that are subject to different quality standards based on a graded approach to assuring
-
Assuring the competence of nuclear power plant contractor personnel
Energy Technology Data Exchange (ETDEWEB)
NONE
2001-07-01
This report was prepared in response to a recommendation by the IAEA International Working Group on Training and Qualification of NPP Personnel (JWG-T and Q) and supported by a number of IAEA meetings on NPP personnel training. IAEA publications on NPP training are the only international documents available to all Member States with nuclear programmes. This report complements the following IAEA publications on NPP personnel training: Technical Reports Series No. 380, Nuclear Power Plant Personnel Training and its Evaluation, A Guidebook; IAEA-TECDOC-1057, Experience in the Use of Systematic Approach to Training (SAT) for Nuclear Power Plant Personnel and IAEA-TECDOC-1063, IAEA World Survey on Nuclear Power Plant Personnel Training. This TECDOC also supplements the IAEA Safety Guide 50-SG-O1 (Rev. 1), Staffing of Nuclear Power Plants and the Recruitment Training and Authorization of Operating Personnel and Safety Standards Series No. NS-R-2, Safety of Nuclear Power Plants. Operation. Within the context of this report NPP contractors are defined as any personnel working for a nuclear power plant who are not directly employed by the nuclear power plant. Competence is the ability to perform to identified standards; it comprises skills, knowledge and attitudes and may be developed through education, experience and training. Qualification is a formal statement of achievement, resulting from an auditable assessment; if competence is assessed, the qualification becomes a formal statement of competence and may be shown on a certificate, diploma, etc. It is recognized that personnel are used to perform tasks that are of a specialised or temporary nature where it is not feasible to hire or maintain a full-time NPP employee. Accordingly, contractors may be used in a variety of situations to support NPPs. Typical situations include: supplies and services being delivered by the contractors that are subject to different quality standards based on a graded approach to assuring
-
48 CFR 52.246-1 - Contractor Inspection Requirements.
2010-10-01
... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Contractor Inspection....246-1 Contractor Inspection Requirements. As prescribed in 46.301, insert the following clause: Contractor Inspection Requirements (APR 1984) The Contractor is responsible for performing or having...
-
48 CFR 970.5244-1 - Contractor purchasing system.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor purchasing... for Management and Operating Contracts 970.5244-1 Contractor purchasing system. As prescribed in 970.4403 insert the following clause: Contractor Purchasing System (AUG 2009) (a) General. The Contractor...
-
48 CFR 52.204-7 - Central Contractor Registration.
2010-10-01
... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Central Contractor....204-7 Central Contractor Registration. As prescribed in 4.1105, use the following clause: Central Contractor Registration (APR 2008) (a) Definitions. As used in this clause— Central Contractor Registration...
-
Environmental liability and the independent contractor
International Nuclear Information System (INIS)
Gilmour, B.S.
1999-01-01
The provisions of the Environmental Protection and Enhancement Act (EPEA) regarding the relationship between a company and an independent contractor were reviewed. The EPEA was introduced in September 1993 and significantly altered the environmental laws in the province of Alberta. The provisions of the EPEA that apply to the petroleum industry are conservation and reclamation as well as provisions concerning release of substances, contaminated sites and penalties. Companies that pollute may be held liable for reclamation, even if the work was carried out by an independent contractor and despite the fact that the independent contractor is not an employee of the company. Under the current EPEA laws, companies may not be able to effectively shift responsibility for environmental liabilities to independent contractors even where the contractor was negligent. This paper presented suggestions regarding contractor agreements and due diligence to help minimize the risk of liability to companies. The paper also discussed the following two types of liabilities under the EPEA's harmful substances section: (1) the obligation to clean up an affected area, and (2) fines and penalties that may be imposed when an offence is committed
-
Systems engineering identification and control of mixed waste technology development
International Nuclear Information System (INIS)
Beitel, G.A.
1997-01-01
The Department of Energy (DOE) established the Mixed Waste Characterization, Treatment, and Disposal Focus Area (MWFA) to develop technologies required to meet the Department's commitments for treatment of mixed low-level and transuranic wastes. Waste treatment includes all necessary steps from generation through disposal. Systems engineering was employed to reduce programmatic risk, that is, risk of failure to meet technical commitments within cost and schedule. Customer needs (technology deficiencies) are identified from Site Treatment Plans, Consent Orders, ten year plans, Site Technical Coordinating Groups, Stakeholders, and Site Visits. The Technical Baseline, a prioritized list of technology deficiencies, forms the basis for determining which technology development activities will be supported by the MWFA. Technology Development Requirements Documents are prepared for each technology selected for development. After technologies have been successfully developed and demonstrated, they are documented in a Technology Performance Report. The Technology Performance Reports are available to any of the customers or potential users of the technology, thus closing the loop between problem identification and product development. This systematic approach to technology development and its effectiveness after 3 years is discussed in this paper
-
Causes of Contractor's Business Failure in Developing Countries: The Case of Palestine
Directory of Open Access Journals (Sweden)
Sherif Mohamed
2006-12-01
Full Text Available The construction industry has unique characteristics that sharply distinguish it from other sectors of the economy. It is fragmented, very sensitive to the economic cycles and political environment, and has a significantly high rate of business failure. Business failure, collapse and bankruptcy are common terms in the industry due to the many risks inherited in how the industry operates. Throughout the world, the relative ease of entry gives rise to a large number of contracting firms competing fiercely in the market exposing many of them to business failure, Palestine is no exception. The objectives of this paper are to report on a research study which aims at exploring the causes of contractor's business failure in Palestine, and investigating their severity from the contractor's point of view. The study's results shows that the main causes of business failure are delay in collecting debt from clients (donors, border closure, heavy dependence on bank loans and payment of high interest on these loans, lack of capital, absence of industry regulations, low profit margin due to high competition, awarding contracts by client to the lowest bidder, and lack of experience in contract management. Based on these findings, recommendations to the Palestinian National Authority (PNA and local contractors are presented in this paper.
-
Innovation Strategy in Slovak Forest Contractor Firms—A SWOT Analysis
Directory of Open Access Journals (Sweden)
Martina Štěrbová
2016-05-01
Full Text Available The aim of the study is to determine the innovation strategy of contractor firms in the Slovak forestry service sector in the area of further innovation activities development. The strategy identification was based on the analysis of the strengths, weaknesses, opportunities and threats in this sector. The results indicate that weaknesses of contractor firms exceed their strengths and, considering the degree and importance of their impact, opportunities exceed identified threats. Based on these findings revealing the relations in the area of innovation activities of forestry service contractors, the “Strategy of Partnership” was suggested as the most suitable type of strategy. It can be concluded that such a form of grouping cooperation brings many benefits to contractors in the form of information availability, guidance, training, and management of conflicts, risks and uncertainty, which are associated with the innovation process.
-
Defense Primer: DOD Contractors
2017-02-10
functions, from intelligence analysis or software development to landscaping or food service. Why does DOD use individual contractors? Going back to...that provide professional services, from research to management support. The bulk of contractors—more than 70%—provide products, and these include...10 U.S.C. Part IV: Service, Supply, and Procurement. CRS Products CRS In Focus IF10548, Defense Primer: U.S. Defense Industrial Base, by Daniel
-
48 CFR 1552.237-76 - Government-Contractor Relations.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Government-Contractor... 1552.237-76 Government-Contractor Relations. As prescribed in 1537.110(g), insert the following clause: Government-Contractor Relations (JUN 1999) (a) The Government and the Contractor understand and agree that...
-
Xu, Lang; Wang, Chuanxu; Li, Hui
2017-06-08
We focus on the impacts of technological spillovers and environmental awareness in a two-echelon supply chain with one-single supplier and one-single manufacturer to reduce carbon emission. In this supply chain, carbon abatement investment becomes one of key factors of cutting costs and improving profits, which is reducing production costs in the components and products-the investment from players in supply chain. On the basis of optimality theory, the centralized and decentralized models are respectively established to investigate the optimal decisions and profits. Further, setting the players' profits of the decentralized scenario as the disagreement points, we propose a bargaining-coordination contract through revenue-cost sharing to enhance the performance. Finally, by theoretical comparison and numerical analysis, the results show that: (i) The optimal profits of players and supply chain improve as technological spillovers and environmental awareness increase, and the profits of them in the bargaining-coordination contract are higher than that in the decentralized scenario; (ii) Technological spillovers between the players amplify the impact of "free-ride" behavior, in which the supplier always incentives the manufacturer to improve carbon emission intensity, but the cooperation will achieves and the profits will improve only when technological spillovers and environmental awareness are great; (iii) The contract can effectively achieve coordinated supply chain, and improve carbon abatement investment.
-
2010-07-01
... Protection of Environment ENVIRONMENTAL PROTECTION AGENCY (CONTINUED) AIR PROGRAMS (CONTINUED) CHEMICAL ACCIDENT PREVENTION PROVISIONS Program 3 Prevention Program § 68.87 Contractors. (a) Application. This... specialty work on or adjacent to a covered process. It does not apply to contractors providing incidental...
-
78 FR 11164 - Policy on Contractor Profits
2013-02-15
... DEPARTMENT OF DEFENSE Defense Acquisition Regulations System Policy on Contractor Profits AGENCY... Authorization Act for Fiscal Year 2013. Section 804, Department of Defense Policy on Contractor Profits... modifications to such guidelines that are necessary to ensure an appropriate link between contractor profit and...
-
48 CFR 46.301 - Contractor inspection requirements.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor inspection... CONTRACT MANAGEMENT QUALITY ASSURANCE Contract Clauses 46.301 Contractor inspection requirements. The contracting officer shall insert the clause at 52.246-1, Contractor Inspection Requirements, in solicitations...
-
48 CFR 970.5203-3 - Contractor's organization.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor's organization... for Management and Operating Contracts 970.5203-3 Contractor's organization. As prescribed in 970.0371-9, insert the following clause: Contractor's Organization (DEC 2000) (a) Organization chart. As...
-
48 CFR 450.303-1 - Contractor requests.
2010-10-01
... 48 Federal Acquisition Regulations System 4 2010-10-01 2010-10-01 false Contractor requests. 450.303-1 Section 450.303-1 Federal Acquisition Regulations System DEPARTMENT OF AGRICULTURE CONTRACT MANAGEMENT EXTRAORDINARY CONTRACTUAL ACTIONS Contract Adjustments 450.303-1 Contractor requests. Contractor...
-
Current information technology needs of small to medium sized apparel manufacturers and contractors
Energy Technology Data Exchange (ETDEWEB)
Wipple, C.; Vosti, E.
1997-11-01
This report documents recent efforts of the American Textile Partnership (AMTEX) Demand Activated Manufacturing Architecture (DAMA) Project to address needs that are characterized of small to medium sized apparel manufactures and contractors. Background on the AMTEX/DAMA project and objectives for this specific efforts are discussed.
-
Coordination in contractual relations: Some preliminary findings from the Malaysian housing industry
Directory of Open Access Journals (Sweden)
Suraya Ismail
2008-12-01
Full Text Available The traditional general procurement route found in many housing projects in Malaysia is conceptualized as a governance structure following the transaction cost economics (TCE approach. This approach has been used to examine governance structures in different economic sectors in several countries but evidence of its use in the context of developing countries is limited. This lack of evidence has prompted the authors to conduct a preliminary study to ascertain whether a TCE approach can explain construction governance structures in developing countries. This research does not discuss the trade-off that governs the choice of hybrids, market or hierarchies for organizing transactions. Rather, it takes advantage of existing research to substantiate the specific properties of hybrid organizations as governance structures. The main focus is coordination. Coordination is specified at two levels. At Level 1 is the coordination of specialization (i.e. the formation of the project team members and at Level 2 is the coordination mode of the contracting parties (client and contractor and the agents involved (the lead designer and project manage r. A case survey method was adopted. Preliminary findings seem to suggest that clients have used hierarchical themes in the contracts and high powered incentives to coordinate with in the contracting parties. The research findings suggest that all participants involved in the sample studied used governance structures symptomatic of a hybrid organization.
-
International Nuclear Information System (INIS)
Lewis, R.A.
1996-05-01
This document contains the revised Environmental Restoration Contractor (ERC) Implementation Plan for compliance with the Dangerous Waste and Hazardous and Solid Waste Amendment portions of the Resource Conservation and Recovery Act (RCRA) Permit for the Treatment, Storage, and Disposal of Dangerous Waste (hereafter referred to as the open-quotes Permitclose quotes). The Permit became effective on September 28, 1994. The ERC has developed the Permit Implementation Plan to ensure that the Permit is properly implemented within the ERC project and functions. The plan contains a list of applicable permit conditions, descriptions, responsible organizations, and the status of compliance. The ERC's responsibilities for Permit implementation are identified within both project and functional organizations. Project Managers are responsible for complying with conditions specific to a particular treatment, storage, or disposal (TSD) unit. TSD-specific compliance in include items such as closure plan deliverables, reporting and record keeping requirements, or compliance with non-unit-specific tasks such as spill reporting and emergency response. Functional organizations are responsible for sitewide activities, such as coordinating Permit modifications and developing personnel training programs
-
Energy Materials Coordinating Committee (EMaCC). Annual technical report, Fiscal Year 2001
Energy Technology Data Exchange (ETDEWEB)
None, None
2002-08-01
The DOE Energy Materials Coordinating Committee (EMaCC) serves primarily to enhance coordination among the Department's materials programs and to further effective use of materials expertise within the Department. These functions are accomplished through the exchange of budgetary and planning information among program managers and through technical meetings/workshops on selected topics involving both DOE and major contractors. In addition, EMaCC assists in obtaining materials-related inputs for both intra- and interagency compilations.
-
48 CFR 2427.305-2 - Follow-up by contractor.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Follow-up by contractor....305-2 Follow-up by contractor. (b) Contractor reports. Contractors shall complete and submit to the... Contracting Officer shall send the form to those contractors whose contract work may have required the...
-
Photogrammetry for rapid prototyping: development of noncontact 3D reconstruction technologies
Knyaz, Vladimir A.
2002-04-01
An important stage of rapid prototyping technology is generating computer 3D model of an object to be reproduced. Wide variety of techniques for 3D model generation exists beginning with manual 3D models generation and finishing with full-automated reverse engineering system. The progress in CCD sensors and computers provides the background for integration of photogrammetry as an accurate 3D data source with CAD/CAM. The paper presents the results of developing photogrammetric methods for non-contact spatial coordinates measurements and generation of computer 3D model of real objects. The technology is based on object convergent images processing for calculating its 3D coordinates and surface reconstruction. The hardware used for spatial coordinates measurements is based on PC as central processing unit and video camera as image acquisition device. The original software for Windows 9X realizes the complete technology of 3D reconstruction for rapid input of geometry data in CAD/CAM systems. Technical characteristics of developed systems are given along with the results of applying for various tasks of 3D reconstruction. The paper describes the techniques used for non-contact measurements and the methods providing metric characteristics of reconstructed 3D model. Also the results of system application for 3D reconstruction of complex industrial objects are presented.
-
32 CFR 989.23 - Contractor prepared documents.
2010-07-01
... 32 National Defense 6 2010-07-01 2010-07-01 false Contractor prepared documents. 989.23 Section... PROTECTION ENVIRONMENTAL IMPACT ANALYSIS PROCESS (EIAP) § 989.23 Contractor prepared documents. All Air Force... should reflect on the cover sheet they are an Air Force document. Contractor preparation information...
-
Solids throttling valves for coal conversion and utilization development. Final report
Energy Technology Data Exchange (ETDEWEB)
Sine, G.C.
1980-11-01
A complete test system to test, evaluate, and develop control valves for slurry letdown service in coal liquefaction plants is needed. The site identified for the test system was the SRC II Pilot Plant located at Ft. Lewis, Washington. The US Department of Energy, Morgantown Energy Technology Center, requested a test system design that would enable testing of various configuration letdown valves that would be compatible with the existing facility and have minimum impact on Pilot Plant operations. Drawings and specifications for such a test system were prepared, coordinated with Ft. Lewis personnel, revised to reflect Ft. Lewis operating personnel comments, and approved for use by the Morgantown Energy Technology Center. These drawings and specifications will enable the test system to be built, installed, and integrated with the existing facility by a general contractor.
-
2006-12-01
These include equitable estoppel , fair competition, appearance of conflict of interests (government and contractor relationship), and most...importantly, intellectually property rights. Regarding equitable estoppel , one legal definition defines it as follows: “A type of estoppel that bars a
-
Developing technologies and resources
Energy Technology Data Exchange (ETDEWEB)
Walker, R.S. [Canadian Nuclear Laboratories, Chalk River, ON (Canada)
2015-07-01
Our success as a nuclear nation rests on interdependent pillars involving industry, governments, regulators, and academia. In a context of coherent public policy, we must achieve: 5 Nuclear Industry Priorities: Ensure refurbishments are completed to cost and schedule; Achieve Canadian supply chain success in international nuclear business; Support a strong Canadian nuclear science, technology and innovation agenda; Enhance the supply of skilled workers; Develop a coordinated and integrated strategy for the long term management of all radioactive waste materials; Refine communication strategies informed by insights from social sciences. Canada's nuclear sector has the opportunity to adapt to the opportunities presented by having a national laboratory in Canada.
-
Developing technologies and resources
International Nuclear Information System (INIS)
Walker, R.S.
2015-01-01
Our success as a nuclear nation rests on interdependent pillars involving industry, governments, regulators, and academia. In a context of coherent public policy, we must achieve: 5 Nuclear Industry Priorities: Ensure refurbishments are completed to cost and schedule; Achieve Canadian supply chain success in international nuclear business; Support a strong Canadian nuclear science, technology and innovation agenda; Enhance the supply of skilled workers; Develop a coordinated and integrated strategy for the long term management of all radioactive waste materials; Refine communication strategies informed by insights from social sciences. Canada's nuclear sector has the opportunity to adapt to the opportunities presented by having a national laboratory in Canada.
-
EPA announced the availability of the final contractor report entitled, Development of an Analytic Approach to Determine How Environmental Protection Agency’s Integrated Risk Information System (IRIS) Is Used By Non EPA Decision Makers. This contractor report analyzed how ...
-
Soft-Fault Detection Technologies Developed for Electrical Power Systems
Button, Robert M.
2004-01-01
The NASA Glenn Research Center, partner universities, and defense contractors are working to develop intelligent power management and distribution (PMAD) technologies for future spacecraft and launch vehicles. The goals are to provide higher performance (efficiency, transient response, and stability), higher fault tolerance, and higher reliability through the application of digital control and communication technologies. It is also expected that these technologies will eventually reduce the design, development, manufacturing, and integration costs for large, electrical power systems for space vehicles. The main focus of this research has been to incorporate digital control, communications, and intelligent algorithms into power electronic devices such as direct-current to direct-current (dc-dc) converters and protective switchgear. These technologies, in turn, will enable revolutionary changes in the way electrical power systems are designed, developed, configured, and integrated in aerospace vehicles and satellites. Initial successes in integrating modern, digital controllers have proven that transient response performance can be improved using advanced nonlinear control algorithms. One technology being developed includes the detection of "soft faults," those not typically covered by current systems in use today. Soft faults include arcing faults, corona discharge faults, and undetected leakage currents. Using digital control and advanced signal analysis algorithms, we have shown that it is possible to reliably detect arcing faults in high-voltage dc power distribution systems (see the preceding photograph). Another research effort has shown that low-level leakage faults and cable degradation can be detected by analyzing power system parameters over time. This additional fault detection capability will result in higher reliability for long-lived power systems such as reusable launch vehicles and space exploration missions.
-
Exploring Coordination Structures in Open Source Software Development
van Hillegersberg, Jos; Harmsen, Frank; Hegeman, J.H.; Amrit, Chintan Amrit; Geisberger, Eva; Keil, Patrick; Kuhrmann, Marco
2007-01-01
Coordination is difficult to achieve in a large globally distributed project setting. The problem is multiplied in open source software development projects, where most of the traditional means of coordination such as plans, system-level designs, schedules and defined process are not used. In order
-
42 CFR 455.202 - Limitation on contractor liability.
2010-10-01
... 42 Public Health 4 2010-10-01 2010-10-01 false Limitation on contractor liability. 455.202 Section... § 455.202 Limitation on contractor liability. (a) A program contractor, a person, or an entity employed... contractor will not be held to have violated any criminal law and will not be held liable in any civil action...
-
Developing and supporting coordinators of structured mentoring schemes in South Africa
Directory of Open Access Journals (Sweden)
Penny Abbott
2010-10-01
Research purpose: The aim of this research is to discover what the characteristics of coordinators of structured mentoring schemes in South Africa are, what is required of such coordinators and how they feel about their role, with a view to improving development and support for them. Motivation for the study: The limited amount of information about role requirements for coordinators which is available in the literature is not based on empirical research. This study aims to supply the empirical basis for improved development and support for coordinators. Research design and method: A purposive sample of 25 schemes was identified and both quantitative and qualitative data, obtained through questionnaires and interviews, were analysed using descriptive statistics and thematic analysis. Main findings: Functions of coordinators tend to be similar across different types of mentoring schemes. A passion for mentoring is important, as the role involves many frustrations. There is little formalised development and support for coordinators. Practical/managerial implications: The study clarifies the functions of the coordinator, offers a job description and profile and makes suggestions on how to improve the development of the coordinator’s skills. Contribution/value-add: An understanding of what is required from a coordinator, how the necessary knowledge and skills can be developed and how the coordinator can be supported,adds value to an organisation setting up or reviewing its structured mentoring schemes.
-
Directory of Open Access Journals (Sweden)
Shahin Mokhlesian
2014-06-01
Full Text Available There are many studies of contractor selection based on clients and the selection of suppliers by contractors. However, supplier selection specifically related to green construction projects has been much less studied. Green construction differs from conventional construction because of differences in its underlying principles and use of environmentally-friendly materials and technologies. This paper studies how procurers in contractor companies in Sweden adopt green projects and how contractor perception of supplier mastery of green knowledge affects supplier selection. The investigation is based on a set of semi-structured interviews conducted among three large contractors in Sweden. A main finding is that the perceived differences between green and conventional projects do not change supplier selection dramatically. An implication is that “greener projects” is a more appropriate denotation than “green project”. Evidence shows that suppliers’ green knowledge is an important factor in supplier selection, as respondents rated suppliers’ knowledge of green projects as very important, and to fix his, there was a consensus among respondents about the need for close collaboration between contractors and suppliers. To ensure knowledge acquisition from suppliers and to increase their competitive advantage over rivals, contractors collaborate with their suppliers in a partnering setting. It is anticipated that the results of this study will be used to fill the gap in the literature on supplier selection in green projects and can also be used for construction firms contemplating getting involved in green projects.
-
Energy Materials Coordinating Committee (EMaCC), Fiscal year 1990
Energy Technology Data Exchange (ETDEWEB)
None, None
1991-05-31
The DOE Energy Materials Coordinating Committee (EMaCC) serves primarily to enhance coordination among the Department's materials programs and to further the effective use of materials expertise within the Department. These functions are accomplished through the exchange of budgetary and planning information among program managers and through technical meetings/workshops on selected topics involving both DOE and major contractors. Four topical subcommittees are established and are continuing their own programs: Structural Ceramics, Electrochemical Technologies, Radioactive Waste Containment, and Superconductivity. In addition, the EMaCC aids in obtaining materialsrelated inputs for both intra- and inter-agency compilations. Membership in the EMaCC is open to any Department organizational unit; participants are appointed by Division or Office Directors. The current active membership is listed on the following four pages. The EMaCC reports to the Director of the Office of Energy Research in his capacity as overseer of the technical programs of the Department. This annual technical report is mandated by the EMaCC terms of reference. This report summarizes EMaCC activities for FY 1990 and describes the materials research programs of various offices and divisions within the Department. The Chairman of EMaCC for FY 1990 was Scott L. Richlen; the Executive Secretary was Dr. Jerry Smith.
-
International Nuclear Information System (INIS)
Certa, P.J.
1998-01-01
Readiness to Proceed With Phase 1B Privatization documents the processes used to determine readiness to proceed with tank waste treatment technologies from private industry, now known as TWRS privatization. An overall systems approach was applied to develop action plans to support the retrieval and disposal mission of the TWRS Project. The systems and infrastructure required to support the mission are known. Required systems are either in place or plans have been developed to ensure they exist when needed. Since October 1996 a robust system engineering approach to establishing integrated Technical Baselines, work breakdown structures, tank farms organizational structure and configurations, work scope, and costs has become part of the culture within the TWRS Project. An analysis of the programmatic, management, and technical activities necessary to declare readiness to proceed with execution of the mission demonstrates that the system, personnel, and hardware will be on line and ready to support the private contractors. The systems approach included defining the retrieval and disposal mission requirements and evaluating the readiness of the Project Hanford Management Contract (PHMC) team to support initiation of waste processing by the private contractors in June 2002 and to receive immobilized waste shortly thereafter. The Phase 1 feed delivery requirements from the private contractor Requests for Proposal were reviewed. Transfer piping routes were mapped, existing systems were evaluated, and upgrade requirements were defined
-
Development of the Coordination between Posture and Manual Control
Haddad, Jeffrey M.; Claxton, Laura J.; Keen, Rachel; Berthier, Neil E.; Riccio, Gary E.; Hamill, Joseph; Van Emmerik, Richard E. A.
2012-01-01
Studies have suggested that proper postural control is essential for the development of reaching. However, little research has examined the development of the coordination between posture and manual control throughout childhood. We investigated the coordination between posture and manual control in children (7- and 10-year-olds) and adults during…
-
International Nuclear Information System (INIS)
Minbiole, P.R.
2006-01-01
A contract electron beam processing company is primarily focused on providing production irradiation services to established customers; however, a forward-thinking services company encourages and enables the development of new polymer applications in a number of ways. Note that in this presentation innovation will typically refer to the development of new polymer applications for sizeable commercial opportunities, as opposed to innovation in scientific research. The traditional, and in many cases current, approach to innovation by service contractors in North America and Europe focuses on providing controlled irradiation for experimental activities by product developers. While some researchers around the world have ready access to electron beams, it may be surprising to point out that product developers in manufacturing companies including companies that operate their own beam for manufacturing existing products often have extremely limited access to that beam for development purposes. In addition, service contractors conduct a wide range of 'missionary' activities to let potential product developers know of the benefits of electron beam processing and to communicate their ability to facilitate the development of valuable products. Activities in this area include: participation in various industrial tradeshows, advertising, direct sales calls, seminars, press releases, website communication, and technical presentations to specific prospects and customers. The presenter's experience consists of more than 20 years as a 'hands-on' president of the largest contract electron beam processing company in North America, a company which provides processing for an exceptionally broad range of industrial applications. Some of these applications are well-known, successful applications involving crosslinking for such products as wire and cable jackets, heat-shrink tubing, PEX tubing, balloon angioplasty tubing, foam, films, hydrogels, etc. These products involve the crosslinking
-
Suzuki, Seigo; Sato, Iori; Emoto, Shun; Kamibeppu, Kiyoko
To determine the association between parental care burdens and care coordination provided by nurses for children with technology dependency, specifically regarding physio-psychological burdens and social restrictions. A cross-sectional study was conducted between October and November 2015. Participants were recruited via home-visit nursing stations, social worker offices, and special-needs schools. A total of 246 parents of children with technology dependency completed anonymous self-report questionnaires. Parental burden was measured using the Zarit Burden Interview. Care coordination for children with technology dependency was examined using items extracted from focus group interviews involving three nursing administrators at home-visit nursing stations, two social workers, and a coordinator of school education for children with special health care needs. Multiple regression analysis was performed to examine the relationship between parental burden and care coordination among 172 parents who contracted with visiting nurses. Parents and children with nursing support were significantly younger and had higher medical care needs and higher parental role strain than those without nursing support. Care coordination from nurses predicted reduced parental burden, role strain, and personal strain (β=-0.247, p=0.002; β=-0.272, p=0.001; β=-0.221, p=0.009, respectively). Nurses' care coordination appears to be associated with a reduction in parents' care burden resulting from home medical care of children with technology dependency, especially the social restrictions and physio-psychological burdens. Strengthening nursing functioning as care coordinators may contribute to reducing care burdens for parents of children with technology dependency. Copyright © 2017 Elsevier Inc. All rights reserved.
-
Energy materials coordinating committee (EMaCC). Annual technical report, fiscal year 2003
Energy Technology Data Exchange (ETDEWEB)
none,
2004-10-18
The DOE Energy Materials Coordinating Committee (EMaCC) serves primarily to enhance coordination among the Department's materials programs and to further effective use of materials expertise within the Department. These functions are accomplished through the exchange of budgetary and planning information among program managers and through technical meetings/workshops on selected topics involving both DOE and major contractors. In addition, EMaCC assists in obtaining materials-related inputs for both intra- and interagency compilations. Topical subcommittees of the EMaCC are responsible for conducting seminars and otherwise facilitating information flow between DOE organizational units in materials areas of particular importance to the Department. The EMaCC Terms of Reference were recently modified and developed into a Charter that was approved on June 5, 2003. As a result of this reorganization, the existing subcommittees were disbanded and new subcommittees are being formed.
-
Development of system integration technology for integral reactor
Energy Technology Data Exchange (ETDEWEB)
Chang, Moon Hee; Kang, D. J.; Kim, K. K. and others
1999-03-01
The objective of this report is to integrate the conceptual design of an integral reactor, SMART producing thermal energy of 330 MW, which will be utilized to supply energy for seawater desalination and small-scale power generation. This project also aims to develop system integration technology for effective design of the reactor. For the conceptual design of SMART, preliminary design requirements including the top-tier requirements and design bases were evaluated and established. Furthermore, in the view of the application of codes and standards to the SMART design, existing laws, codes and standards were analyzed and evaluated with respect to its applicability. As a part of this evaluation, directions and guidelines were proposed for the development of new codes and standards which shall be applied to the SMART design. Regarding the integration of SMART conceptual designs, major design activities and interfaces between design departments were established and coordinated through the design process. For the effective management of all design schedules, a work performance evaluation system was developed and applied to the design process. As the results of this activity, an integrated output of SMART designs was produced. Two additional scopes performed in this project include the preliminary economic analysis on the SMART utilization for seawater desalination, and the planning of verification tests for technology implemented into SMART and establishing development plan of the computer codes to be used for SMART design in the next phase. The technical cooperation with foreign country and international organization for securing technologies for integral reactor design and its application was coordinated and managed through this project. (author)
-
Multi-megawatt inverter/converter technology for space power applications
Myers, Ira T.; Baumann, Eric D.; Kraus, Robert; Hammoud, Ahmad N.
1992-01-01
Large power conditioning mass reductions will be required to enable megawatt power systems envisioned by the Strategic Defense Initiative, the Air Force, and NASA. Phase 1 of a proposed two phase interagency program has been completed to develop an 0.1 kg/kW DC/DC converter technology base for these future space applications. Three contractors, Hughes, General Electric (GE), and Maxwell were Phase 1 contractors in a competitive program to develop a megawatt lightweight DC/DC converter. Researchers at NASA Lewis Research Center and the University of Wisconsin also investigated technology in topology and control. All three contractors, as well as the University of Wisconsin, concluded at the end of the Phase 1 study, which included some critical laboratory work, that 0.1-kg/kW megawatt DC/DC converters can be built. This is an order of magnitude lower specific weight than is presently available. A brief description of each of the concepts used to meet the ambitious goals of this program are presented.
-
Developing a scalable modeling architecture for studying survivability technologies
Mohammad, Syed; Bounker, Paul; Mason, James; Brister, Jason; Shady, Dan; Tucker, David
2006-05-01
To facilitate interoperability of models in a scalable environment, and provide a relevant virtual environment in which Survivability technologies can be evaluated, the US Army Research Development and Engineering Command (RDECOM) Modeling Architecture for Technology Research and Experimentation (MATREX) Science and Technology Objective (STO) program has initiated the Survivability Thread which will seek to address some of the many technical and programmatic challenges associated with the effort. In coordination with different Thread customers, such as the Survivability branches of various Army labs, a collaborative group has been formed to define the requirements for the simulation environment that would in turn provide them a value-added tool for assessing models and gauge system-level performance relevant to Future Combat Systems (FCS) and the Survivability requirements of other burgeoning programs. An initial set of customer requirements has been generated in coordination with the RDECOM Survivability IPT lead, through the Survivability Technology Area at RDECOM Tank-automotive Research Development and Engineering Center (TARDEC, Warren, MI). The results of this project are aimed at a culminating experiment and demonstration scheduled for September, 2006, which will include a multitude of components from within RDECOM and provide the framework for future experiments to support Survivability research. This paper details the components with which the MATREX Survivability Thread was created and executed, and provides insight into the capabilities currently demanded by the Survivability faculty within RDECOM.
-
Development of interpersonal coordination between peers during a drumming task
Endedijk, H.M.; Ramenzoni, V.C.; Cox, R.F.A.; Cillessen, A.H.N.; Bekkering, H.; Hunnius, S.
2015-01-01
During social interaction, the behavior of interacting partners becomes coordinated. Although interpersonal coordination is well-studied in adults, relatively little is known about its development. In this project we explored how 2-, 3-, and 4-year-old children spontaneously coordinated their
-
Development of Interpersonal Coordination Between Peers During a Drumming Task
Endedijk, Hinke M.; Ramenzoni, Veronica C. O.; Cox, Ralf F. A.; Cillessen, Antonius H. N.; Bekkering, Harold; Hunnius, Sabine
During social interaction, the behavior of interacting partners becomes coordinated. Although interpersonal coordination is well-studied in adults, relatively little is known about its development. In this project we explored how 2-, 3-, and 4-year-old children spontaneously coordinated their
-
1997-04-01
This report discusses (1) the roles, responsibilities, and authority of : agencies that establish policy, provide funds or oversee funding requests, : and develop explosives and narcotics detection technologies; : (2) mechanisms used to coordinate th...
-
International Nuclear Information System (INIS)
O'Brien, William P Jr
2003-01-01
Students discover the equivalence between plausible geographic variables (co-latitude and longitude) of the Earth and less-familiar geometric variables (polar and azimuthal angles) of spherical polar coordinates by collecting and analysing positional data recorded during field exercises with a handheld global positioning system (GPS) receiver. This pedagogical approach to teaching spherical geometry, based on field experience rather than classroom theory, uses GPS technology to capture the curiosity of contemporary students, technical or otherwise, who might not normally find the topic of the spherical polar coordinate system comprehensible, relevant or interesting
-
International Nuclear Information System (INIS)
McCabe, G.H.; Stein, S.L.; Serie, P.J.
1995-01-01
The US Department of Energy (DOE) faces a major challenge in cleaning up its contaminated sites throughout the United States. One major area of concern is the plumes in soil and ground water which are contaminated with a myriad of different pollutants. DOE recently organized its plume-related problems into the Plume Focus Area. The mission of the Plume Focus Area is to enhance the deployment of innovative technologies for containing and cleaning up contaminant plumes in ground water and soil at all DOE sites. Environmental cleanup priorities for soil and ground water plumes are being defined and technology users have the challenge of matching current and innovative technologies to those priorities. By involving a range of stakeholders in the selection, demonstration, and evaluation of new technologies, the deployment of these technologies can be enhanced. If new plume cleanup technologies are to be deployable, they must improve on today's baseline technologies. The Sites' Coordination Team (SCT) of the Plume Focus Area develops and supports the implementation of methods for stakeholder involvement throughout the multiple steps that define focus area activities. Site-specific teams are being formed to carry out the strategy at each site, and the teams will work through Site Technology Coordination Groups (STCGs) at each location. The SCT is responsible for identifying the site-specific stakeholder involvement teams, training the team members, preparing needed national-level guidance and strategies, helping the teams tailor a strategy for their particular site that meets the overall needs of the focus area, and facilitating inter-site coordination. The results will be used to develop national technology acceptance reports on the innovative technologies being funded and evaluated under the Plume Focus Area
-
Military Contractors - Too Much Dependence
National Research Council Canada - National Science Library
Hill, Nathan E
2008-01-01
.... There is undoubtedly a need for military contractors and there are numerous positive arguments in their favor. However, the negative arguments have not been highlighted enough recently and the scales are now out of balance. The intent of this research paper is to encourage the U.S. military to rebalance the scales and curb the over-reliance on contractors.
-
The responsibility of the contractor for project deficiencies
Directory of Open Access Journals (Sweden)
Pušac Jovana
2011-01-01
Full Text Available In this paper the author analyzes a civil law responsibility of the Contractor for project deficiencies resulting in reduced quality of the construction, i.e. not affecting its solidity. Primary obligation of the Contractor is to perform works in compliance with professional standards, the contract and the approved project. The Contractor cannot change the approved project at will, even when he has designed it. Hence, the question must be raised of the obligation of the Contractor to strictly abide by the project, assigned to him by the Authority, regardless of evident deficiencies of the Project and of his responsibility for performing works in compliance with the said project resulting in deficiencies in the construction, that is construction works. If the latter hypothesis is correct, then it must be established what deficiencies in the project fall under the responsibility of the Contractor (visible or hidden, i.e. the issue of dividing responsibility between the Project Designer and the Contractor in terms of the project deficiencies must be set up and solved. Finally, it is also important to define the realization of rights and duties of the Contractor in case the Contractor has to recede from the Project. In this paper the author tries to offer detail and complete answers to raised questions.
-
Energy Materials Coordinating Committee, fiscal year 1997. Annual technical report
Energy Technology Data Exchange (ETDEWEB)
NONE
1998-07-31
The DOE Energy Materials Coordinating Committee (EMaCC) serves primarily to enhance coordination among the Department`s materials programs and to further effective use of materials expertise within the Department. These functions are accomplished through the exchange of budgetary and planning information among program managers and through technical meetings/workshops on selected topics involving both DOE and major contractors. In addition, EMaCC assists in obtaining materials-related inputs for both intra- and interagency compilations. This report summarizes EMaCC activities for FY 1997 and describes the materials research programs of various offices and divisions within the Department.
-
48 CFR 952.251-70 - Contractor employee travel discounts.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor employee travel... Contractor employee travel discounts. As prescribed in 951.7002, insert the following clause: Contractor Employee Travel Discounts (AUG 2009) (a) The Contractor shall take advantage of travel discounts offered to...
-
48 CFR 245.608 - Screening of contractor inventory.
2010-10-01
... 48 Federal Acquisition Regulations System 3 2010-10-01 2010-10-01 false Screening of contractor inventory. 245.608 Section 245.608 Federal Acquisition Regulations System DEFENSE ACQUISITION REGULATIONS... Disposal of Contractor Inventory 245.608 Screening of contractor inventory. ...
-
48 CFR 1553.209 - Contractor qualifications.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor qualifications. 1553.209 Section 1553.209 Federal Acquisition Regulations System ENVIRONMENTAL PROTECTION AGENCY CLAUSES AND FORMS FORMS Prescription of Forms 1553.209 Contractor qualifications. ...
-
48 CFR 45.501 - Prime contractor alternate locations.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Prime contractor alternate... CONTRACT MANAGEMENT GOVERNMENT PROPERTY Support Government Property Administration 45.501 Prime contractor... administration from another contract administration office, for purposes of evaluating prime contractor...
-
48 CFR 1852.209-72 - Composition of the contractor.
2010-10-01
... contractor. 1852.209-72 Section 1852.209-72 Federal Acquisition Regulations System NATIONAL AERONAUTICS AND... and Clauses 1852.209-72 Composition of the contractor. As prescribed in 1809.670, insert the following clause: Composition of the Contractor (DEC 1988) If the Contractor is comprised of more than one legal...
-
48 CFR 53.209 - Contractor qualifications.
2010-10-01
... 48 Federal Acquisition Regulations System 2 2010-10-01 2010-10-01 false Contractor qualifications. 53.209 Section 53.209 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION (CONTINUED) CLAUSES AND FORMS FORMS Prescription of Forms 53.209 Contractor qualifications. ...
-
48 CFR 2936.201 - Evaluation of contractor performance.
2010-10-01
... 48 Federal Acquisition Regulations System 7 2010-10-01 2010-10-01 false Evaluation of contractor... Construction 2936.201 Evaluation of contractor performance. The HCA must establish procedures to evaluate construction contractor performance and prepare performance reports as required by FAR 36.201. ...
-
48 CFR 1552.209-76 - Contractor performance evaluations.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor performance... 1552.209-76 Contractor performance evaluations. As prescribed in section 1509.170-1, insert the following clause in all applicable solicitations and contracts. Contractor Performance Evaluations (OCT 2002...
-
48 CFR 8.406-7 - Contractor Performance Evaluation.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor Performance... ACQUISITION PLANNING REQUIRED SOURCES OF SUPPLIES AND SERVICES Federal Supply Schedules 8.406-7 Contractor Performance Evaluation. Ordering activities must prepare an evaluation of contractor performance for each...
-
48 CFR 32.909 - Contractor inquiries.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor inquiries. 32.909 Section 32.909 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION GENERAL CONTRACTING REQUIREMENTS CONTRACT FINANCING Prompt Payment 32.909 Contractor inquiries. (a) Direct questions...
-
National Radon Contractor Proficiency Program. Proficiency report: Supplement
International Nuclear Information System (INIS)
1991-02-01
The report, a supplement to the RCP Proficiency Report, will further assist governmental officials in providing advice to the public on the selection of proficient radon mitigation contractors. These reports list 1,123 contractors who have met the requirements of the RCP Program as of December 15, 1990. The Proficiency Report provides information on each contractor's name, RCP identification number, company name, address, phone number, and geographic service area. The report provides two additional tables, indexed by company name and by RCP identification number. The report is intended to help users quickly identify a proficient contractor if only the company name is known, or to verify which contractor is associated with a particular ID number
-
National Research Council Canada - National Science Library
Granetto, Paul
1994-01-01
.... Examples of computer software costs that contractors charge through indirect rates are material management systems, security systems, labor accounting systems, and computer-aided design and manufacturing...
-
Richardson, Joshua E; Vest, Joshua R; Green, Cori M; Kern, Lisa M; Kaushal, Rainu
2015-07-01
We investigated ways that patient-centered medical homes (PCMHs) are currently using health information technology (IT) for care coordination and what types of health IT are needed to improve care coordination. A multi-disciplinary team of researchers conducted semi-structured telephone interviews with 28 participants from 3 PCMHs in the United States. Participants included administrators and clinicians from PCMHs, electronic health record (EHR) and health information exchange (HIE) representatives, and policy makers. Participants identified multiple barriers to care coordination using current health IT tools. We identified five areas in which health IT can improve care coordination in PCMHs: 1) monitoring patient populations, 2) notifying clinicians and other staff when specific patients move across care settings, 3) collaborating around patients, 4) reporting activities, and 5) interoperability. To accomplish these tasks, many participants described using homegrown care coordination systems separate from EHRs. The participants in this study have resources, experience, and expertise with using health IT for care coordination, yet they still identified multiple areas for improvement. We hypothesize that focusing health IT development in the five areas we identified can enable more effective care coordination. Key findings from this work are that homegrown systems apart from EHRs are currently used to support care coordination and, also, that reporting tools are key components of care coordination. New health IT that enables monitoring, notifying, collaborating, reporting, and interoperability would enhance care coordination within PCMHs beyond what current health IT enables. © The Author 2015. Published by Oxford University Press on behalf of the American Medical Informatics Association. All rights reserved. For Permissions, please email: journals.permissions@oup.com.
-
48 CFR 2452.251-70 - Contractor employee travel.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor employee travel... 2452.251-70 Contractor employee travel. As prescribed in 2451.7001, insert the following clause in all cost-reimbursement solicitations and contracts involving travel: Contractor Employee Travel (OCT 1999...
-
48 CFR 3036.201 - Evaluation of contractor performance.
2010-10-01
... 48 Federal Acquisition Regulations System 7 2010-10-01 2010-10-01 false Evaluation of contractor performance. 3036.201 Section 3036.201 Federal Acquisition Regulations System DEPARTMENT OF HOMELAND SECURITY... contractor performance. (a)(2) Performance reports shall be prepared and entered into the Contractor...
-
48 CFR 2152.215-70 - Contractor records retention.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor records... PRECONTRACT PROVISIONS AND CONTRACT CLAUSES Text of Provisions and Clauses 2152.215-70 Contractor records retention. As prescribed in 2115.071, insert the following clause: Contractor Records Retention (OCT 2005...
-
48 CFR 36.506 - Superintendence by the contractor.
2010-10-01
... contractor. 36.506 Section 36.506 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION... Superintendence by the contractor. The contracting officer shall insert the clause at 52.236-6, Superintendence by the Contractor, in solicitations and contracts when a fixed-price construction contract or a fixed...
-
48 CFR 1652.204-70 - Contractor records retention.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor records... of FEHBP Clauses 1652.204-70 Contractor records retention. As prescribed in 1604.705 the following clause will be inserted in all FEHB Program contracts. Contractor Records Retention (JUL 2005...
-
International Nuclear Information System (INIS)
Lackey, Michael B.; Waisley, Sandra L.; Dusek, Lansing G.
2007-01-01
Approximately $153.2 billion of work currently remains in the United States Department of Energy's (DOE's) Office of Environmental Management (EM) life cycle budget for United States projects. Contractors who manage facilities for the DOE have been challenged to identify transformational changes to reduce the life cycle costs and develop a knowledge management system that identifies, disseminates, and tracks the implementation of lessons learned and best practices. At the request of the DOE's EM Office of Engineering and Technology, the Energy Facility Contractors Group (EFCOG) responded to the challenge with formation of the Deactivation and Decommissioning (D and D) and Facility Engineering (DD/FE) Working Group. Since October 2006, members have already made significant progress in realizing their goals: adding new D and D best practices to the existing EFCOG Best Practices database; participating in lessons learned forums; and contributing to a DOE initiative on identifying technology needs. The group is also participating in a DOE project management initiative to develop implementation guidelines, as well as a DOE radiation protection initiative to institute a more predictable and standardized approach to approving authorized limits and independently verifying cleanup completion at EM sites. Finally, a D and D hotline to provide real-time solutions to D and D challenges is also being launched. (authors)
-
48 CFR 4.102 - Contractor's signature.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Contractor's signature. 4.102 Section 4.102 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION GENERAL ADMINISTRATIVE MATTERS Contract Execution 4.102 Contractor's signature. (a) Individuals. A contract with an...
-
48 CFR 253.209 - Contractor qualifications.
2010-10-01
... 48 Federal Acquisition Regulations System 3 2010-10-01 2010-10-01 false Contractor qualifications. 253.209 Section 253.209 Federal Acquisition Regulations System DEFENSE ACQUISITION REGULATIONS SYSTEM, DEPARTMENT OF DEFENSE CLAUSES AND FORMS FORMS Prescription of Forms 253.209 Contractor qualifications. ...
-
National Research Council Canada - National Science Library
1997-01-01
... over the $92 billion of Government property in the custody of contractors. After several years of planning, DoD has not developed a standard accounting system for recording, tracking, and reporting Government property in the custody of contractors...
-
VIRTUE ETHICS - NEW COORDINATES FOR ECONOMIC DEVELOPMENT
Directory of Open Access Journals (Sweden)
PUP ANCA
2010-12-01
Full Text Available Operating with business ethic we meet, some ethical systems, some of them developed in Antiquity, that still have a great influence upon economics development. One of these is the ethics of virtue. The aim of this paper work is to focus upon the one ethical system virtue ethics and to illustrate his influence in economical field, offering a new coordination in this direction. We understand the importance of the human character for a successful leadership and management. Recent ethical dilemmas illustrate us how a vicious character has an influence not only to the possessor of that type of character but also to the entire community where he develop his activities. For a comprehensive understanding I expose a briefly review on virtue ethics as it was developed by Plato and Aristotle, ant its new coordination and influence upon our contemporaneous economy, illustrated by some examples.
-
International Nuclear Information System (INIS)
1997-02-01
Low and intermediate level radioactive waste is generated from the use of radioactive materials in industrial applications, research and medicine. The waste management programmes and activities in many developing Member States have been reviewed through a Waste Management Advisory Programme (WAMAP) implemented by the IAEA in 1987-1995. One of the WAMAP objectives was to assist in practical development and implementation of safe and efficient waste treatment methods. In this context the IAEA has initiated a co-ordinated research programme on treatment technologies for institutional wastes covering the most important recurring problems in developing Member States. The programme was intended to cover the research and development required for reliable waste treatment operations, including the likely variations in institutional waste inputs using simple low cost processes. This co-ordinated research programme was initiated in 1991 and brought together 14 participants from 13 countries. The results of the studies were discussed at three research co-ordination meetings. This report summarizes the salient features and results obtained during five year investigations and provides recommendations for future work in this area. Refs, figs, tabs
-
Energy Technology Data Exchange (ETDEWEB)
NONE
1997-02-01
Low and intermediate level radioactive waste is generated from the use of radioactive materials in industrial applications, research and medicine. The waste management programmes and activities in many developing Member States have been reviewed through a Waste Management Advisory Programme (WAMAP) implemented by the IAEA in 1987-1995. One of the WAMAP objectives was to assist in practical development and implementation of safe and efficient waste treatment methods. In this context the IAEA has initiated a co-ordinated research programme on treatment technologies for institutional wastes covering the most important recurring problems in developing Member States. The programme was intended to cover the research and development required for reliable waste treatment operations, including the likely variations in institutional waste inputs using simple low cost processes. This co-ordinated research programme was initiated in 1991 and brought together 14 participants from 13 countries. The results of the studies were discussed at three research co-ordination meetings. This report summarizes the salient features and results obtained during five year investigations and provides recommendations for future work in this area. Refs, figs, tabs.
-
International Nuclear Information System (INIS)
Edgar, D.E.
1993-01-01
Argonne National Laboratory (ANL) assisted in identifying and evaluating foreign technologies to meet EM needs; supported the evaluation, removal, and/or revision of barriers to international technology and information transfer/exchange; facilitated the integration and coordination of U.S. government international environmental restoration and waste management activities; and enhanced U.S. industry's competitiveness in the international environmental technology market
-
30 CFR 875.20 - Contractor eligibility.
2010-07-01
... 30 Mineral Resources 3 2010-07-01 2010-07-01 false Contractor eligibility. 875.20 Section 875.20 Mineral Resources OFFICE OF SURFACE MINING RECLAMATION AND ENFORCEMENT, DEPARTMENT OF THE INTERIOR ABANDONED MINE LAND RECLAMATION CERTIFICATION AND NONCOAL RECLAMATION § 875.20 Contractor eligibility. Every...
-
30 CFR 874.16 - Contractor eligibility.
2010-07-01
... 30 Mineral Resources 3 2010-07-01 2010-07-01 false Contractor eligibility. 874.16 Section 874.16 Mineral Resources OFFICE OF SURFACE MINING RECLAMATION AND ENFORCEMENT, DEPARTMENT OF THE INTERIOR ABANDONED MINE LAND RECLAMATION GENERAL RECLAMATION REQUIREMENTS § 874.16 Contractor eligibility. To receive...
-
7 CFR 3015.183 - Access to contractor records.
2010-01-01
... 7 Agriculture 15 2010-01-01 2010-01-01 false Access to contractor records. 3015.183 Section 3015... contractor records. The Attachment 0 requires recipients to include in specified kinds of contracts a provision for access to the contractor's records by the recipient and the Federal government. The following...
-
Energy Materials Coordinating Committee (EMaCC): Annual technical report, Fiscal year 1987
International Nuclear Information System (INIS)
1988-09-01
The DOE Energy Materials Coordinating Committee (EMaCC) serves primarily to enhance coordination among the Department's materials programs and to further the effective use of materials expertise within the Department. These functions are accomplished through the exchange of budgetary and planning information among program managers and through technical meetings/workshops on selected topics involving both DOE and major contractors. This annual technical report is mandated by the EMaCC terms of reference. This report summarizes EMaCC activities for FY 1987 and describes the materials research programs of various offices and divisions within the Department
-
New media, old media: The technologies of international development
Ingle, Henry T.
1986-09-01
The research, theory and practice of educational technology over the past 75 years provide convincing evidence that this process offers a comprehensive and integrated approach to solving educational and social problems. The use of media and technology in development has shifted from an emphasis on mass media to personal media. A variety of electronic delivery systems are being used and are usually coordinated by centralized governmental agencies. There are no patterns of use since the problems vary and the medium used is responsive to the problem. Computers are used most frequently and satellite telecommunication networks follow. The effective use of these and other technologies requires a long-term commitment to financial support and training of personnel. The extension model of face-to-face contact still prevails in developing nations whether in agriculture, education or rural development. Low-cost technologies are being used in local projects while major regional and national companies use radio, film and related video technologies. The use of all available and cost-effective media and technologies make possible appropriate communications for specific goals with specific audiences. There appears to be no conflict among proponents of various media formats. Development in education and other sectors has much to gain from old and new communication technologies and has hardly been tapped. Several new educational technology developments are discussed as potential contributors to formal and nonformal education.
-
Problems of Technology of Energy-Saving Buildings and Their Impact on Energy Efficiency in Buildings
Kwasnowski, Pawel; Fedorczak-Cisak, Malgorzata; Knap, Katarzyna
2017-10-01
Introduction of EPBD in legislation of the EU member states caused that buildings must meet very stringent requirements of thermal protection and energy efficiency. On the basis of EPBD provisions, EU Member States introduce standard of NZEB (Nearly Zero-Energy Buildings). Such activities cause a need for new, innovative materials and technologies, and new approaches to design, construction and retrofitting of buildings. Indispensable is the precise coordination of the design of structure and technical installations of building, which may be provided in an integrated design process in the system BIM. Good coordination and cooperation of all contractors during the construction phase is also necessary. The article presents the problems and the new methodology for the design, construction and use of energy efficient buildings in terms of energy saving technologies, including discussion of the significant impact of the automation of technical installations on the building energy efficiency.
-
Directory of Open Access Journals (Sweden)
FRANKY AMBON
2012-12-01
Full Text Available Industrialised Building System (IBS is the term coined by the government and industry in Malaysia to represent the construction industry and the application of prefabrication method in building construction. The purpose of this exploratory research paper is to highlight business strategy being pursued by large Malaysian contractors in adopting IBS. The paper uses case study as research method. The analysis is based primarily on cross-case analysis and pattern matching technique. The paper observes contractors which involved in IBS are part of larger holding companies in a corporate set-up include design and manufacturing subsidiaries. The companies positioned themselves as one-stop total solution provider for IBS and offer a wider range of services from design, production, and installation to clients. To become competitive and able to create total solution, contractors need to establish cluster and consortium of integrated project team by creating a partnership when and where it is needed. A vendor development programme modelled along the lines of the development of automotive industry should also be established. Future empirical studies should extensively examine these areas, especially the development of business model for contractors. The availability of this model could help to accelerate the uptake of IBS among contractors.
-
Technical Assistance Contractor management plan. Revision 1
International Nuclear Information System (INIS)
1995-08-01
The Technical Assistance Contractor (TAC) for the Uranium Mill Tailings Remedial Action (UMTRA) Project comprises Jacobs Engineering Group Inc. (JEG) as the prime contractor and three teaming partner subcontractors: Roy F. Weston, Inc. (RFW), AGRA Earth and Environmental, Inc. (AGRA), and Geraghty and Miller, Inc. (G and M). The TAC contract's scope is to provide technical, analytical, environmental, engineering, design, inspection, and management support services to the US Department of Energy (DOE) for both Surface and Ground Water Projects. The TAC team supports the DOE in completing surface remedial action and initiating ground water remediation work for start-up, characterization, compliance planning, design, construction oversight, and remedial operations. The TAC provides the DOE UMTRA Project Team with a dedicated management, scientific, and technical resource base in Albuquerque, New Mexico, which is supplemented by corporate resources. A carefully developed and maintained staff of technical experts is available to assess, analyze, develop, and execute cost-effective solutions to the demanding technical and institutional problems presented by the UMTRA Project
-
Ho, Shih Ping; Yu, Chong Yang; Hsu, Yaowen
2017-04-01
More and more international firms in the A/E/C (Architecture/Engineering/ Construction) industries voluntarily invest in sustainable development and disclose their efforts publicly. Especially, the sustainable development efforts of the firms in Construction industry draw more attentions from the public, compared to that in A/E industries. There are various reporting systems in practice for reporting the performance of a firm's development on sustainability. The most well known reporting systems include Global Reporting Initiative (GRI), United Nations Global Compact (UNGC), and the AA1000 Accountability Principal Standards. However, most of these reporting systems are very complicated in terms of the performance indices and the categories and subcategories of these indices. It is impossible and also unnecessary for a firm to be evaluated on all the indices. However, it is also not clear on what indices are more important for a firm than other indices and why. The more fundamental questions are "what sustainable development efforts contribute more to a particular firm's competitive advantages and why?" In this research, we studied the world's top 10 contractors in ENR (Engineering News Records). We analyzed how these contractors disclose their efforts and performance in sustainable development and, most importantly, why. Lastly, based on the insights obtained from the analysis, we developed a contingency view of sustainable development and disclosure strategies. This strategic framework can be further examined from the perspective of firms' competitive advantages and give implications to how a firm's top managers should implement the firm's sustainable development program.
-
2013-10-25
... DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT [Docket No. FR-5683-N-88] 30-Day Notice of Proposed Information Collection: Contractor's Requisition--Project Mortgages AGENCY: Office of the Chief Information... Title of Information Collection: Contractor's Requisition--Project Mortgages. OMB Approval Number: 2502...
-
48 CFR 3052.204-71 - Contractor employee access.
2010-10-01
... 48 Federal Acquisition Regulations System 7 2010-10-01 2010-10-01 false Contractor employee access... CLAUSES Text of Provisions and Clauses 3052.204-71 Contractor employee access. As prescribed in (HSAR) 48...: Contractor Employee Access (JUN 2006) (a) “Sensitive Information,” as used in this Chapter, means any...
-
Legal Coordinator | IDRC - International Development Research ...
International Development Research Centre (IDRC) Digital Library (Canada)
Develops systems and procedures for administering and tracking legal undertakings, coordinates and consolidates the legal information in order to meet deadlines. • Collaborates with the Secretary and General Counsel to ensure that all legal issues are handled efficiently, while respecting the highly confidential nature of ...
-
The Professional Development of High School Chemistry Coordinators
Hofstein, Avi; Carmeli, Miriam; Shore, Relly
2004-02-01
The implementation of new content and pedagogical standards in science education necessitates intensive, long-term professional development of science teachers. In this paper, we describe the rationale and structure of a comprehensive and intensive professional development program of school-based leaders, namely school chemistry coordinators. The year-long program was designed so that the chemistry teachers who enrolled in the program were able to develop in three interrelated aspects: content knowledge, pedagogical content knowledge, and leadership ability. Several strategies for the development of these aspects were adopted from Loucks-Horsley, Hewson, Love, & Stiles (1998). The evaluation of the program focused on the changes that participating teachers underwent regarding their personal beliefs and their functioning as school chemistry coordinators in their schools.
-
Development of Modern Technologies – Is the Basis of a Sustainable Economy?
Directory of Open Access Journals (Sweden)
Andronaty N. R.
2015-08-01
Full Text Available The significance of the problem of providing technological assurance of processes is demonstrated based on examination of the development of computer technology in Moldova. Only human potential availability of well trained professionals, logistics and coordination of the whole process of the work cycle from research to production can provide a high level of quality, contribute to promoting and ensuring market competitiveness of manufactured products. It is demonstrated that there are many areas that require the use of computer systems, including analog and digital specialized electronic machines. Providing conditions for the evolution of new technologies and their development is the most important prerequisite for sustainable economic development.
-
Determinants of contractor pricing strategy
Moses, O. Douglas
1988-01-01
This paper investigates pricing strategies used by major defense contractors. Two pricing strategies are identified and discussed: penetration, which calls for a relatively low initial price followed by little reduction in price over time, and skimming, which calls for a relatively high initial price coupled with greater reduction in price over time. It is argued that contractor pricing strategy will depend on features of the defense program under consideration and featur...
-
2013-07-30
... DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT [Docket No. FR-5687-N-34] 60-Day Notice of Proposed Information Collection: Contractor's Requisition--Project Mortgages AGENCY: Office of the Assistant Secretary... Section A. A. Overview of Information Collection Title of Information Collection: Contractor's Requisition...
-
DOE contractor radiation safety CBT [computer based training] course
International Nuclear Information System (INIS)
Gardner, P.R.
1986-01-01
Westinghouse Hanford Company developed a generic Radiation Worker safety CBT course for Department of Energy contractors. Task analysis concentrated on actual and potential tasks and included visits to fourteen different contractor sites. Team Design and Prototype verification formed the major portion of the development phase. Lesson entry was accomplished using the WISE author system from WICAT Systems, Inc. The course features graded task simulations for both Pretest and Final; fourteen Topics in five Lessons, each Topic keyed to ''Critical Acts'' and Questions in the Pretest and Final; Automatic, Intensive, and Manual modes of instruction available for each Lesson; Practical Problems and Sample Questions associated with each Topic; and provisions for local configuration in several areas. The course is deliverable on IBM PC compatible equipment. 2 refs
-
International Nuclear Information System (INIS)
Wellman, Dawn M.; Triplett, Mark B.; Freshley, Mark D.; Truex, Michael J.; Gephart, Roy E.; Johnson, Timothy C.; Chronister, Glen B.; Gerdes, Kurt D.; Chamberlain, Skip; Marble, Justin; Ramirez, Rosa
2011-01-01
DOE-EM, Office of Groundwater and Soil Remediation and DOE Richland, in collaboration with the Hanford site and Pacific Northwest National Laboratory, have established the Deep Vadose Zone Applied Field Research Center (DVZ-AFRC). The DVZ-AFRC leverages DOE investments in basic science from the Office of Science, applied research from DOE EM Office of Technology Innovation and Development, and site operation (e.g., site contractors [CH2M HILL Plateau Remediation Contractor and Washington River Protection Solutions], DOE-EM RL and ORP) in a collaborative effort to address the complex region of the deep vadose zone. Although the aim, goal, motivation, and contractual obligation of each organization is different, the integration of these activities into the framework of the DVZ-AFRC brings the resources and creativity of many to provide sites with viable alternative remedial strategies to current baseline approaches for persistent contaminants and deep vadose zone contamination. This cooperative strategy removes stove pipes, prevents duplication of efforts, maximizes resources, and facilitates development of the scientific foundation needed to make sound and defensible remedial decisions that will successfully meet the target cleanup goals for one of DOE EM's most intractable problems, in a manner that is acceptable by regulators.
-
Exploration Life Support Technology Development for Lunar Missions
Ewert, Michael K.; Barta, Daniel J.; McQuillan, Jeffrey
2009-01-01
Exploration Life Support (ELS) is one of NASA's Exploration Technology Development Projects. ELS plans, coordinates and implements the development of new life support technologies for human exploration missions as outlined in NASA's Vision for Space Exploration. ELS technology development currently supports three major projects of the Constellation Program - the Orion Crew Exploration Vehicle (CEV), the Altair Lunar Lander and Lunar Surface Systems. ELS content includes Air Revitalization Systems (ARS), Water Recovery Systems (WRS), Waste Management Systems (WMS), Habitation Engineering, Systems Integration, Modeling and Analysis (SIMA), and Validation and Testing. The primary goal of the ELS project is to provide different technology options to Constellation which fill gaps or provide substantial improvements over the state-of-the-art in life support systems. Since the Constellation missions are so challenging, mass, power, and volume must be reduced from Space Shuttle and Space Station technologies. Systems engineering analysis also optimizes the overall architecture by considering all interfaces with the life support system and potential for reduction or reuse of resources. For long duration missions, technologies which aid in closure of air and water loops with increased reliability are essential as well as techniques to minimize or deal with waste. The ELS project utilizes in-house efforts at five NASA centers, aerospace industry contracts, Small Business Innovative Research contracts and other means to develop advanced life support technologies. Testing, analysis and reduced gravity flight experiments are also conducted at the NASA field centers. This paper gives a current status of technologies under development by ELS and relates them to the Constellation customers who will eventually use them.
-
Methodology Development for Assessment of Spaceport Technology Returns and Risks
Joglekar, Prafulla; Zapata, Edgar
2001-01-01
As part of Kennedy Space Center's (KSC's) challenge to open the space frontier, new spaceport technologies must be developed, matured and successfully transitioned to operational systems. R&D investment decisions can be considered from multiple perspectives. Near mid and far term technology horizons must be understood. Because a multitude of technology investment opportunities are available, we must identify choices that promise the greatest likelihood of significant lifecycle At the same time, the costs and risks of any choice must be well understood and balanced against its potential returns The problem is not one of simply rank- ordering projects in terms of their desirability. KSC wants to determine a portfolio of projects that simultaneously satisfies multiple goals, such as getting the biggest bang for the buck, supporting projects that may be too risky for private funding, staying within annual budget cycles without foregoing the requirements of a long term technology vision, and ensuring the development of a diversity of technologies that, support the variety of operational functions involved in space transportation. This work aims to assist in the development of in methods and techniques that support strategic technology investment decisions and ease the process of determining an optimal portfolio of spaceport R&D investments. Available literature on risks and returns to R&D is reviewed and most useful pieces are brought to the attention of the Spaceport Technology Development Office (STDO). KSC's current project management procedures are reviewed. It is found that the "one size fits all" nature of KSC's existing procedures and project selection criteria is not conducive to prudent decision-making. Directions for improving KSC's - procedures and criteria are outlined. With help of a contractor, STDO is currently developing a tool, named Change Management Analysis Tool (CMAT)/ Portfolio Analysis Tool (PAT), to assist KSC's R&D portfolio determination. A
-
International Nuclear Information System (INIS)
2001-12-01
The Co-ordinated Research Project (CRP) on Radiotracer Technology for Engineering Unit Operation Studies and Unit Process Optimization was carried out by the International Atomic Energy Agency (IAEA) from December 1997 until December 2000. The project developed and validated procedures and protocols for investigation of major industrial processes, including fluidized beds, sugar crystallizers, trickle bed reactors, cement rotary kilns, flotation cells, grinding mills, incinerators, wastewater treatment units and interwell communications in oil fields. This publication is the output of the above mentioned CRP. It provides the principles and state of the art of radiotracer methodology and technology as applied to industry and environment. It is expected to provide wider interest for further development of skills and confidence prior to carrying out field work. It facilitates transfer of technology from developed to developing countries and from nuclear research institutions to industrial end users. The publication could be a suitable guide for radiotracer applications in almost all types of process investigations. The case studies described in this publication deal with typical problems in industry and environment common to all countries. It is intended for radiotracer groups as well as for end engineers and managers from chemical and petrochemical industries, mineral ore and raw material processing, wastewater treatment plants, and other industrial sectors
-
Insulation coordination workstation for AC and DC substations
International Nuclear Information System (INIS)
Booth, R.R.; Hileman, A.R.
1990-01-01
The Insulation Coordination Workstation was designed to aid the substation design engineer in the insulation coordination process. The workstation utilizes state of the art computer technology to present a set of tools necessary for substation insulation coordination, and to support the decision making process for all aspects of insulation coordination. The workstation is currently being developed for personal computers supporting OS/2 Presentation Manager. Modern Computer-Aided Software Engineering (CASE) technology was utilized to create an easily expandable framework which currently consists of four modules, each accessing a central application database. The heart of the workstation is a library of user-friendly application programs for the calculation of important voltage stresses used for the evaluation of insulation coordination. The Oneline Diagram is a graphic interface for data entry into the EPRI distributed EMTP program, which allows the creation of complex systems on the CRT screen using simple mouse clicks and keyboard entries. Station shielding is graphically represented in the Geographic Viewport using a three-dimensional substation model, and the interactive plotting package allows plotting of EPRI EMTP output results on the CRT screen, printer, or pen plotter. The Insulation Coordination Workstation was designed by Advanced Systems Technology (AST), a division of ABB Power Systems, Inc., and sponsored by the Electric Power Research Institute under RP 2323-5, AC/DC Insulation Coordination Workstation
-
International Nuclear Information System (INIS)
Emoto, Masahiko; Yoshida, Masanobu; Suzuki, Chihiro; Suzuki, Yasuhiro; Ida, Katsumi; Nagayama, Yoshio; Akiyama, Tsuyoshi; Kawahata, Kazuo; Narihara, Kazumichi; Tokuzawa, Tokihiko; Yamada, Ichihiro
2012-01-01
Highlights: ► We have developed a mapping system of the electron temperature profile to the flux coordinates. ► To increases the performance, multiple virtual machines are used. ► The virtual machine technology is flexible when increasing the number of computers. - Abstract: This paper presents a system called “TSMAP” that maps electron temperature profiles to flux coordinates for the Large Helical Device (LHD). Considering the flux surface is isothermal, TSMAP searches an equilibrium database for the LHD equilibrium that fits the electron temperature profile. The equilibrium database is built through many VMEC computations of the helical equilibria. Because the number of equilibria is large, the most important technical issue for realizing the TSMAP system is computational performance. Therefore, we use multiple personal computers to enhance performance when building the database for TSMAP. We use virtual machines on multiple Linux computers to run the TSMAP program. Virtual machine technology is flexible, allowing the number of computers to be easily increased. This paper discusses how the use of virtual machine technology enhances the performance of TSMAP calculations when multiple CPU cores are used.
-
10 CFR 719.42 - What types of field actions must be coordinated with Headquarters?
2010-01-01
... 10 Energy 4 2010-01-01 2010-01-01 false What types of field actions must be coordinated with Headquarters? 719.42 Section 719.42 Energy DEPARTMENT OF ENERGY CONTRACTOR LEGAL MANAGEMENT REQUIREMENTS... adverse decisions, where legal issues of first impression, sensitive issues, issues of significance to the...
-
48 CFR 1852.242-73 - NASA contractor financial management reporting.
2010-10-01
... Provisions and Clauses 1852.242-73 NASA contractor financial management reporting. As prescribed in 1842.7202, insert the following clause: NASA Contractor Financial Management Reporting (NOV 2004) (a) The Contractor... instructions in NASA Procedures and Guidelines (NPR) 9501.2, NASA Contractor Financial Management Reporting...
-
78 FR 46783 - Federal Acquisition Regulation; Documenting Contractor Performance
2013-08-01
..., Sequence 1] RIN 9000-AM09 Federal Acquisition Regulation; Documenting Contractor Performance AGENCY... the Contractor Performance Assessment Reporting System (CPARS), the single Governmentwide past... Procurement Policy (OFPP) memorandum entitled ``Improving the Use of Contractor Performance Information...
-
Private Security Contractors in Darfur
DEFF Research Database (Denmark)
Leander, Anna
2006-01-01
This article argues that the role of Private Security Contractors in Darfur reflects and reinforces neo-liberal governmentality in contemporary security governance. It is an argument (in line with other articles in this special issue) which is more interested in discussing how the privatization....... It underlines that governance is increasingly taking place through a set of (quasi-) markets, it is marked by entrepreneurial values, and a hands off approach to governance. We then discuss the way this overall change is reflected in and reinforced by the role of private security contractors in Darfur. Drawing...... at these processes is necessary to understand the role of private security contractors in Darfur. But more than this, practices in Darfur entrench neo-liberal governmentality in security more generally. The managerial and `de-politicizing' approach to security in Darfur displaces alternative views not only...
-
Co-ordination Action on Ocean Energy (CA-OE)
DEFF Research Database (Denmark)
Tedd, James; Frigaard, Peter
In October 2004, the Co-ordination Action on Ocean Energy (CA-OE) was launched, co-financed by the European Commission, under the Renewable Energy Technologies priority within the 6th Framework programme, contract number 502701, chaired by Kim Nielsen, Rambøll, Denmark. The project involves 41...... partners. In general the public is not aware of the development of ocean energy and its exploitation. There is a need to make a united effort from the developers and research community to present the various principles and results in a coordinated manner with public appeal. The main objectives of the Co......-ordination Action on Ocean Energy are: To develop a common knowledge base necessary for coherent research and development policiesTo bring a co-ordinated approach within key areas of ocean energy research and development.To provide a forum for the longer term marketing of promising research developments...
-
Technology road mapping to guide development planning
International Nuclear Information System (INIS)
Goossen, J.E.; Congedo, T.V.
2004-01-01
For the past five years, Westinghouse Electric Company, has made ever increasing use of Technology Road Mapping, to direct company development efforts to achieve maximum benefits for our customers and ourselves. Comprised of business units in Nuclear Fuels, Nuclear Services and Nuclear Power Plants, including domestic and international business segments, Westinghouse must pay particular attention to coordinating development to satisfy the diverse needs of our growing international customer base. We must develop products which both benefit the individual Business Unit customer base, and which create synergy to produce the best possible offerings to the broader marketplace. The knowledge we gain through customer contacts and direct customer participation provides the basis from which we develop the Technology Road Map. This Road Map development process can be compared to painting a picture, where the background colors and features correspond to drivers related to the Customer and the prevailing features of the market environment. The subsequent layers of detail include broad Technical Objectives and then specific Technical Goals which will support achieving those objectives. The process is described in detail, and examples are provided. (authors)
-
76 FR 37704 - Federal Acquisition Regulation; Documenting Contractor Performance
2011-06-28
... Federal Acquisition Regulation; Documenting Contractor Performance AGENCY: Department of Defense (DoD..., and to require all past performance information be entered into the Contractor Performance Assessment... Contractor Performance Information. These changes provide Governmentwide standardized evaluation factors and...
-
Financial management of construction contractors.
Lacaria, Chris J.
1994-01-01
The scope of this paper is to discuss the financial management of a construction contractor. This paper attempts to approach this subject in a logical and systematic way. It communicates the importance of financial analysis and planning along with cash planning and profit planning. This report is not intended to be an all inclusive discussion of financial management in construction. Contractor's Financial Management is an extremely important subject. It has been told ...
-
A guide for heating contractor; Opas laempoeyrittaejaelle
Energy Technology Data Exchange (ETDEWEB)
Solmio, H; Tuomi, S; Valkonen, J
1996-12-31
Heating contractor is eg. a forest owner, who is responsible for the heating of a commune owned school using firewood purchased from the contractor`s own forests. This is a new alternative for entrepreneurship in the countryside. This guide has been meant as an aid for persons starting heating contraction. It is supposed to be of importance for the designers of the communal energy supply, for advisors and instructors, as well as for those already started the heating contraction. The guide discusses the following topics: Why to became a heating contractor; The ways of heating contraction; operational requirements; Contracts; Conversion of a boiler plant to wood fuels; Fuel purchase; Heating work; Profitably estimation; Examples of operational solutions. The guide also includes as an example a draft contract for heating contraction
-
National Radon Contractor Proficiency Program. Proficiency report, October 1990
International Nuclear Information System (INIS)
1990-10-01
The report lists those individual contractors in the United States who have met the requirements of the Radon Contractor Proficiency (RCP) Program as of August 18, 1990. These requirements are designed to provide minimum proficiency criteria for individuals who design and supervise the installation of radon mitigation systems in buildings. (Some States have more stringent requirements as part of their radon certification programs. The States should be consulted directly for details on their programs; see Section 5 for a list of State radon contacts). The RCP Program measures the proficiency of an individual contractor, not their company. Therefore, users of the report who select a mitigation firm should ensure that the services are provided by the listed contractor. The National RCP Program does not accredit mitigation contractors, nor does it certify, recommend, or endorse participating companies. Only the listed contractor, not their company of affilation, are deemed proficient. The inclusion of a contractor in the report should not be interpreted as a certification or accreditation of the individual or affiliated company
-
Brayton Isotope Power System (BIPS). Phase I: Integrated Program Plan (IPP). Report 75-311574A
International Nuclear Information System (INIS)
1976-01-01
The government, AIRPHX, AIRLA, and contractor BIPS program coordination efforts are discussed. These coordination efforts are essential for defining program objectives, and achieving these objectives in an efficient manner. The IPP outlines a long range effort intended to: (a) develop end product confidence; (b) identify government and contractor activities pertinent and contributory to BIPS development; (c) recommend government and contractor activities required to ensure BIPS program success; (d) establish activity priorities based on program cost and schedule impacts, and achievement of technical objectives; (e) coordinate the efforts of contributing agencies; (f) provide general information and, to a limited extent, BIPS program-related development activity status to interested individuals and agencies; and (g) provide contractor team program planning guidance
-
Begum, Rawshan Ara; Siwar, Chamhuri; Pereira, Joy Jacqueline; Jaafar, Abdul Hamid
2007-01-01
Malaysia is facing an increase in the generation of waste and of accompanying problems with the disposal of this waste. In the last two decades, extensive building and infrastructure development projects have led to an increase in the generation of construction waste material. The construction industry has a substantial impact on the environment, and its environmental effects are in direct relation to the quality and quantity of the waste it generates. This paper discusses general characteristics of the construction contractors, the contractors' willingness to pay (WTP) for improved construction waste management, determining factors which affect the amount of their willingness to pay, and suggestions and policy implications in the perspective of construction waste management in Malaysia. The data in this study is based on contractors registered with the construction industry development board (CIDB) of Malaysia. Employing the open ended contingent valuation method, the study assessed the contractors' average maximum WTP for improved construction waste management to be RM69.88 (1US$=3.6 RM) per tonne of waste. The result shows that the average maximum WTP is higher for large contractors than for medium and small contractors. The highest average maximum WTP value is RM88.00 for Group A (large contractors) RM78.25 for Group B (medium-size contractors) and RM55.80 for Group C (small contractors). One of the contributions of this study is to highlight the difference of CIDB registration grade in the WTP for improved construction waste management. It is found that contractors' WTP for improved waste collection and disposal services increases with the increase in contractors' current paid up capital. The identified factors and determinants of the WTP will assist the formulation of appropriate policies in addressing the construction waste problem in Malaysia and indirectly improve the quality of construction in the country.
-
TECHNICAL AND ECONOMICAL ANALYSIS OF LOGGING CONTRACTORS
Directory of Open Access Journals (Sweden)
Abilio Donizetti de Morais Filho
2009-09-01
Full Text Available The objective of this study was to describe the financial conditions of forestry contractors, concerning life quality aspects, condition of work and equipments, operational costs, and economic credit to invest in new technologies. Five companies had been analyzed, with an annual income between US$ 400,000.00 and US$ 1,720,000.00, with an average of US$ 950,000.00. The number of employees varied between 33 and 181, and the companies were classified in terms of size as: one small, two average, and two big. The main difficulties to invest in new machines were high financial taxes, more than 12% an year, and a lack of long term contracts to guarantee the payment capability. It was observed that the contractors did not consider the capital remuneration and a correct depreciation of machines, resulting in an average machine life higher than 10 years. The final conclusions were that the costs were above the paid values for the services, when computed the depreciation and capital remuneration, with negative results in the financial analyzes of three companies. Finally, the mechanization process increased the workers life quality, however, the annual income was around US$ 2,112.00 per worker, approximately 39% lower than the average Brazilian population.
-
Coordinating Management Activities in Distributed Software Development Projects
Bendeck, Fawsy; Goldmann, Sigrid; Holz, Harald; Kötting, Boris
1999-01-01
Coordinating distributed processes, especially engineering and software design processes, has been a research topic for some time now. Several approaches have been published that aim at coordinating large projects in general, and large software development processes in specific. However, most of these approaches focus on the technical part of the design process and omit management activities like planning and scheduling the project, or monitoring it during execution. In this paper, we focus o...
-
77 FR 6676 - Office of Inspector General; Contractor Requirements
2012-02-09
... POSTAL SERVICE 39 CFR Part 230 Office of Inspector General; Contractor Requirements AGENCY: Postal... for contractors employed by the Office of Inspector General. The rule also emphasizes consistency in contractor selection, and clarifies the OIG's exclusive authority to set qualifications and standards for its...
-
2010-04-01
... 24 Housing and Urban Development 4 2010-04-01 2010-04-01 false What prohibitions on the use of debarred, suspended, or ineligible contractors apply? 1000.44 Section 1000.44 Housing and Urban Development... § 1000.44 What prohibitions on the use of debarred, suspended, or ineligible contractors apply? In...
-
Energy Materials Coordinating Committee (EMaCC) Fiscal Year 1999 annual technical report
Energy Technology Data Exchange (ETDEWEB)
None
2000-10-31
The DOE Energy Materials Coordinating Committee (EMaCC) serves primarily to enhance coordination among the Department`s materials programs and to further effective use of materials expertise within the Department. These functions are accomplished through the exchange of budgetary and planning information among program managers and through technical meetings/workshops on selected topics involving both DOE and major contractors. In addition, EMaCC assists in obtaining materials-related inputs for both intra- and interagency compilations. This report summarizes EMaCC activities for FY 1999 and describes the materials research programs of various offices and divisions within the Department.
-
1996-01-01
This report presents some of the challenging research and technology accomplished at NASA Ames Research Center during FY95. The accomplishments address almost all goals of NASA's four Strategic Enterprises: Aeronautics and Space Transportation Technology, Space Sciences, Human Exploration and Development of Space, and Mission to Planet Earth. The report's primary purpose is to inform stakeholders, customers, partners, colleagues, contractors, employees, and the American people in general about the scope and diversity of the research and technology activities. Additionally, the report will enable the reader to know how these goals are being addressed.
-
48 CFR 970.0407 - Contractor records retention.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor records retention. 970.0407 Section 970.0407 Federal Acquisition Regulations System DEPARTMENT OF ENERGY AGENCY SUPPLEMENTARY REGULATIONS DOE MANAGEMENT AND OPERATING CONTRACTS Administrative Matters 970.0407 Contractor...
-
48 CFR 227.7108 - Contractor data repositories.
2010-10-01
... repositories. 227.7108 Section 227.7108 Federal Acquisition Regulations System DEFENSE ACQUISITION REGULATIONS... Technical Data 227.7108 Contractor data repositories. (a) Contractor data repositories may be established when permitted by agency procedures. The contractual instrument establishing the data repository must...
-
77 FR 12754 - Contractor Legal Management Requirements; Acquisition Regulations
2012-03-02
... DEPARTMENT OF ENERGY 10 CFR Part 719 48 Parts 931, 952 and 970 RIN 1990-AA37 Contractor Legal... rulemaking (NOPR) to revise existing regulations covering contractor legal management requirements and make... relating to the DOE notice of proposed rulemaking to revise existing regulations covering contractor legal...
-
48 CFR 1252.237-70 - Qualifications of contractor employees.
2010-10-01
... contractor employees. 1252.237-70 Section 1252.237-70 Federal Acquisition Regulations System DEPARTMENT OF....237-70 Qualifications of contractor employees. As prescribed in (TAR) 48 CFR 1237.110(a), insert the following clause: Qualifications of Contractor Employees (APR 2005) a. Definitions. As used in this clause...
-
48 CFR 2452.237-75 - Clearance of contractor personnel.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Clearance of contractor... Clauses 2452.237-75 Clearance of contractor personnel. As prescribed in 2437.110(e), insert the following clause in solicitations and contracts. Clearance of Contractor Personnel (OCT 1999) (a) General. This...
-
Technical Assistance Contractor management plan. Revision 1
Energy Technology Data Exchange (ETDEWEB)
NONE
1995-08-01
The Technical Assistance Contractor (TAC) for the Uranium Mill Tailings Remedial Action (UMTRA) Project comprises Jacobs Engineering Group Inc. (JEG) as the prime contractor and three teaming partner subcontractors: Roy F. Weston, Inc. (RFW), AGRA Earth and Environmental, Inc. (AGRA), and Geraghty and Miller, Inc. (G and M). The TAC contract`s scope is to provide technical, analytical, environmental, engineering, design, inspection, and management support services to the US Department of Energy (DOE) for both Surface and Ground Water Projects. The TAC team supports the DOE in completing surface remedial action and initiating ground water remediation work for start-up, characterization, compliance planning, design, construction oversight, and remedial operations. The TAC provides the DOE UMTRA Project Team with a dedicated management, scientific, and technical resource base in Albuquerque, New Mexico, which is supplemented by corporate resources. A carefully developed and maintained staff of technical experts is available to assess, analyze, develop, and execute cost-effective solutions to the demanding technical and institutional problems presented by the UMTRA Project.
-
Self-Defense Distributed Engagement Coordinator
2016-02-01
Distributed Engagement Coordinator MIT Lincoln Laboratory helped develop a unique decision support tool that automatically evaluates responses to...Laboratory researchers collaborated with scientists from the Operations Research Center at MIT’s Sloan School of Management to apply modern computational...epidemic. A Technology Solution MIT Lincoln Laboratory, in collaboration with the Office of Naval Research (ONR), has developed an automated
-
Directory of Open Access Journals (Sweden)
Ru Liang
2018-01-01
Full Text Available The magnitude of business dynamics has increased rapidly due to increased complexity, uncertainty, and risk of large-scale infrastructure projects. This fact made it increasingly tough to “go alone” into a contractor. As a consequence, joint venture contractors with diverse strengths and weaknesses cooperatively bid for bidding. Understanding project complexity and making decision on the optimal joint venture contractor is challenging. This paper is to study how to select joint venture contractors for undertaking large-scale infrastructure projects based on a multiattribute mathematical model. Two different methods are developed to solve the problem. One is based on ideal points and the other one is based on balanced ideal advantages. Both of the two methods consider individual difference in expert judgment and contractor attributes. A case study of Hong Kong-Zhuhai-Macao-Bridge (HZMB project in China is used to demonstrate how to apply these two methods and their advantages.
-
76 FR 81408 - Contractor Legal Management Requirements; Acquisition Regulations
2011-12-28
... DEPARTMENT OF ENERGY 10 CFR Part 719 48 CFR Parts 931, 952 and 970 RIN 1990-AA37 Contractor Legal... Energy (DOE or Department) is proposing to revise existing regulations covering contractor legal... costs by certain contractors whose contracts exceed $100,000,000 as well as legal counsel retained...
-
78 FR 25795 - Contractor Legal Management Requirements; Acquisition Regulations
2013-05-03
... DEPARTMENT OF ENERGY 10 CFR Part 719 48 CFR Parts 931, 952, and 970 RIN 1990-AA37 Contractor Legal.... ACTION: Final rule. SUMMARY: The Department of Energy revises existing regulations covering contractor... costs by certain contractors whose contracts exceed $100,000,000 as well as legal counsel retained...
-
48 CFR 52.236-6 - Superintendence by the Contractor.
2010-10-01
... Contractor. 52.236-6 Section 52.236-6 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION....236-6 Superintendence by the Contractor. As prescribed in 36.506, insert the following clause: Superintendence by the Contractor (APR 1984) At all times during performance of this contract and until the work...
-
Development of an International School Nurse Asthma Care Coordination Model
Garwick, Ann W.; Svavarsdóttir, Erla Kolbrun; Seppelt, Ann M.; Looman, Wendy S.; Anderson, Lori S.; Örlygsdóttir, Brynja
2015-01-01
Aim To identify and compare how school nurses in Reykjavik, Iceland and St. Paul, Minnesota coordinated care for youth with asthma (ages 10–18) and to develop an asthma school nurse care coordination model. Background Little is known about how school nurses coordinate care for youth with asthma in different countries. Design A qualitative descriptive study design using focus group data. Methods Six focus groups with 32 school nurses were conducted in Reykjavik (n=17) and St. Paul (n=15) using the same protocol between September 2008 – January 2009. Descriptive content analytic and constant comparison strategies were used to categorize and compare how school nurses coordinated care, which resulted in the development of an International School Nurse Asthma Care Coordination Model. Findings Participants in both countries spontaneously described a similar asthma care coordination process that involved information gathering, assessing risk for asthma episodes, prioritizing health care needs and anticipating and planning for student needs at the individual and school levels. This process informed how they individualized symptom management, case management and/or asthma education. School nurses played a pivotal part in collaborating with families, school and health care professionals to ensure quality care for youth with asthma. Conclusions Results indicate a high level of complexity in school nurses’ approaches to asthma care coordination that were responsive to the diverse and changing needs of students in school settings. The conceptual model derived provides a framework for investigators to use in examining the asthma care coordination process of school nurses in other geographic locations. PMID:25223389
-
Development of an International School Nurse Asthma Care Coordination Model.
Garwick, Ann W; Svavarsdóttir, Erla Kolbrun; Seppelt, Ann M; Looman, Wendy S; Anderson, Lori S; Örlygsdóttir, Brynja
2015-03-01
To identify and compare how school nurses in Reykjavik, Iceland and St. Paul, Minnesota coordinated care for youth with asthma (ages 10-18) and to develop an asthma school nurse care coordination model. Little is known about how school nurses coordinate care for youth with asthma in different countries. A qualitative descriptive study design using focus group data. Six focus groups with 32 school nurses were conducted in Reykjavik (n = 17) and St. Paul (n = 15) using the same protocol between September 2008 and January 2009. Descriptive content analytic and constant comparison strategies were used to categorize and compare how school nurses coordinated care, which resulted in the development of an International School Nurse Asthma Care Coordination Model. Participants in both countries spontaneously described a similar asthma care coordination process that involved information gathering, assessing risk for asthma episodes, prioritizing healthcare needs and anticipating and planning for student needs at the individual and school levels. This process informed how they individualized symptom management, case management and/or asthma education. School nurses played a pivotal part in collaborating with families, school and healthcare professionals to ensure quality care for youth with asthma. Results indicate a high level of complexity in school nurses' approaches to asthma care coordination that were responsive to the diverse and changing needs of students in school settings. The conceptual model derived provides a framework for investigators to use in examining the asthma care coordination process of school nurses in other geographic locations. © 2014 John Wiley & Sons Ltd.
-
The Design Co-ordination Framework: key elements for effective product development
DEFF Research Database (Denmark)
Andreasen, Mogens Myrup; Bowen, J.; Storm, T.
1997-01-01
This paper proposes a Design Co-ordination Framework (DCF) i.e. a concept for an ideal DC system with the abilities to support co-ordination of various complex aspects of product development. A set of frames, modelling key elements of co-ordination, which reflect the states of design, plans, orga...
-
76 FR 31416 - Federal Acquisition Regulation; Oversight of Contractor Ethics Programs
2011-05-31
...-AL92 Federal Acquisition Regulation; Oversight of Contractor Ethics Programs AGENCY: Department of... that contractors have implemented the mandatory contractor business ethics program requirements. DATES... to Improve DoD's Oversight of Contractor Ethics Programs. The ethics program requirement flows from...
-
48 CFR 1437.7001 - Contractor qualification requirements.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Contractor qualification requirements. 1437.7001 Section 1437.7001 Federal Acquisition Regulations System DEPARTMENT OF THE INTERIOR... Contractor qualification requirements. (a) Prior to award of a contract for real property appraisal services...
-
Smith, Nanette R.
1995-01-01
The objective of this summer's work was to attempt to enhance Technology Application Group (TAG) ability to measure the outcomes of its efforts to transfer NASA technology. By reviewing existing literature, by explaining the economic principles involved in evaluating the economic impact of technology transfer, and by investigating the LaRC processes our William & Mary team has been able to lead this important discussion. In reviewing the existing literature, we identified many of the metrics that are currently being used in the area of technology transfer. Learning about the LaRC technology transfer processes and the metrics currently used to track the transfer process enabled us to compare other R&D facilities to LaRC. We discuss and diagram impacts of technology transfer in the short run and the long run. Significantly, it serves as the basis for analysis and provides guidance in thinking about what the measurement objectives ought to be. By focusing on the SBIR Program, valuable information regarding the strengths and weaknesses of this LaRC program are to be gained. A survey was developed to ask probing questions regarding SBIR contractors' experience with the program. Specifically we are interested in finding out whether the SBIR Program is accomplishing its mission, if the SBIR companies are providing the needed innovations specified by NASA and to what extent those innovations have led to commercial success. We also developed a survey to ask COTR's, who are NASA employees acting as technical advisors to the SBIR contractors, the same type of questions, evaluating the successes and problems with the SBIR Program as they see it. This survey was developed to be implemented interactively on computer. It is our hope that the statistical and econometric studies that can be done on the data collected from all of these sources will provide insight regarding the direction to take in developing systematic evaluations of programs like the SBIR Program so that they can
-
14 CFR 1274.402 - Contractor acquired property.
2010-01-01
... 14 Aeronautics and Space 5 2010-01-01 2010-01-01 false Contractor acquired property. 1274.402 Section 1274.402 Aeronautics and Space NATIONAL AERONAUTICS AND SPACE ADMINISTRATION COOPERATIVE AGREEMENTS WITH COMMERCIAL FIRMS Property § 1274.402 Contractor acquired property. As provided in § 1274.923...
-
48 CFR 1646.301 - Contractor inspection requirements.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor inspection requirements. 1646.301 Section 1646.301 Federal Acquisition Regulations System OFFICE OF PERSONNEL MANAGEMENT... Clauses 1646.301 Contractor inspection requirements. The clause set forth at 1652.246-70 shall be inserted...
-
48 CFR 645.608 - Screening of contractor inventory.
2010-10-01
... inventory. 645.608 Section 645.608 Federal Acquisition Regulations System DEPARTMENT OF STATE CONTRACT MANAGEMENT GOVERNMENT PROPERTY Reporting, Redistribution, and Disposal of Contractor Inventory 645.608 Screening of contractor inventory. ...
-
2010-02-09
... DEPARTMENT OF HEALTH AND HUMAN SERVICES Office of the National Coordinator for Health Information Technology; HIT Policy Committee's Adoption/Certification Workgroup Meeting; Notice of Meeting AGENCY: Office... of Committee: HIT Policy Committee's Adoption/Certification Workgroup. General Function of the...
-
Program plan for research and development in support of LWR fuel recycle
International Nuclear Information System (INIS)
1975-01-01
The ERDA program that is being planned to assist industry in the commercialization of the LWR fuel cycle will involve a range of activities, including joint programs with industry, R and D to provide technology, conceptual design of fuel recycle facilities, and environmental and economic assessments. A two-part program to begin in 1976 that is a portion of the overall ERDA plan is described. Responsibility for coordination and management of the tasks described in this document has been assigned to Du Pont as prime contractor to the ERDA Savannah River Operations Office. The first part of the program consists of the conceptual design of complete recycle facilities. The second part of the program, which will proceed concurrently, consists of supporting R and D activities, economic and environmental studies, and other studies to assist in the regulatory process. The R and D program will include both near-term activities in support of the conceptual design effort, and other activities aimed at general improvements in fuel cycle technology. The conceptual design will be used to develop current cost information for a complete reprocessing complex. The design will be based initially on current technology with provision for improvements as confirmatory information and advanced technology become available from the R and D program. The conceptual design and cost estimate will be developed by the Du Pont Atomic Energy Division. The R and D program and supporting studies will be directed at uncertainties in current technology as well as toward development of improved technology. It will include such R and D as might be appropriate for ERDA to undertake in support of joint programs with industry. The Savannah River Laboratory will have responsibility for coordinating the program
-
International Nuclear Information System (INIS)
Mazur, A.B.; Ermolenko, A.I.; Shaptala, D.V.; Postil, S.D.; Yachmenev, V.V.
1999-01-01
Integrated system of spatial coordinates was developed for modeling of diverse processes occurring in the exclusion zone. Technology of joint use of CAD and geoinformation system was worked out,which resulted in the 'Ukryttia' object fixing to the topographic base in accordance with geographic coordinates, editing of nomenclative sheets of the area adjacent to the ChNPP and renovation of its relief, as well as conversion of the files made in AutoCad to Arc View format files was performed
-
Rantz, Marilyn; Lane, Kari; Phillips, Lorraine J; Despins, Laurel A; Galambos, Colleen; Alexander, Gregory L; Koopman, Richelle J; Hicks, Lanis; Skubic, Marjorie; Miller, Steven J
2015-01-01
When planning the Aging in Place Initiative at TigerPlace, it was envisioned that advances in technology research had the potential to enable early intervention in health changes that could assist in proactive management of health for older adults and potentially reduce costs. The purpose of this study was to compare length of stay (LOS) of residents living with environmentally embedded sensor systems since the development and implementation of automated health alerts at TigerPlace to LOS of those who are not living with sensor systems. Estimate potential savings of living with sensor systems. LOS for residents living with and without sensors was measured over a span of 4.8 years since the implementation of sensor-generated health alerts. The group living with sensors (n = 52) had an average LOS of 1,557 days (4.3 years); the comparison group without sensors (n = 81) was 936 days (2.6 years); p = .0006. Groups were comparable based on admission age, gender, number of chronic illnesses, SF12 physical health, SF12 mental health, Geriatric Depression Scale (GDS), activities of daily living, independent activities of daily living, and mini-mental status examination scores. Both groups, all residents living at TigerPlace since the implementation of health alerts, receive registered nurse (RN) care coordination as the standard of care. Results indicate that residents living with sensors were able to reside at TigerPlace 1.7 years longer than residents living without sensors, suggesting that proactive use of health alerts facilitates successful aging in place. Health alerts, generated by automated algorithms interpreting environmentally embedded sensor data, may enable care coordinators to assess and intervene on health status changes earlier than is possible in the absence of sensor-generated alerts. Comparison of LOS without sensors TigerPlace (2.6 years) with the national median in residential senior housing (1.8 years) may be attributable to the RN care coordination
-
Contractors on the Battlefield: Planning Considerations and Requirements
National Research Council Canada - National Science Library
2002-01-01
Contractors on the Battlefield: Planning Considerations and Requirements introduces the basics and foundation for those who want to learn about the history, terminology, and process for obtaining contractor support on the battlefield...
-
Convergent microRNA actions coordinate neocortical development.
Barca-Mayo, Olga; De Pietri Tonelli, Davide
2014-08-01
Neocortical development is a complex process that, at the cellular level, involves tight control of self-renewal, cell fate commitment, survival, differentiation and delamination/migration. These processes require, at the molecular level, the precise regulation of intrinsic signaling pathways and extrinsic factors with coordinated action in a spatially and temporally specific manner. Transcriptional regulation plays an important role during corticogenesis; however, microRNAs (miRNAs) are emerging as important post-transcriptional regulators of various aspects of central nervous system development. miRNAs are a class of small, single-stranded noncoding RNA molecules that control the expression of the majority of protein coding genes (i.e., targets). How do different miRNAs achieve precise control of gene networks during neocortical development? Here, we critically review all the miRNA-target interactions validated in vivo, with relevance to the generation and migration of pyramidal-projection glutamatergic neurons, and for the initial formation of cortical layers in the embryonic development of rodent neocortex. In particular, we focus on convergent miRNA actions, which are still a poorly understood layer of complexity in miRNA signaling, but potentially one of the keys to disclosing how miRNAs achieve the precise coordination of complex biological processes such as neocortical development.
-
78 FR 1256 - Guam Military Base Realignment Contractor Recruitment Standards
2013-01-08
... Contractor Recruitment Standards AGENCY: Employment and Training Administration, Labor. ACTION: Final notice... issuing this notice to announce recruitment standards that construction contractors are required to follow... B) by adding a new subsection (6). This provision prohibits contractors engaged in construction...
-
77 FR 3503 - Guam Military Base Realignment Contractor Recruitment Standards
2012-01-24
... Contractor Recruitment Standards AGENCY: Employment and Training Administration, Labor. ACTION: Notice... issuing this notice to announce the recruitment standards that construction contractors are required to... contractors engaged in construction projects related to the realignment of U.S. military forces from Okinawa...
-
Coordination of flower development by homeotic master regulators.
Ito, Toshiro
2011-02-01
Floral homeotic genes encode transcription factors and act as master regulators of flower development. The homeotic protein complex is expressed in a specific whorl of the floral primordium and determines floral organ identity by the combinatorial action. Homeotic proteins continue to be expressed until late in flower development to coordinate growth and organogenesis. Recent genomic studies have shown that homeotic proteins bind thousands of target sites in the genome and regulate the expression of transcription factors, chromatin components and various proteins involved in hormone biosynthesis and signaling and other physiological activities. Further, homeotic proteins program chromatin to direct the developmental coordination of stem cell maintenance and differentiation in shaping floral organs. Copyright © 2010 Elsevier Ltd. All rights reserved.
-
New Possibilities for Technology Development in the Auspices of Low-Emission EU Strategy
International Nuclear Information System (INIS)
Car, S.; Jelavic, V.
2016-01-01
United Nations Framework Convention on Climate Change has elevated the level of responsibility of the international community for implementation of measures for climate preservation and CO2 reduction. After the Paris Agreement, the base for carrying out the measures lies in the following: contribution to emissions reduction determined on a national level, establishing new platforms for energy management based on low-emission development, new technological and economy development and technology transfer. European Development Fund is an opportunity for accelerating the technological development of Croatian economy and to coordinate it with EU low-emission strategy, taking into account the advanced specialization economy strategy which was recently approved by the EC and adopted in the Parliament. Technological development, based on available local resources, new technologies, innovations and global market, is a basis of a long-term sustainable development and it is expected that it will be supported not just from the EU funds but also with local fiscal and other measures. Visions for development of some technologies will be shown, as well as examples of new possibilities for Croatian electro industry that is already present on the global market and only confirms the possibility and necessity of such technological development.(author).
-
A Case Study of Coordination in Distributed Agile Software Development
Hole, Steinar; Moe, Nils Brede
Global Software Development (GSD) has gained significant popularity as an emerging paradigm. Companies also show interest in applying agile approaches in distributed development to combine the advantages of both approaches. However, in their most radical forms, agile and GSD can be placed in each end of a plan-based/agile spectrum because of how work is coordinated. We describe how three GSD projects applying agile methods coordinate their work. We found that trust is needed to reduce the need of standardization and direct supervision when coordinating work in a GSD project, and that electronic chatting supports mutual adjustment. Further, co-location and modularization mitigates communication problems, enables agility in at least part of a GSD project, and renders the implementation of Scrum of Scrums possible.
-
International Nuclear Information System (INIS)
2008-10-01
There are dozens of old reactors and other nuclear facilities worldwide that are either being actively dismantled or are candidates for decommissioning in the near term. A significant proportion of these facilities are situated in Member States or institutions that do not have adequate expertise and technologies for planning and implementing state of the art decommissioning projects. The technology selection process is critical in that regard. The main objective of the IAEA technical activities on decommissioning is to promote the exchange of lessons learned in order to improve the technologies, thereby contributing to successful planning and implementation of decommissioning. This should be achieved through a better understanding of the decision making process in technology comparison and selection and relevant issues affecting the entire decommissioning process. The specific objectives of the Coordinated Research Project (CRP) on Innovative and Adaptive Technologies in Decommissioning of Nuclear Facilities include the following general aspects: (a) To establish methodologies and data needs for developing concepts and approaches relevant to technology comparison and selection in decommissioning; (b) To improve and expand the database on applications and performance of various types of decommissioning technologies; (c) To address specific issues for individual decommissioning technologies and generate data relevant to their comparison and selection. It is also expected that this project, and in particular the papers collected in this TECDOC, will draw Member States' attention to the practicality and achievability of timely planning and implementation of decommissioning, especially for many smaller projects. Concluding reports that summarized the work undertaken under the aegis of the CRP were presented at the third and final research coordination meeting held in Rez, Czech Republic, 3-7 December 2007, and collected in this technical publication. Operating
-
48 CFR 1403.570 - Restrictions on contractor advertising.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Restrictions on contractor advertising. 1403.570 Section 1403.570 Federal Acquisition Regulations System DEPARTMENT OF THE INTERIOR... 1403.570 Restrictions on contractor advertising. ...
-
Directory of Open Access Journals (Sweden)
E. N. Dotsenko
2013-08-01
Full Text Available Purpose. To analyze the problem of motor abilities development and health of students of special medical group in the process of physical education in technical universities. Determine the major factors, characteristics, and the relationship of physical development, physical fitness and coordination abilities of female students in special medical group. Establish regularities in precise movements mastering of different coordination structure and develop model characteristics of the relationship of coordination abilities and motor characteristics of students in special medical group. To substantiate and verify efficiency of coordination abilities development method of female students with regard to their functional status in the course of physical education in higher school. Methodology. Theoretical and methodological argument, characteristic of the experimental program in physical education teaching process of students in special medical group was shown. Findings. Research is to develop the training content in special medical groups with the use of coordinating elements and exercises to enhance the motor abilities of female students. Their influence on the level of physical development, functional training, as well as regularities in mastering and movement control of different coordinating structure at the female students of special medical group was studied. The comparative characteristic of female students athletic ability in the dynamics of the educational process, differentiated into groups according to nosology was presented. The criterion of spare capacities upgrade of the motor system in controlling the movements of different coordination structure was determined. Originality. The method of coordination abilities development of female students in special medical group, that aims on the formation and correction of motor control system of different coordination structure, a sense of body position and its individual parts in space, improving
-
76 FR 48776 - Federal Acquisition Regulation; Documenting Contractor Performance; Correction
2011-08-09
... Regulation; Documenting Contractor Performance; Correction AGENCY: Department of Defense (DoD), General... published in the Federal Register of June 28, 2011, regarding the proposed rule for Documenting Contractor... published in the Federal Register of June 28, 2011, regarding the proposed rule for Documenting Contractor...
-
42 CFR 405.874 - Appeals of CMS or a CMS contractor.
2010-10-01
... 42 Public Health 2 2010-10-01 2010-10-01 false Appeals of CMS or a CMS contractor. 405.874 Section... Part B Program § 405.874 Appeals of CMS or a CMS contractor. A CMS contractor's (that is, a carrier... supplier enrollment application. If CMS or a CMS contractor denies a provider's or supplier's enrollment...
-
DOE contractor trade network: a decade of experience in training resource exchange
International Nuclear Information System (INIS)
Croll, P.; Weseman, M.
1989-01-01
Training Resources and Data Exchange (TRADE) refers to a series of activities designed to increase communication and exchanges of ideas, information, and resources among US Department of Energy contractor operated facilities in the field of training and human resource development. TRADE activities are planned and implemented by the DOE Contractor TRADE Executive Committee. TRADE objectives are accomplished through conference workshops, publications, and special interest groups. TRADE special interest groups include the following: computer-based training, emergency preparedness, industrial hygiene training, human resource issues, radiation protection training, safeguards and security training. The authors discuss how TRADE has evolved to meet changing contractor needs to improve human performance over the last 10 years. TRADE currently has working agreements to share training information with INPO, the Federal Laboratories Consortium, and the National Registry of Radiation Protection Technologists
-
Core science and technology development plan for indirect-drive ICF ignition. Revision 1
Energy Technology Data Exchange (ETDEWEB)
Powell, H.T.; Kilkenny, J.D. [eds.
1995-12-01
To define the development work needed to support inertial confinement fusion (ICF) program goals, the authors have assembled this Core Science and Technology (CS and T) Plan that encompasses nearly all science research and technology development in the ICF program. The objective of the CS and T Plan described here is to identify the development work needed to ensure the success of advanced ICF facilities, in particular the National Ignition Facility (NIF). This plan is intended as a framework to facilitate planning and coordination of future ICF programmatic activities. The CS and T Plan covers all elements of the ICF program including laser technology, optic manufacturing, target chamber, target diagnostics, target design and theory, target components and fabrication, and target physics experiments. The CS and T Plan has been divided into these seven different technology development areas, and they are used as level-1 categories in a work breakdown structure (WBS) to facilitate the organization of all activities in this plan. The scope of the CS and T Plan includes all research and development required to support the NIF leading up to the activation and initial operation as an indirect-drive facility. In each of the CS and T main development areas, the authors describe the technology and issues that need to be addressed to achieve NIF performance goals. To resolve all issues and achieve objectives, an extensive assortment of tasks must be performed in a coordinated and timely manner. The authors describe these activities and present planning schedules that detail the flow of work to be performed over a 10-year period corresponding to estimated time needed to demonstrate fusion ignition with the NIF. Besides the benefits to the ICF program, the authors also discuss how the commercial sector and the nuclear weapons science may profit from the proposed research and development program.
-
Core science and technology development plan for indirect-drive ICF ignition. Revision 1
International Nuclear Information System (INIS)
Powell, H.T.; Kilkenny, J.D.
1995-12-01
To define the development work needed to support inertial confinement fusion (ICF) program goals, the authors have assembled this Core Science and Technology (CS and T) Plan that encompasses nearly all science research and technology development in the ICF program. The objective of the CS and T Plan described here is to identify the development work needed to ensure the success of advanced ICF facilities, in particular the National Ignition Facility (NIF). This plan is intended as a framework to facilitate planning and coordination of future ICF programmatic activities. The CS and T Plan covers all elements of the ICF program including laser technology, optic manufacturing, target chamber, target diagnostics, target design and theory, target components and fabrication, and target physics experiments. The CS and T Plan has been divided into these seven different technology development areas, and they are used as level-1 categories in a work breakdown structure (WBS) to facilitate the organization of all activities in this plan. The scope of the CS and T Plan includes all research and development required to support the NIF leading up to the activation and initial operation as an indirect-drive facility. In each of the CS and T main development areas, the authors describe the technology and issues that need to be addressed to achieve NIF performance goals. To resolve all issues and achieve objectives, an extensive assortment of tasks must be performed in a coordinated and timely manner. The authors describe these activities and present planning schedules that detail the flow of work to be performed over a 10-year period corresponding to estimated time needed to demonstrate fusion ignition with the NIF. Besides the benefits to the ICF program, the authors also discuss how the commercial sector and the nuclear weapons science may profit from the proposed research and development program
-
Theoretical and methodical going near development of coordinating capabilities of young people
Directory of Open Access Journals (Sweden)
Kolumbet A.N.
2012-04-01
Full Text Available An estimation over of positions of conception of coordination and coordinating capabilities is brought in the field of theory of physical education. Data of modern scientific literature on development and perfection of coordinating capabilities are considered. It is shown approaches according to classifications. The further ways of development of motive coordinations of young people are certain. An analysis over is brought 177 publications of domestic and foreign scientists and researchers. Find data allow to establish that now there is enough accumulated material which allows to step over the traditional aspects of pedagogical process of mastering the man of motive abilities and skills
-
Roadmaps for the Development of Technologies Related to Danish Wave Power Systems
DEFF Research Database (Denmark)
Nielsen, Kim; Krogh, Jan; Brodersen, H. J.
2015-01-01
seconded by offshore industry, and research institutions. The Danish Partnership for Wave Power has further been consolidated through the follow-on Roadmap project described in this paper. The roadmap project has in detail investigated how the four most common technology areas for wave power developers can...... of coordinating and focus the research, development and test activities. The aim is that the resources (financial and know-how) are used appropriately and with the greatest possible progress. Within each of the 4 areas, the starting point is based on the state of the art technology, and the roadmaps outline what...
-
Agencies Need Improved Financial Data Reporting for Private Security Contractors
National Research Council Canada - National Science Library
Warren, David R; Bianco, Michael A; Nasser, Waheed; Kusman, Richard R; Shafer, James; Venner, Jason; Walls, Lovell Q; Wright, Samson J
2008-01-01
Section 842 of the National Defense Authorization Act of 2008 (Public Law 110-181), required SIGIR to, among other things, develop a plan to evaluate various characteristics of contracting for private security contractor services in Iraq...
-
48 CFR 2804.470 - Contractor Personnel Security Program.
2010-10-01
... 48 Federal Acquisition Regulations System 6 2010-10-01 2010-10-01 true Contractor Personnel Security Program. 2804.470 Section 2804.470 Federal Acquisition Regulations System DEPARTMENT OF JUSTICE General ADMINISTRATIVE MATTERS Safeguarding Classified Information Within Industry 2804.470 Contractor...
-
Crosscutting Technology Development at the Center for Advanced Separation Technologies
Energy Technology Data Exchange (ETDEWEB)
Christopher Hull
2009-10-31
The U.S. is the largest producer of mining products in the world. In 2003, U.S. mining operations produced $57 billion worth of raw materials that contributed a total of $564 billion to the nation's wealth. Despite these contributions, the mining industry has not been well supported with research and development funds as compared to mining industries in other countries. To overcome this problem, the Center for Advanced Separation Technologies (CAST) was established to develop technologies that can be used by the U.S. mining industry to create new products, reduce production costs, and meet environmental regulations. Originally set up by Virginia Tech and West Virginia University, this endeavor has been expanded into a seven-university consortium -- Virginia Tech, West Virginia University, University of Kentucky, University of Utah, Montana Tech, New Mexico Tech and University of Nevada, Reno - that is supported through U.S. DOE Cooperative Agreement No. DE-FC26-02NT41607: Crosscutting Technology Development at the Center for Advanced Separation Technologies. Much of the research to be conducted with Cooperative Agreement funds will be longer-term, high-risk, basic research and will be carried out in five broad areas: (1) Solid-solid separation; (2) Solid-liquid separation; (3) Chemical/biological extraction; (4) Modeling and control; and (5) Environmental control. Distribution of funds is handled via competitive solicitation of research proposals through Site Coordinators at the seven member universities. These were first reviewed and ranked by a group of technical reviewers (selected primarily from industry). Based on these reviews, and an assessment of overall program requirements, the CAST Technical Committee made an initial selection/ranking of proposals and forwarded these to the DOE/NETL Project Officer for final review and approval. The successful projects are listed by category, along with brief abstracts of their aims and objectives.
-
International Nuclear Information System (INIS)
2006-01-01
The objectives of this CRP are to evaluate various generator and concentration technologies for 188 W- 188 Re, 99 Mo- 99 mTc and 90 Sr- 90 Y generators, to optimize generator fabrication and use, to standardize quality control techniques for the eluted radionuclides and to provide standardized procedures to participating laboratories. The following issues will be addressed during the CRP. - Development of reproducible methodologies for the preparation of 188 W- 188 Re, 99 Mo- 99 mTc and 90 Sr- 90 Y generators. - Development and evaluation of chromatography adsorbents (Zr/Ti composites) having higher binding capacities and demonstration of their utility in the preparation of column generators for 188 Re and 99 mTc. - Comparison and optimization of technologies for post elution concentration of 188 Re and 99 mTc in order to improve the radioactive concentration. - Development of quality control techniques and specifications for generator eluted therapeutic radionuclides
-
Waste isolation safety assessment program. Task 4. Third contractor information meeting
International Nuclear Information System (INIS)
1980-06-01
The Contractor Information Meeting (October 14 to 17, 1979) was part of the FY-1979 effort of Task 4 of the Waste Isolation Safety Assessment Program (WISAP): Sorption/Desorption Analysis. The objectives of this task are to: evaluate sorption/desorption measurement methods and develop a standardized measurement procedure; produce a generic data bank of nuclide-geologic interactions using a wide variety of geologic media and groundwaters; perform statistical analysis and synthesis of these data; perform validation studies to compare short-term laboratory studies to long-term in situ behavior; develop a fundamental understanding of sorption/desorption processes; produce x-ray and gamma-emitting isotopes suitable for the study of actinides at tracer concentrations; disseminate resulting information to the international technical community; and provide input data support for repository safety assessment. Conference participants included those subcontracted to WISAP Task 4, representatives and independent subcontractors to the Office of Nuclear Waste Isolation, representatives from other waste disposal programs, and experts in the area of waste/geologic media interaction. Since the meeting, WISAP has been divided into two programs: Assessment of Effectiveness of Geologic Isolation Systems (AEGIS) (modeling efforts) and Waste/Rock Interactions Technology (WRIT) (experimental work). The WRIT program encompasses the work conducted under Task 4. This report contains the information presented at the Task 4, Third Contractor Information Meeting. Technical Reports from the subcontractors, as well as Pacific Northwest Laboratory (PNL), are provided along with transcripts of the question-and-answer sessions. The agenda and abstracts of the presentations are also included. Appendix A is a list of the participants. Appendix B gives an overview of the WRIT program and details the WRIT work breakdown structure for 1980
-
Waste isolation safety assessment program. Task 4. Third contractor information meeting
Energy Technology Data Exchange (ETDEWEB)
1980-06-01
The Contractor Information Meeting (October 14 to 17, 1979) was part of the FY-1979 effort of Task 4 of the Waste Isolation Safety Assessment Program (WISAP): Sorption/Desorption Analysis. The objectives of this task are to: evaluate sorption/desorption measurement methods and develop a standardized measurement procedure; produce a generic data bank of nuclide-geologic interactions using a wide variety of geologic media and groundwaters; perform statistical analysis and synthesis of these data; perform validation studies to compare short-term laboratory studies to long-term in situ behavior; develop a fundamental understanding of sorption/desorption processes; produce x-ray and gamma-emitting isotopes suitable for the study of actinides at tracer concentrations; disseminate resulting information to the international technical community; and provide input data support for repository safety assessment. Conference participants included those subcontracted to WISAP Task 4, representatives and independent subcontractors to the Office of Nuclear Waste Isolation, representatives from other waste disposal programs, and experts in the area of waste/geologic media interaction. Since the meeting, WISAP has been divided into two programs: Assessment of Effectiveness of Geologic Isolation Systems (AEGIS) (modeling efforts) and Waste/Rock Interactions Technology (WRIT) (experimental work). The WRIT program encompasses the work conducted under Task 4. This report contains the information presented at the Task 4, Third Contractor Information Meeting. Technical Reports from the subcontractors, as well as Pacific Northwest Laboratory (PNL), are provided along with transcripts of the question-and-answer sessions. The agenda and abstracts of the presentations are also included. Appendix A is a list of the participants. Appendix B gives an overview of the WRIT program and details the WRIT work breakdown structure for 1980.
-
29 CFR 500.60 - Farm labor contractors' recruitment, contractual and general obligations.
2010-07-01
... labor contractors' recruitment, contractual and general obligations. The Act imposes certain specific recruitment, contractual and general obligations on farm labor contractors and farm labor contractor employees... 29 Labor 3 2010-07-01 2010-07-01 false Farm labor contractors' recruitment, contractual and...
-
Directory of Open Access Journals (Sweden)
Wenxia Zhai
2017-06-01
Full Text Available The relationship between transportation infrastructure investment and regional economic growth has been the focus of domestic and foreign academic research. Using the models of coupling degree and coupling coordination degree, this paper calculated the coupling degree and coupling coordination degree between the comprehensive level of transportation infrastructure investment and economic development in Hubei province and its 17 cities, and analyzed its temporal and spatial characteristics. The result showed that, from 2001 to 2013, the coupling and coupling coordination between transportation infrastructure investment and economic development in Hubei province were on a steady rise in the time sequence characteristics. It experienced the upgrade from the uncoordinated – nearly uncoordinated – barely coordinated – intermediately coordinated stages. In the year of 2013, the coupling and coupling coordination of transportation infrastructure investment and economic development in the 17 prefecture-level cities of Hubei Province showed a very uneven spatial difference. Good coordination, primary coordination, barely coordinate, and barely in-coordination are distributed in the province. The average coordination degree of the 17 prefecture-level cities in Hubei is relatively low, and there is a negative tend to expand the difference. This study has confirmed the relationship between transportation infrastructure investment and the economic development to be in an interactive coupling and coordination, but in different regions and different stages, the degree of coordination has obvious spatial and temporal differences.
-
Nuclear-Renewable Hybrid Energy Systems: 2016 Technology Development Program Plan
International Nuclear Information System (INIS)
Bragg-Sitton, Shannon M.; Boardman, Richard; Rabiti, Cristian; Suk Kim, Jong; McKellar, Michael; Sabharwall, Piyush; Chen, Jun; Cetiner, M. Sacit; Harrison, T. Jay; Qualls, A. Lou
2016-01-01
The United States is in the midst of an energy revolution, spurred by advancement of technology to produce unprecedented supplies of oil and natural gas. Simultaneously, there is an increasing concern for climate change attributed to greenhouse gas (GHG) emissions that, in large part, result from burning fossil fuels. An international consensus has concluded that the U.S. and other developed nations have an imperative to reduce GHG emissions to address these climate change concerns. The global desire to reduce GHG emissions has led to the development and deployment of clean energy resources and technologies, particularly renewable energy technologies, at a rapid rate. At the same time, each of the major energy sectors-the electric grid, industrial manufacturing, transportation, and the residential/commercial consumers- is increasingly becoming linked through information and communications technologies, advanced modeling and simulation, and controls. Coordination of clean energy generation technologies through integrated hybrid energy systems, as defined below, has the potential to further revolutionize energy services at the system level by coordinating the exchange of energy currency among the energy sectors in a manner that optimizes financial efficiency (including capital investments), maximizes thermodynamic efficiency (through best use of exergy, which is the potential to use the available energy in producing energy services), reduces environmental impacts when clean energy inputs are maximized, and provides resources for grid management. Rapid buildout of renewable technologies has been largely driven by local, state, and federal policies, such as renewable portfolio standards and production tax credits that incentivize investment in these generation sources. A foundational assumption within this program plan is that renewable technologies will continue to be major contributors to the future U.S. energy infrastructure. While increased use of clean renewable
-
Nuclear-Renewable Hybrid Energy Systems: 2016 Technology Development Program Plan
Energy Technology Data Exchange (ETDEWEB)
Bragg-Sitton, Shannon M. [Idaho National Lab. (INL), Idaho Falls, ID (United States); Boardman, Richard [Idaho National Lab. (INL), Idaho Falls, ID (United States); Rabiti, Cristian [Idaho National Lab. (INL), Idaho Falls, ID (United States); Suk Kim, Jong [Idaho National Lab. (INL), Idaho Falls, ID (United States); McKellar, Michael [Idaho National Lab. (INL), Idaho Falls, ID (United States); Sabharwall, Piyush [Idaho National Lab. (INL), Idaho Falls, ID (United States); Chen, Jun [Idaho National Lab. (INL), Idaho Falls, ID (United States); Cetiner, M. Sacit [Oak Ridge National Lab. (ORNL), Oak Ridge, TN (United States); Harrison, T. Jay [Oak Ridge National Lab. (ORNL), Oak Ridge, TN (United States); Qualls, A. Lou [Oak Ridge National Lab. (ORNL), Oak Ridge, TN (United States)
2016-03-01
The United States is in the midst of an energy revolution, spurred by advancement of technology to produce unprecedented supplies of oil and natural gas. Simultaneously, there is an increasing concern for climate change attributed to greenhouse gas (GHG) emissions that, in large part, result from burning fossil fuels. An international consensus has concluded that the U.S. and other developed nations have an imperative to reduce GHG emissions to address these climate change concerns. The global desire to reduce GHG emissions has led to the development and deployment of clean energy resources and technologies, particularly renewable energy technologies, at a rapid rate. At the same time, each of the major energy sectors—the electric grid, industrial manufacturing, transportation, and the residential/commercial consumers— is increasingly becoming linked through information and communications technologies, advanced modeling and simulation, and controls. Coordination of clean energy generation technologies through integrated hybrid energy systems, as defined below, has the potential to further revolutionize energy services at the system level by coordinating the exchange of energy currency among the energy sectors in a manner that optimizes financial efficiency (including capital investments), maximizes thermodynamic efficiency (through best use of exergy, which is the potential to use the available energy in producing energy services), reduces environmental impacts when clean energy inputs are maximized, and provides resources for grid management. Rapid buildout of renewable technologies has been largely driven by local, state, and federal policies, such as renewable portfolio standards and production tax credits that incentivize investment in these generation sources. A foundational assumption within this program plan is that renewable technologies will continue to be major contributors to the future U.S. energy infrastructure. While increased use of clean
-
Considerations on technology transfer process in nuclear power industry for developing countries
International Nuclear Information System (INIS)
Castro, I.P.
2000-01-01
Nuclear know-how cannot possibly be developed globally in developing countries, so technology transfer is the only conceivable way to make nuclear power accessible to these countries. Technology transfer process accounts for three mayor steps, namely acquisition, assimilation and diffusion, so a serious nuclear power program should comprise all of them. Substantial national efforts should be made by developing countries in financial, industrial, scientific, organizational and many other aspects in order to succeed a profitable technology transfer, but developing countries cannot make it by themselves. Finance is the biggest problem for developing world nuclear power projects. Human resource qualification is another important aspect of the nuclear power technology transfer, where technology receptor countries should prepare thousands of professionals in domestic and foreign schools. Challenge for nuclear power deployment is economical, but also social and political. Developed countries should be open to cooperate with developing countries in meeting their needs for nuclear power deployment that should be stimulated and coordinated by an international body which should serve as mediator for nuclear power technology transfer. This process must be carried out on the basis of mutual benefits, in which the developed world can exploit the fast growing market of energy in the developing world, but with the necessary condition of the previous preparation of our countries for this technology transfer. (author)
-
Energy Technology Data Exchange (ETDEWEB)
NONE
1999-12-01
This technological development is intended to develop a process technology to dispose adequately of air bags convergently when they are removed from waste cars, with consideration paid on environmental and safety aspects. This technology that can dispose of air bags remaining as air bag modules (ABM) in large quantity and adequately can solve the problems of maloperation in opening them in cars and noise in conventional disposal methods. The recovery and disposal system using an inflator can be expected of reducing work load on dismantling contractors and enhancing the work safety. Furthermore, the energy saving process utilizing combustion of plastics can save resources. However, this technology has not elucidated how dioxins, dust, smoke, sulfides, and nitrogen oxides are generated and how the generation can be prevented. Therefore, an exhaust gas dioxin testing facility and an exhaust gas treating facility were installed additionally to the existing heating treatment facility to develop a disposal technology to treat adequately the exhaust gases generated when ABMs are disposed conveergently in large quantity, and treat the waste water discharged from the facilities. Fiscal 1998 has performed preliminary tests to accumulate fundamental data, and design and installation of the above two facilities. (NEDO)
-
Selection and assessment of contractors; Auswahl und Beurteilung von Auftragnehmerfirmen
Energy Technology Data Exchange (ETDEWEB)
Lier, K.H. [ExxonMobil Production Deutschland GmbH, Hannover (Germany)
2007-09-13
Reliable and efficient contractors are important for the activities of ExxonMobil. Qualification of contractors is to ensure that contractors provide technical services in accordance with the specifications of ExxonMobil. Apart from the financial, oranisational and legal qualification this covers technical qualification, i.e. industrial safety, health protection and environmental protection, as well as technical efficiency and quality. The ultimate intention is to find out if contractors have the processes and systems at their disposal that are required for the services. The qualification process is described. (orig.)
-
Technical assistance contractor management plan: Surface and ground water
International Nuclear Information System (INIS)
1994-09-01
This report presents the general management structure of the Technical Assistance Contractor (TAC) for the Uranium Mill Tailings Remedial Action (UMTRA) Project. This team is a partnership of four major private subcontractors, which teamed together, are striving to be the leader in environmental restoration of uranium mining and milling operations. It will provide a pool of experts in various aspects of the technologies necessary to accomplish this goal, available to DOE to deal with mission concerns. The report expands on goals from TAC's mission statement, which include management concerns, environment, safety, and health, quality, technical support, communications, and personnel
-
Technical assistance contractor management plan: Surface and ground water
Energy Technology Data Exchange (ETDEWEB)
1994-09-01
This report presents the general management structure of the Technical Assistance Contractor (TAC) for the Uranium Mill Tailings Remedial Action (UMTRA) Project. This team is a partnership of four major private subcontractors, which teamed together, are striving to be the leader in environmental restoration of uranium mining and milling operations. It will provide a pool of experts in various aspects of the technologies necessary to accomplish this goal, available to DOE to deal with mission concerns. The report expands on goals from TAC`s mission statement, which include management concerns, environment, safety, and health, quality, technical support, communications, and personnel.
-
Directory of Open Access Journals (Sweden)
P. Wang
2018-04-01
Full Text Available In the image plane of GB-SAR, identification of deformation distribution is usually carried out by artificial interpretation. This method requires analysts to have adequate experience of radar imaging and target recognition, otherwise it can easily cause false recognition of deformation target or region. Therefore, it is very meaningful to connect two-dimensional (2D plane coordinate system with the common three-dimensional (3D terrain coordinate system. To improve the global accuracy and reliability of the transformation from 2D coordinates of GB-SAR images to local 3D coordinates, and overcome the limitation of traditional similarity transformation parameter estimation method, 3D laser scanning data is used to assist the transformation of GB-SAR image coordinates. A straight line fitting method for calculating horizontal angle was proposed in this paper. After projection into a consistent imaging plane, we can calculate horizontal rotation angle by using the linear characteristics of the structure in radar image and the 3D coordinate system. Aided by external elevation information by 3D laser scanning technology, we completed the matching of point clouds and pixels on the projection plane according to the geometric projection principle of GB-SAR imaging realizing the transformation calculation of GB-SAR image coordinates to local 3D coordinates. Finally, the effectiveness of the method is verified by the GB-SAR deformation monitoring experiment on the high slope of Geheyan dam.
-
Wang, P.; Xing, C.
2018-04-01
In the image plane of GB-SAR, identification of deformation distribution is usually carried out by artificial interpretation. This method requires analysts to have adequate experience of radar imaging and target recognition, otherwise it can easily cause false recognition of deformation target or region. Therefore, it is very meaningful to connect two-dimensional (2D) plane coordinate system with the common three-dimensional (3D) terrain coordinate system. To improve the global accuracy and reliability of the transformation from 2D coordinates of GB-SAR images to local 3D coordinates, and overcome the limitation of traditional similarity transformation parameter estimation method, 3D laser scanning data is used to assist the transformation of GB-SAR image coordinates. A straight line fitting method for calculating horizontal angle was proposed in this paper. After projection into a consistent imaging plane, we can calculate horizontal rotation angle by using the linear characteristics of the structure in radar image and the 3D coordinate system. Aided by external elevation information by 3D laser scanning technology, we completed the matching of point clouds and pixels on the projection plane according to the geometric projection principle of GB-SAR imaging realizing the transformation calculation of GB-SAR image coordinates to local 3D coordinates. Finally, the effectiveness of the method is verified by the GB-SAR deformation monitoring experiment on the high slope of Geheyan dam.
-
RCRA permitting strategies for the development of innovative technologies: Lessons from Hanford
International Nuclear Information System (INIS)
Gajewski, S.W.; Donaghue, J.F.
1994-01-01
The Hanford Site restoration is the largest waste cleanup operation in history. The Hanford plutonium production mission generated two-thirds of all the nuclear waste, by volume, in the Department of Energy (DOE) Complex. Cleanup challenges include not only large stored volumes of radioactive, hazardous, and mixed waste, but contaminated soil and groundwater and scores of major structures slated for decontamination, decommissioning, and demolition. DOE and its contractors will need to invent the technology required to do the job on a timetable driven by negotiated milestones, public concerns, and budgetary constraints. This paper will discuss the effort at Hanford to develop an integrated, streamlined strategy for compliance with the Resource Conservation and Recovery Act (RCRA) and the Comprehensive Environmental Response, Compensation and Liability Act (CERCLA) in the conduct of research, development, and demonstration (RD ampersand D) of innovative cleanup technologies. The aspects that will be discussed include the following: the genesis of the RD ampersand D permitting challenge at Hanford; permitting options in the existing regulatory framework; regulatory options that offered the best fit for Hanford RD ampersand D activities, and the problems associated with them; and conclusions and recommendations made to regulatory bodies
-
International Nuclear Information System (INIS)
2007-01-01
To meet expressed Member States' needs, the IAEA has initiated a Coordinated Research Project (CRP) on 'Studies of Advanced Reactor Technology Options for Effective Incineration of Radioactive Waste'. The final goal of the CRP is to deepen the understanding of the dynamics of transmutation systems, e.g. the accelerator driven system, especially systems with deteriorated safety parameters, qualify the available methods, specify the range of validity of methods, and formulate requirements for future theoretical developments. Should transient experiments be available, the CRP will pursue experimental benchmarking work. In any case, based on the results, the CRP will conclude on the potential need of transient experiments and make appropriate proposals for experimental programs. The Technical Meeting in Chennai was the 3rd Research Coordination Meeting (RCM) of the CRP The man objectives of the RCM were to: - Discuss and perform inter-comparisons of the various benchmark results; - Prepare the first draft of the final CRP Report Status of the analyses and inter-comparisons of the results. The main objective of the CRP was to study innovative technology options for incinerating/utilizing radioactive wastes. The CRP's benchmarking exercises focused on eight innovative transmutation 'Domains', which correspond to different critical and sub-critical concepts or groups of concepts: I. Critical fast reactor, solid fuel, with fertile; II. Critical fast reactor, solid fuel, fertile-free; III. ADS, solid fuel, with fertile; IV. ADS, solid fuel, fertile-free; V. Critical reactor and ADS, molten salt fuel, with fertile; VI. Critical reactor and ADS, molten salt fuel, fertile-free; VII. Critical fast reactor and ADS, gas cooled; VIII. Fusion/fission hybrid system. For each of these Domains, the discussions and inter-comparisons considered the following issues: - Reactor-models; - Scenarios/phenomena; - Static analyses; - Dynamic analyses; - Methods; - Codes; - Neutronic data base
-
Contractor Selection for Enhancing the Quality of University ...
African Journals Online (AJOL)
Contractor Selection for Enhancing the Quality of University Education in Nigeria using the Hamming Distance. DEA Omorogbe, SO Aibieyi. Abstract. The need for contractor selection in our university education system cannot be over emphasized. And applying scientific techniques for appropriateness and accuracy in the ...
-
48 CFR 36.201 - Evaluation of contractor performance.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Evaluation of contractor performance. 36.201 Section 36.201 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION... Contracting for Construction 36.201 Evaluation of contractor performance. See 42.1502(e) for the requirements...
-
48 CFR 49.405 - Completion by another contractor.
2010-10-01
... 48 Federal Acquisition Regulations System 1 2010-10-01 2010-10-01 false Completion by another contractor. 49.405 Section 49.405 Federal Acquisition Regulations System FEDERAL ACQUISITION REGULATION... contractor. If the surety does not arrange for completion of the contract, the contracting officer normally...
-
Fiscal Liability of State Contractors
Directory of Open Access Journals (Sweden)
Santiago Fajardo-Peña
2017-06-01
Full Text Available The State contract is one of the most important tools for public management. The formation, execution and liquidation of State contracts are also a potential cause of State patrimonial damages. Perhaps for this reason, many State contractors are prosecuted as if they were public spending managers. The question, however, is not as simple. The fiscal liability process has a qualified recipient: the fiscal manager. In this article, through a conceptual exposition and a case study, we identify the criterion for determining in which cases a State contractor acquires the function of controlling public funds and when he/she can be subjected to a fiscal liability.
-
International Nuclear Information System (INIS)
Chockie, Alan
2005-09-01
The use of contractors has been an integral and important part of the design, construction, operation, and maintenance of nuclear power plants. To ensure the safe and efficient completion of contracted tasks, each nuclear plant licensee has developed and refined formal contract management processes to meet their specific needs and plant requirements. Although these contract management processes have proven to be effective tools for the procurement of support and components tailored to the needs of nuclear power plants, contractor-related incidents and accidents have revealed some serious weaknesses with the implementation of these processes. Identifying and addressing implementation problems are becoming more complicated due to organizational and personnel changes affecting the nuclear power industry. The ability of regulators and licensees to effectively monitor and manage the safety-related performance of contractors will likely be affected by forthcoming organization and personnel changes due to: the aging of the workforce; the decline of the nuclear industry; and the deregulation of nuclear power. The objective of this report is to provide a review of current and potential future challenges facing safety-related contractor activities at nuclear power plants. The purpose is to assist SKI in establishing a strategy for the proactive oversight of contractor safety-related activities at Swedish nuclear power plants and facilities. The nature and role of contractors at nuclear plants is briefly reviewed in the first section of the report. The second section describes the essential elements of the contract management process. Although organizations have had decades of experience with the a contract management process, there remain a number of common implantation weaknesses that have lead to serious contractor-related incidents and accidents. These implementation weaknesses are summarized in the third section. The fourth section of the report highlights the
-
Energy Technology Data Exchange (ETDEWEB)
Chockie, Alan [Chockie Group International, Inc., Seattle, WA (United States)
2005-09-15
The use of contractors has been an integral and important part of the design, construction, operation, and maintenance of nuclear power plants. To ensure the safe and efficient completion of contracted tasks, each nuclear plant licensee has developed and refined formal contract management processes to meet their specific needs and plant requirements. Although these contract management processes have proven to be effective tools for the procurement of support and components tailored to the needs of nuclear power plants, contractor-related incidents and accidents have revealed some serious weaknesses with the implementation of these processes. Identifying and addressing implementation problems are becoming more complicated due to organizational and personnel changes affecting the nuclear power industry. The ability of regulators and licensees to effectively monitor and manage the safety-related performance of contractors will likely be affected by forthcoming organization and personnel changes due to: the aging of the workforce; the decline of the nuclear industry; and the deregulation of nuclear power. The objective of this report is to provide a review of current and potential future challenges facing safety-related contractor activities at nuclear power plants. The purpose is to assist SKI in establishing a strategy for the proactive oversight of contractor safety-related activities at Swedish nuclear power plants and facilities. The nature and role of contractors at nuclear plants is briefly reviewed in the first section of the report. The second section describes the essential elements of the contract management process. Although organizations have had decades of experience with the a contract management process, there remain a number of common implantation weaknesses that have lead to serious contractor-related incidents and accidents. These implementation weaknesses are summarized in the third section. The fourth section of the report highlights the
-
The NITRD Program: FY2004 Interagency Coordination Report
Networking and Information Technology Research and Development, Executive Office of the President — This Interagency Coordination Report ICR provides a comprehensive description of the FY 2004 activities of the multi-agency $2 billion Federal Networking and...
-
DOE New Technology: Sharing New Frontiers, April 1, 1993--September 30, 1993
Energy Technology Data Exchange (ETDEWEB)
Tamura, A.T.; Henline, D.M. [eds.
1993-12-01
The purpose of DOE New Technology is to provide information on how to access specific technologies developed through research sponsored by DOE and performed by DOE laboratories or by DOE-contracted researchers. This document describes technologies identified as having potential for commercial applications in addition to a catalog of current patent applications and patents available for licensing from DOE and DOE contractors.
-
2012-07-23
...; Information Collection; Central Contractor Registration AGENCY: Department of Defense (DOD), General Services... requirement concerning the Central Contractor Registration database. Public comments are particularly invited... Information Collection 9000- 0159, Central Contractor Registration, by any of the following methods...
-
Research and Technology 1996: Innovation in Time and Space
1996-01-01
As the NASA Center responsible for assembly, checkout, servicing, launch, recovery, and operational support of Space Transportation System elements and payloads, the John F. Kennedy Space Center is placing increasing emphasis on its advanced technology development program. This program encompasses the efforts of the Engineering Development Directorate laboratories, most of the KSC operations contractors, academia, and selected commercial industries - all working in a team effort within their own areas of expertise. This edition of the Kennedy Space Center Research and Technology 1996 Annual Report covers efforts of all these contributors to the KSC advanced technology development program, as well as our technology transfer activities.
-
2013-02-22
...; Information Collection; Central Contractor Registration AGENCIES: Department of Defense (DOD), General... collection requirement concerning the Central Contractor Registration database. A notice was published in the... Information Collection 9000- 0159, Central Contractor Registration, by any of the following methods...
-
Towards Implementation of Green Technology in Sabah Construction Industry
Azland Jainudin, Noor; Jugah, Ivy; Nasrizal Awang Ali, Awang; Tawie, Rudy
2017-12-01
The construction industry in Sabah is one of the major roles for development of social, economic infrastructures and buildings in generating wealth to the state besides the tourism sector. The increasing number of construction projects particularly in the rapid developing city of Kota Kinabalu, green technology as a whole is becoming more significant as it helps to develop effective solutions to encounter global environmental issues. The objective of the research is to identify the awareness and implementation of green technology in construction industry in Kota Kinabalu, Sabah. The methodology of the research is through distributing the questionnaire to the contractors, developers, consultants, architects and state government agencies to the area in Kota Kinabalu only. The questionnaires had been analysed to find out the mean value. 100 questionnaires distributed to the respondents but merely 85 questionnaires collected have been analysed. Based on the findings, 83.5% organisations were aware with the concept of green technology in construction project. In terms of the implementation only 64.7% had been implemented in their organizations. More than 50% from the major players such as contractors, consultants, developers, architects and state government agencies were aware based on six green technology concepts in their organizations. As a conclusion, the awareness towards green policy concept in construction industry is very satisfied. Meanwhile, in terms of implementation need to be increased the number of organizations to be involved in green technology in construction industry.
-
Configuration Management Plan for the Tank Farm Contractor
International Nuclear Information System (INIS)
WEIR, W.R.
2000-01-01
The Configuration Management Plan for the Tank Farm Contractor describes configuration management the contractor uses to manage and integrate its technical baseline with the programmatic and functional operations to perform work. The Configuration Management Plan for the Tank Farm Contractor supports the management of the project baseline by providing the mechanisms to identify, document, and control the technical characteristics of the products, processes, and structures, systems, and components (SSC). This plan is one of the tools used to identify and provide controls for the technical baseline of the Tank Farm Contractor (TFC). The configuration management plan is listed in the management process documents for TFC as depicted in Attachment 1, TFC Document Structure. The configuration management plan is an integrated approach for control of technical, schedule, cost, and administrative processes necessary to manage the mission of the TFC. Configuration management encompasses the five functional elements of: (1) configuration management administration, (2) configuration identification, (3) configuration status accounting, (4) change control, and (5 ) configuration management assessments
-
Configuration Management Plan for the Tank Farm Contractor
Energy Technology Data Exchange (ETDEWEB)
WEIR, W.R.
2000-04-21
The Configuration Management Plan for the Tank Farm Contractor describes configuration management the contractor uses to manage and integrate its technical baseline with the programmatic and functional operations to perform work. The Configuration Management Plan for the Tank Farm Contractor supports the management of the project baseline by providing the mechanisms to identify, document, and control the technical characteristics of the products, processes, and structures, systems, and components (SSC). This plan is one of the tools used to identify and provide controls for the technical baseline of the Tank Farm Contractor (TFC). The configuration management plan is listed in the management process documents for TFC as depicted in Attachment 1, TFC Document Structure. The configuration management plan is an integrated approach for control of technical, schedule, cost, and administrative processes necessary to manage the mission of the TFC. Configuration management encompasses the five functional elements of: (1) configuration management administration, (2) configuration identification, (3) configuration status accounting, (4) change control, and (5 ) configuration management assessments.
-
Development of safety analysis technology for LMR
International Nuclear Information System (INIS)
Lee, Y. B.; Kwon, Y. M.; Suk, S. D.
2005-03-01
The MATRA-LMR-FB has been developed internally for the damage prevention as well as the safety assessment during a channel blockage accident and, as a the result, the quality of the code becomes comparable to that developed in the leading countries. For a code-to-code comparison, KAERI could have access to the SASSYS-1 through a bilateral collaboration between KAERI and ANL. The study could bring into the reliability improvements both on the reactivity models in the SSC-K and on the SSC-K prediction capability. It finally leads to the completion of the SSC-K version 1.3 resulting from the qualitative and quantitative code-to-code comparison. The preliminary analysis for a metal fueled LMR could also become possible with the MELT-III and the VENUS-II, which had originally been developed for the HCDA analysis with an oxidized fuel, by developing the relevant models For the development of the safety evaluation technology, the safety limits have been set up, and the analyses of the internal and external channel blockages in an assembly have also been performed. Besides, the more reliable analysis results on the key design concepts could be obtained by way of the methodology improvement resulting from the qualitative and quantitative comparison study. For an efficient and systematic control of the main project, the integration of the developed technologies and the establishment of their data base have been pursued. It has gone through the development of the process control with taking account of interfaces among the sub-projects, the overall coordination of the developed technologies, the data base for the design products, and so on
-
The role of health information technology in care coordination in the United States.
Hsiao, Chun-Ju; King, Jennifer; Hing, Esther; Simon, Alan E
2015-02-01
Examine the extent to which office-based physicians in the United States receive patient health information necessary to coordinate care across settings and determine whether receipt of information needed to coordinate care is associated with use of health information technology (HIT) (defined by presence or absence of electronic health record system and electronic sharing of information). Cross-sectional study using the 2012 National Electronic Health Records Survey (65% weighted response rate). Office-based physicians. Use of HIT and 3 types of patient health information needed to coordinate care. In 2012, 64% of physicians routinely received the results of a patient's consultation with a provider outside of their practice, whereas 46% routinely received a patient's history and reason for a referred consultation from a provider outside of their practice. About 54% of physicians reported routinely receiving a patient's hospital discharge information. In adjusted analysis, significant differences in receiving necessary information were observed by use of HIT. Compared with those not using HIT, a lower percentage of physicians who used an electronic health record system and shared patient health information electronically failed to receive the results of outside consultations or patient's history and reason for a referred consultation. No significant differences were observed for the receipt of hospital discharge information by use of HIT. Among physicians routinely receiving information needed for care coordination, at least 54% of them did not receive the information electronically. Although a higher percentage of physicians using HIT received patient information necessary for care coordination than those who did not use HIT, more than one third did not routinely receive the needed patient information at all.
-
Operator/contractor teamwork is the key to performance improvement
International Nuclear Information System (INIS)
Robins, K.B.; Roberts, J.D.M.
1996-01-01
The contract strategies developed by the two major E and P companies operating in the North Sea emphasize teamwork between operator and contractors to achieve the common goal of maximizing project value. These strategies have had significant repercussions across the whole industry. This paper compares these strategies and concludes that although they are structurally different, they have the same fundamental objectives. It describes the evolution of what these operators consider to be their core business, with the resultant changing roles for both operator and contractor staff. Several examples of results achieved through implementing these changes are described, highlighting the need for a structured performance measurement system to quantify the success of these initiatives. Finally, the potential for even greater efficiency improvements through further industry-wide cooperation is emphasized
-
Development of Plant Control Diagnosis Technology and Increasing Its Applications
Kugemoto, Hidekazu; Yoshimura, Satoshi; Hashizume, Satoru; Kageyama, Takashi; Yamamoto, Toru
A plant control diagnosis technology was developed to improve the performance of plant-wide control and maintain high productivity of plants. The control performance diagnosis system containing this technology picks out the poor performance loop, analyzes the cause, and outputs the result on the Web page. Meanwhile, the PID tuning tool is used to tune extracted loops from the control performance diagnosis system. It has an advantage of tuning safely without process changes. These systems are powerful tools to do Kaizen (continuous improvement efforts) step by step, coordinating with the operator. This paper describes a practical technique regarding the diagnosis system and its industrial applications.
-
Wang, Dunxing; Gao, Qin; Li, Zhizhong; Song, Fei; Ma, Liang
2017-12-01
This study aims to develop a taxonomy of coordination behaviours during emergencies in nuclear power plants (NPPs). We summarised basic coordination behaviours from literature in aviation, health care and nuclear field and identified coordination behaviours specific to the nuclear domain by interviewing and surveying control crew operators. The established taxonomy includes 7 workflow stages and 24 basic coordination behaviours. To evaluate the reliability and feasibility of the taxonomy, we analysed 12 videos of operators' training sessions by coding coordination behaviours with the taxonomy and the inter-rater reliability was acceptable. Further analysis of the frequency, the duration and the direction of the coordination behaviours revealed four coordination problems. This taxonomy provides a foundation of systematic observation of coordination behaviours among NPP crews, advances researchers' understanding of the coordination mechanism during emergencies in NPPs and facilitate the possibility to deepen the understanding of the relationships between coordination behaviours and team performance. Practitioner Summary: A taxonomy of coordination behaviours during emergencies in nuclear power plants was developed. Reliability and feasibility of the taxonomy was verified through the analysis of 12 training sessions. The taxonomy can serve as an observation system for analysis of coordination behaviours and help to identify coordination problems of control crews.
-
Dense Magnetized Plasmas. Report of a Coordinated Research Project 2001-2006
International Nuclear Information System (INIS)
2013-04-01
The IAEA strives to promote the development and utilization of nuclear technologies offering research opportunities for the growth of industrial applications in various domains. The Coordinated Research Project (CRP) on Dense Magnetized Plasmas (DMPs) was intended to coordinate the development of compact and low cost sources for the generation of charged particle beams, neutrons, X rays and plasma streams. Intense short bursts of neutrons are required for testing and calibrating neutron based diagnostics. Intense particle beams and plasma streams from DMP sources find applications in various research fields and technology, for instance, high heat load testing of candidate materials for the first wall of future fusion reactors. On-site detection of illicit and explosive materials using high rep-rate neutron bursts from compact DMP devices is of great interest. Soft and hard X ray beams produced from such sources have potential applications in biology and enzymology. The overall objective of this CRP was to stimulate and promote investigation of DMPs through synergistic international cooperation. Specific objectives were: (i) to coordinate complementary research efforts related to DMPs by experts in developed and developing Members States, (ii) to speed up the progress in DMP applications by sharing knowledge, expertise and costs, (iii) to promote technology transfer among Member States, and (iv) to contribute to knowledge preservation by involving additional scientists from developing Member States who are not yet experts in DMPs. The three major components of DMP devices are the driver (power supply, electrode system and its associated switch), the target and the target chamber. Engineering fields related to DMP system design include vacuum technology, radiation resistant material development, ablation hydrodynamics and neutronics. In each case, the integration of the components must account for the unique interfaces and constraints of the particular application
-
Recent IAEA activities to support advanced water cooled reactor technology development
International Nuclear Information System (INIS)
Choi, J.-H.; Bilbao y Leon, S.; Rao, A.S.
2009-01-01
The International Atomic Energy Agency (IAEA) is the world's center of cooperation in the nuclear field. The IAEA works with its Member States and multiple partners worldwide to promote safe, secure and peaceful nuclear technologies. To catalyse innovation in nuclear power technology in Member States, the IAEA coordinates cooperative research, promotes information exchange, and analyses technical data and results, with a focus on reducing capital costs and construction periods while further improving performance, safety and proliferation resistance. This paper summarizes the recent major IAEA activities to support technology development for water cooled reactors, which is the most common type of reactor design at present and will probably still be in the near future. (author)
-
Coordinating Permit Offices and the Development of Utility-Scale Geothermal Energy (Presentation)
Energy Technology Data Exchange (ETDEWEB)
Levine, A.; Young, K.; Witherbee, K.
2013-10-01
Permitting is a major component of the geothermal development process. Better coordination across government agencies could reduce uncertainty of the process and the actual time of permitting. This presentation highlights various forms of coordinating permit offices at the state and federal level in the western United States, discusses inefficiencies and mitigation techniques for permitting natural resource projects, analyzes whether various approaches are easily adaptable to utility-scale geothermal development, and addresses advantages and challenges for coordinating permit offices. Key successful strategies identified include: 1. Flexibility in implementing the approach (i.e. less statutory requirements for the approach); 2. Less dependence on a final environmental review for information sharing and permit coordination; 3. State and federal partnerships developed through memorandum of understanding to define roles and share data and/or developer information. A few of the most helpful techniques include: 1. A central point of contact for the developer to ask questions surrounding the project; 2. Pre-application meetings to assist the developer in identifying all of the permits, regulatory approvals, and associated information or data required; 3. A permit schedule or timeline to set expectations for the developer and agencies; 4. Consolidating the public notice, comment, and hearing period into fewer hearings held concurrently.
-
Distributed optimal coordination for distributed energy resources in power systems
DEFF Research Database (Denmark)
Wu, Di; Yang, Tao; Stoorvogel, A.
2017-01-01
Driven by smart grid technologies, distributed energy resources (DERs) have been rapidly developing in recent years for improving reliability and efficiency of distribution systems. Emerging DERs require effective and efficient coordination in order to reap their potential benefits. In this paper......, we consider an optimal DER coordination problem over multiple time periods subject to constraints at both system and device levels. Fully distributed algorithms are proposed to dynamically and automatically coordinate distributed generators with multiple/single storages. With the proposed algorithms...
-
Energy Technology Data Exchange (ETDEWEB)
Clark, W.W. II [Office of Planning and Research, Sacramento, CA (United States); Paolucci, E. [Politecnico di Torino University (Italy). Production and Economics Dept.
2001-07-01
Economic importance of environmental issues is increasing, and new technologies are expected to reduce pollution derived both from productive processes and products, with costs that are still unknown. Until now there is still little knowledge concerning the process of technological innovation in this field. What does exist, is outdated due to rapid change in technology. In this paper we analyse the development of Zinc Air Fuel Cells (ZAFC) and their transfer from research laboratories to large mass production. ZAFC are a new environmental technology, proved to have a commercial value, that can be used for building Zero Emission Vehicles (ZEV). Although ZAFC performances are higher than traditional lead-acid batteries ones, difficulties in funding ZAFC engineering and moving them from laboratories to production caused some years delay in their diffusion. On the bases of this paradigmatic case, we argue that existing economic and organizational literature concerning technological innovation is not able to fully explain steps followed in developing environmental technologies. Existing models mainly consider adoption problems as due to market uncertainty, weak appropriability regime, lack of a dominant design, and difficulties in reconfiguring organizational routines. Additionally, the following aspects play a fundamental role in developing environmental technologies, pointing out how technological trajectories depend both on exogenous market conditions and endogenous firm competencies: 1 regulations concerning introduction of ZEV create market demand and business development for new technologies; they impose constraints that can be met only by segmenting transportation market at each stage of technology development; 2 each stage of technology development requires alternative forms of division and coordination of innovative labour; upstream and downstream industries are involved in new forms of inter-firm relationships, causing a reconfiguration of product architecture
-
Coordinator, Evaluation Unit | IDRC - International Development ...
International Development Research Centre (IDRC) Digital Library (Canada)
Job Summary The Evaluation Unit Coordinator is expected to: ... with Centre policies and procedures and disseminates information to Unit staff on changes ... Coordinates the planning and organization of technical and administrative meetings ...
-
2012-11-20
... Contractor Registration AGENCY: Department of Defense (DoD), General Services Administration (GSA), and... changes the clauses requiring contractor registration in the Central Contractor Registration (CCR... unique identifier for contractors. It is used (1) to uniquely identify a contractor entity, and (2) to...
-
Exposing government response action contractors to environmental tort liability
International Nuclear Information System (INIS)
Roy, M.J.
1991-01-01
Government contractors, particularly those involved with hazardous waste response action activities, are encountering increased risks for environmental tort liabilities. Contracts often include tasks and work assignments requiring the management of industrial, chemical, nuclear or mining wastes, spent fuels, munitions or other toxic substances. Contractors exposure to liability for damages results directly from the environmental laws and regulations pursuant to which the Government has contracted them to respond. Additionally, contractors may be exposed to common law liability under such dogmas as nuisance, trespass and strict liability in tort
-
2010-10-29
...-AG52 Defense Federal Acquisition Regulation Supplement (DFARS); Continuation of Essential Contractor... that contractors providing essential contractor services, as determined by the requiring activity..., implementing the requirements of DoDI 3020.37, Continuation of Essential DoD Contractor Services During Crises...
-
48 CFR 52.236-23 - Responsibility of the Architect-Engineer Contractor.
2010-10-01
... Architect-Engineer Contractor. 52.236-23 Section 52.236-23 Federal Acquisition Regulations System FEDERAL... Provisions and Clauses 52.236-23 Responsibility of the Architect-Engineer Contractor. As prescribed in 36.609-2(b), insert the following clause: Responsibility of the Architect-Engineer Contractor (APR 1984) (a...
-
Marhani, M. A.; Muksain, M. A. S.
2018-02-01
Malaysia has developed Green Building Index (GBI) as the green rating tool for buildings and townships to encourage sustainability in the construction industry. Understanding the roles and tasks of a contractor is essential in accomplishing the GBI assessment on a green building project. However, there are challenges in adapting the GBI. The objective of this paper is to identify the knowledge of contractor for each area of assessments in GBI’s checklist. Data were collected through the questionnaire surveys to the selected contractors, which were involved in GBI projects. The findings revealed that most of the respondents agreed and acknowledged the impact of each criterion in the assessment. Thus, it is highly recommended to educate and change the public perception on the awareness of the green building. Aside, more research and development (R&D) process should be encouraged to accelerate the GBI certificate implementation in the construction industry. In conclusion, proper education training, more legislative and financial framework are essential for the future of green building projects.
-
A contractor's approach to engineering process plant for radioactive liquor processing
International Nuclear Information System (INIS)
Braide, W.M.; Fletcher, P.D.
1982-01-01
Protection of personnel from damaging sources of radiation is the overriding consideration which influences the fundamental design of plant for processing active liquors in the Nuclear Industry. The conventional design procedures of the Chemical Plant Contractor have therefore to be modified to meet the specific technology and additional safety requirements. Ways in which the added factor of radiation influences the design philosophy for Nuclear Plant compared to conventional Chemical Plant are described. Design philosophy is demonstrated by design studies for active liquor storage and evaporation plant. (author)
-
2013-05-22
... Number 0750-AG38 Defense Federal Acquisition Regulation Supplement; Government Support Contractor Access... Government support contractors to have access to proprietary technical data belonging to prime contractors and other third parties, provided that the technical data owner may require the support contractor to...
-
Analysis of Criteria Influencing Contractor Selection Using TOPSIS Method
Alptekin, Orkun; Alptekin, Nesrin
2017-10-01
Selection of the most suitable contractor is an important process in public construction projects. This process is a major decision which may influence the progress and success of a construction project. Improper selection of contractors may lead to problems such as bad quality of work and delay in project duration. Especially in the construction projects of public buildings, the proper choice of contractor is beneficial to the public institution. Public procurement processes have different characteristics in respect to dissimilarities in political, social and economic features of every country. In Turkey, Turkish Public Procurement Law PPL 4734 is the main regulatory law for the procurement of the public buildings. According to the PPL 4734, public construction administrators have to contract with the lowest bidder who has the minimum requirements according to the criteria in prequalification process. Public administrators are not sufficient for selection of the proper contractor because of the restrictive provisions of the PPL 4734. The lowest bid method does not enable public construction administrators to select the most qualified contractor and they have realised the fact that the selection of a contractor based on lowest bid alone is inadequate and may lead to the failure of the project in terms of time delay Eand poor quality standards. In order to evaluate the overall efficiency of a project, it is necessary to identify selection criteria. This study aims to focus on identify importance of other criteria besides lowest bid criterion in contractor selection process of PPL 4734. In this study, a survey was conducted to staff of Department of Construction Works of Eskisehir Osmangazi University. According to TOPSIS (Technique for Order Preference by Similarity to the Ideal Solution) for analysis results, termination of construction work in previous tenders is the most important criterion of 12 determined criteria. The lowest bid criterion is ranked in rank 5.
-
Safeguards technology development for spent fuel storage and disposal
International Nuclear Information System (INIS)
Sanders, K.E.
1991-01-01
This paper reports on facilities for monitored retrievable storage and geologic repository that will be operating in the US by 1998 and 2010 respectively. The international safeguards approach for these facilities will be determined broadly by the Safeguards Agreement and the IAEA Safeguards Criteria (currently available for 1991-1995) and defined specifically in the General Subsidiary Arrangements and Specific Facility Attachments negotiated under the US/IAEA Safeguards Agreement. Design information for these facilities types, as it is conceptualized, will be essential input to the safeguards approach. Unique design and operating features will translate into equally unique challenges to the application of international safeguards. The development and use of new safeguards technologies offers the greatest potential for improving safeguards. The development and use of new safeguards technologies offers the greatest potential for improving safeguards by enabling efficient and effective application with regard to the operator's interest, US policies, and the IAEA's statutorial obligations. Advanced unattended or remote measurement, authentication of operator's measurement, authentication of operator's measurement data, and integration of monitoring and containment/surveillance potentially are among the most fruitful areas of technology development. During the next year, a long range program plan for international safeguard technology development for monitored retrievable storage and geologic repository will be developed by the International Branch in close coordination with the Office of Civilian Radioactive Waste Management. This presentation preliminarily identifies elements of this long range program
-
Christiansen, Line; Fagerström, Cecilia; Nilsson, Lina
2017-07-01
To facilitate communications between care levels and improve coordination during hospital discharges, there is great potential in using information and communication technology systems, because they can significantly help to deter unnecessary readmissions. However, there is still a lack of knowledge about how often nurses use information and communication technology and the indicators related to its use. The aims of this study were to describe the indicators related to nurses' use of an information and communication technology system for collaboration between care levels and to estimate whether the level of use can be related to nurses' perceptions of the information and communication technology system's contribution to improve coordination during hospital discharges. A quantitative survey of 37 nurses from 11 primary healthcare centers was performed in a county in southern Sweden. The data were analyzed using descriptive and comparative analyses. The results showed that perceptions concerning the information and communication technology system's usability and time consumption differed between nurses who used the system and those who did not. Simultaneously, the nurses were rather unaware of the ability of the information and communication technology system to improve coordination during patient discharges.
-
Advanced Stirling Convertor (ASC) Technology Maturation
Wong, Wayne A.; Wilson, Scott; Collins, Josh; Wilson, Kyle
2016-01-01
The Advanced Stirling Convertor (ASC) development effort was initiated by NASA Glenn Research Center with contractor Sunpower, Inc., to develop high-efficiency thermal-to-electric power conversion technology for NASA Radioisotope Power Systems (RPSs). Early successful performance demonstrations led to the expansion of the project as well as adoption of the technology by the Department of Energy (DOE) and system integration contractor Lockheed Martin Space Systems Company as part of the Advanced Stirling Radioisotope Generator (ASRG) flight project. The ASRG integrates a pair of ASCs to convert the heat from a pair of General Purpose Heat Source (GPHS) modules into electrical power. The expanded NASA ASC effort included development of several generations of ASC prototypes or engineering units to help prepare the ASC technology and Sunpower for flight implementation. Sunpower later had two parallel contracts allowing the last of the NASA engineering units called ASC-E3 to serve as pathfinders for the ASC-F flight convertors being built for DOE. The ASC-E3 convertors utilized the ASC-F flight specifications and were built using the ASC-F design and process documentation. Shortly after the first ASC-F pair achieved initial operation, due to budget constraints, the DOE ASRG flight development contract was terminated. NASA continues to invest in the development of Stirling RPS technology including continued production of the ASC-E3 convertors, seven of which have been delivered with one additional unit in production. Starting in fiscal year 2015, Stirling Convertor Technology Maturation has been reorganized as an element of the RPS Stirling Cycle Technology Development (SCTD) Project and long-term plans for continued Stirling technology advancement are in reformulation. This paper provides a status on the ASC project, an overview of advancements made in the design and production of the ASC at Sunpower, and a summary of acceptance tests, reliability tests, and tactical
-
Project Finance Model for Small Contractors in USA
Directory of Open Access Journals (Sweden)
Jawahar Nesan
2012-11-01
Full Text Available Construction projects do not require a large capital outlay but a large working capital to start up the project. Unfortunately, for small contractors there are very limited options available from the banks or other lending institutions to cover this large working capital requirement in the absence of sufficient collateral. The “Project Finance” method presented in this paper is recommended as the most effective method for small contractors in the United States. The problems of small and start up contractors in funding their projects have been little addressed in the literature. The current financing practices were observed through both the literature review and interviews with contractors and bankers in the western Michigan area and subsequently a system has been proposed which could help a small start-up company seeking higher growth. The growth rates that can be achieved using the project finance system in contrast to the traditional “line of credit” arrangements as illustrated in this paper show that the project finance model is beneficial.
-
Energy Technology Data Exchange (ETDEWEB)
Burdick, Arlan [IBACOS Inc., Pittsburgh, PA (United States)
2011-10-01
This expert meeting was hosted by the IBACOS Building America research team to determine how HVAC companies can transition from a traditional contractor status to a service provider for whole house energy upgrade contracting.
-
76 FR 50714 - Federal Acquisition Regulation; Documenting Contractor Performance; Correction
2011-08-16
... Regulation; Documenting Contractor Performance; Correction AGENCY: Department of Defense (DoD), General... August 9, 2011, regarding the proposed rule for Documenting Contractor Performance. DATES: The comment...
-
Project Coordinator - Karianet | IDRC - International Development ...
International Development Research Centre (IDRC) Digital Library (Canada)
Primary Duties or Responsibilities. The specific responsibilities of the Project Coordinator are grouped into three categories: Knowledge Management, Research Management and Project Management. As Knowledge Manager, the program coordinator will play a lead role in: Introducing and using knowledge management ...
-
Financial Planning and Management Practices of Electrical Contractors
Directory of Open Access Journals (Sweden)
Lucko Gunnar
2016-12-01
Full Text Available Contractors must carefully manage their cash outflows (e.g., for materials to enable their work and inflows (after the work to be profitable, particularly in an economy that is still recovering from the 2008-2012 recession that grew out of the mortgage crisis. Their importance for business success is undisputed, as bankruptcies due to insufficient cash flow underline. Therefore, this study investigated current business practices of electrical contracting companies of different sizes with respect to their financial planning and management. A detailed questionnaire was developed with best guidelines on survey studies and pilot testing. It was sent to members of the National Electrical Contractors Association. Respondent anonymity was ensured. The survey recorded demographics, business practices, operating conditions, and other important factors using 57 subquestions. Each section allowed feedback to clarify the numerical responses. Responses were well distributed across company sizes, so that the results are representative for the entire industry. The results indicated that contractors generally have a substantial amount of experience in financial decision making. Their approach is conservative and focuses on healthy growth. Yet, opportunities to fine-tune business practices are identified, e.g., immediate invoicing, considering discounts to accelerate payment receipts, attempting to negotiate and use favorable credit terms, reviewing payment performance, and performing frequent cash flow forecasts. Some of the differences in the responses can be attributed to different company sizes. To help especially smaller companies in planning their cash flow, a spreadsheet for implementation has been created.
-
2010-10-01
...; (B) Storage and disposal of civilian high-level nuclear waste and spent fuel technology; and (C... (including an English-language version if filed in a language other than English); (ii) An executed and... Contractor shall obtain patent agreements to effectuate the provisions of subparagraph (o)(1) of this clause...
-
International Nuclear Information System (INIS)
Sun Xingdong
2014-01-01
The coordinated instrumentation control and protection technology between reactor and steam turbine generator (TG) usually is very significant and complicated for a new construction of nuclear power plant, because it carries the safety, economy and availability of nuclear power plant. Based on successful practice of a nuclear power plant, the experience on interface design and hardware architecture of coordinated instrumentation control and protection technology between reactor and steam turbine generator was abstracted and researched. In this paper, the key points and engineering experience were introduced to give the helpful instructions for the new project. (author)
-
Requirements for the project management in the client / engineering contractor relationship
International Nuclear Information System (INIS)
Hack, W.L.
1995-01-01
Investment projects impose a multitude of requirements upon clients and engineering contractors to cope with the management of project inherent conflicts. The paper reviews certain aspects on why such conflicts develop, and how they may be resolved. (orig.)
-
Medicare Administrative Contractor Performance Evaluation
U.S. Department of Health & Human Services — The Centers for Medicare and Medicaid Services (CMS) has compiled a summary of overall Medicare Administrative Contractor (MAC) performance information as measured...
-
Advanced remediation, technology development in the underground storage tank
International Nuclear Information System (INIS)
Gates, T.E.; Gilchrist, R.L.
1992-01-01
Production of nuclear materials has been a major mission of the U. S. Department of Energy (DOE) over the last 50 years. These activities have contributed to a substantial accumulation of hazardous, radioactive, and mixed wastes. In 1989, the DOE established the Office of Environmental Restoration and Waste Management. This office coordinates and manages the DOE's remediation, waste minimization, and environmental compliance activities. It also has responsibility for waste generated by current operations. Within this office is the Office of Technology Development, which is responsible for providing technology improvements. This paper reports on integrated demonstrations which have been established to efficiently bring the best technologies to bear on the common needs of multiple DOE sites. One such need is resolution of the actions required for final closure and waste disposal of liquid (including sludge and salt cake) radioactive and chemical wastes that have been transferred to underground storage tanks
-
48 CFR 852.236-72 - Performance of work by the contractor.
2010-10-01
... 48 Federal Acquisition Regulations System 5 2010-10-01 2010-10-01 false Performance of work by the....236-72 Performance of work by the contractor. As prescribed in 836.501, insert the following clause: Performance of Work by the Contractor (JUL 2002) The clause entitled “Performance of Work by the Contractor...
-
Kong, Wei; Ren, Liang; Wang, Shu Jia; Liu, Yu Feng
2016-09-01
Based on the constructed evaluation index system of ecological environment and economy coordinated development in Hebei Province, accompanied by introducing the Coupling Degree Mo-del, the paper estimated the ecological environment comprehensive index, the economic comprehensive index and the coupling degree of ecological environment and economy coordinated development of Hebei Province from 2000 to 2014 and 11 cities in 4 years (2000, 2006, 2010, 2014). The results showed that during the study period, the level of the coordinated development of the eco-logical environment and economy in Hebei Province had been increasing, from the brink of a recession to the well coordinated development, which had gone through 3 evident stages. The coordinating degree of ecological environment and economy of the 11 cities increased year by year, and pre-sented significant difference in spatial distribution. Through analyzing the spatial and temporal evolution mechanism of the ecological environment and economy coordinated development in Hebei Province, the policy, economy, industry and location were the key contributing factors, accordingly, suggestions on the further coordinated development of ecological environment and economy in Hebei Province were proposed.
-
Strategic management competencies in Scandinavian contractors
DEFF Research Database (Denmark)
Koch, Christian; Buhl, Henrik
2013-01-01
Over the past ten years, a series of contractors operating in Denmark, Norway and Sweden have slowly but surely expanded their markets beyond their previous single-country base towards operating in Scandinavia as a whole, and beyond. This expansion has been accompanied by a restructuring of company...... management and HR concepts and approaches. Methodologically, a sample of the top level leaders of the hundred largest business units at some thirty Scandinavian contractors has been analysed. The focus is on the 400 top level managers in these organisations. On the basis of a desk study, an analysis of 124...
-
The Role of Climate and Socialization in Developing Interfunctional Coordination.
Wooldridge, Barbara Ross; Minsky, Barbara D.
2002-01-01
Develops a model illustrating that two elements of organizational culture--climate and socialization processes--foster acceptance of organizational values and facilitate the development of interfunctional coordination, which in turn influences firm performance. (Contains 42 references.) (JOW)
-
National Research Council Canada - National Science Library
Geertsema, Cameron
2003-01-01
.... Specifically, this document will focus on how the outcome of capital facility projects are affected by human resources practices, and the management principles and practices of the contractor-owner...
-
2012-08-27
...; Information Collection; Contractors' Purchasing Systems Reviews AGENCY: Department of Defense (DOD), General... collection requirement concerning contractors' purchasing systems reviews. Public comments are particularly... Information Collection 9000- 0132, Contractors' Purchasing Systems Reviews, by any of the following methods...
-
2011-09-30
...; Information Collection; Contractor Business Ethics Compliance Program and Disclosure Requirements AGENCIES... concerning contractor business ethics compliance program and disclosure requirements. Public comments are... Collection 9000- 0164, Contractor Business Ethics Compliance Program and Disclosure Requirements, by any of...
-
Programmatic Baseline Summary for Phase 1 Privatization for the Tank Farm contractor
International Nuclear Information System (INIS)
DIEDIKER, J.A.
2000-01-01
The document describes the systematic integrated baseline planning process and provides a summary of the Tank Farm Contractor scope, schedule and cost analysis developed in support of the Phase 1 privatization mission
-
Programmatic Baseline Summary for Phase 1 Privatization for the Tank Farm contractor
Energy Technology Data Exchange (ETDEWEB)
DIEDIKER, J.A.
2000-04-22
The document describes the systematic integrated baseline planning process and provides a summary of the Tank Farm Contractor scope, schedule and cost analysis developed in support of the Phase 1 privatization mission.
-
International Nuclear Information System (INIS)
1995-12-01
99 Tc m is the workhorse of nuclear medicine and currently accounts for over 80% of all in vivo diagnostic procedures. This radionuclide is made available to nuclear medicine centers in the form of a generator wherein the parent 99 Mo (generally produced by the fission of 235 U) is retained on a column of alumina and the daughter 99 Tc m produced by the decay of 99 Mo is separated out by elution of the column with saline solution. Fission 99 Mo is now routinely produced only in a few large production centers in the world and the short half-life of 99 Mo poses transportation problems. Recognizing the need to develop alternative technologies for the production of 99 Tc m generators in developing Member States operating medium neutron flux research reactors, the IAEA initiated a co-ordinated research programme (CRP) in 1983. As a result of the work carried out under the auspices of this CRP (1983-1989), it became apparent that technologies based on low temperature sublimation processes and polymolybade gels showed excellent potential for the preparation of reliable and economical 99 Tc m generators. Generators based on elution of polymolybade gels have since been developed and evaluated. Further, based on their own research work and publication from other sources, the experts who participated in this CRP have made a detailed evaluation of other possible alternative technologies for the production of 99 Tc m generators using 99 Mo produced by the non-fission route. 24 refs, 16 figs
-
Energy Technology Data Exchange (ETDEWEB)
Waite, J.L.
1996-04-12
This plan has been developed by Westinghouse Hanford Company (WHC), and its subcontractors ICF Kaiser Hanford (ICF KH) and BCS Richland, Inc. (BCSR), at the direction of the US Department of Energy (DOE), Richland Operations Office (RL). WHC and its subcontractors are hereafter referred to as the Maintenance and Operations (M and O) Contractor. The plan identifies actions involving the M and O Contractor that are critical to (1) prepare for a smooth transition to the Project Hanford Management Contractor (PHMC), and (2) support and assist the PHMC and RL in achieving transition as planned, with no or minimal impact to ongoing baseline activities. The plan is structured around two primary phases. The first is the pre-award phase, which started in mid-February 1996 and is currently scheduled to be completed on June 1, 1996, at which time the contract is currently planned to be awarded. The second is the follow-on four-month post-award phase from June 1, 1996, until October 1, 1996. Considering the magnitude and complexity of the scope of work being transitioned, completion in four months will require significant effort by all parties. To better ensure success, the M and O Contractor has developed a pre-award phase that is intended to maximize readiness for transition. Priority is given to preparation for facility assessments and processing of personnel, as these areas are determined to be on the critical path for transition. In addition, the M and O Contractor will put emphasis during the pre-award phase to close out open items prior to contract award, to include grievances, employee concerns, audit findings, compliance issues, etc.
-
A contractors's approach to engineering process plant for radioactive liquor processing
International Nuclear Information System (INIS)
Braide, W.M.; Fletcher, P.D.
1982-01-01
Protection of personnel from damaging sources of radiation is the overriding consideration which influences the fundamental design of plant for processing active liquors in the Nuclear Industry. The conventional design procedures of the Chemical Plant Contractor have therefore to be modified to meet the specific technology and additional safety requirements. This paper describes ways in which the added factor of radiation influences the design philosophy for Nuclear Plant compared to conventional Chemical Plant. The design philosophy is demonstrated by design studies for active liquor storage and evaporation plant. (author)
-
Directory of Open Access Journals (Sweden)
I.A. Bodrenkova
2014-12-01
Full Text Available Purpose : to develop theoretically and experimentally justify the methodology of development of coordination abilities of athletes aged 7-9 years involved in sports aerobics. Material : the study involved 20 participants (7-9 years. 8 athletes performed the test tasks. The choice of tests carried out on the basis of the analysis of the dominant motor mode competition exercises. Results : It was found that the coordination abilities are necessary in the development of speed, density, and the number of running technical elements. With more than a significant increase in performance test tasks that characterize: musicality, coordination, dynamic balance. The basic tools, methods, techniques, and requirements for the exercises. The level of development of coordination abilities. Conclusions : the author's method of development of coordination abilities include: rational choice of means and methods of training impact on their similarities and differences with the target competitive activity.
-
Energy Materials Coordinating Committee (EMaCC). Fiscal year 1994
Energy Technology Data Exchange (ETDEWEB)
NONE
1995-07-31
The committee serves primarily to enhance coordination among the Department`s materials programs and to further effective use of materials expertise within the Department. This is accomplished through the exchange of budgetary and planning information among program managers and through technical meetings/workshops involving DOE and major contractors. The program descriptions consist of a funding summary for each Assistant Secretary office and the Office of Energy Research, and detailed project summaries with project goals and accomplishments. A FY 1994 budget summary table for each program is included. A directory and a keyword index is included at the end of this document.
-
2013-09-30
...-AH97 Defense Federal Acquisition Regulation Supplement: Enhancement of Contractor Employee... contractor and subcontractor employees. DATES: Effective date: September 30, 2013. In accordance with FAR 1... Whistleblower Protections for Contractor Employees) made extensive changes to 10 U.S.C. 2409, entitled...
-
Technology Summary Advancing Tank Waste Retrieval And Processing
International Nuclear Information System (INIS)
Sams, T.L.; Mendoza, R.E.
2010-01-01
This technology overview provides a high-level summary of technologies being investigated and developed by Washington River Protection Solutions (WRPS) to advance Hanford Site tank waste retrieval and processing. Technology solutions are outlined, along with processes and priorities for selecting and developing them. This technology overview provides a high-level summary of technologies being investigated, developed, and deployed by WRPS to advance Hanford Site tank waste retrieval and processing. Transformational technologies are needed to complete Hanford tank waste retrieval and treatment by 12/31/2047. Hanford's underground waste storage tanks hold approximately 57 million gallons of radiochemical waste from nuclear defense production - more tank waste than any other site in the United States. In addition, the waste is uniquely complicated because it contains constituents from at least six major radiochemical processes and several lesser processes. It is intermixed and complexed more than any other waste collection known to exist in the world. The multi-faceted nature of Hanford's tank waste means that legally binding agreements in the Federal Facility Agreement and Consent Order (known as the Tri-Party Agreement) and between the Department of Energy (DOE) and its contractors may not be met using current vitrification schedules, plans, and methods. WRPS and the DOE are developing, testing, and deploying technologies to meet the necessary commitments and complete the DOE's River Protection Project (RPP) mission within environmentally acceptable requirements. Technology solutions are outlined, along with processes and priorities for selecting and developing them. DOE's Office of Environmental Management (EM) identifies the environmental management technology needs and the activities necessary to address them. The U.S. Congress then funds these activities through EM or the DOE field offices. Finally, an array of entities that include DOE site prime contractors and
-
Contractors on the Battlefield: What Have We Signed Up For?
National Research Council Canada - National Science Library
Zamparelli, Steven
1999-01-01
The role of contractors in warfare has changed dramatically. As the Services have drawn down, more and more of the duties formerly accomplished by military members are being performed by contractors...
-
Directory of Open Access Journals (Sweden)
M. Gorohovatska
2013-07-01
Full Text Available Results of scientific cooperation between European countries, including Ukraine, within the Seventh Framework Programme for Research and Technological Development are reviewed. Terms of preparation of joint and coordinated EUUkraine calls within the Framework Programme «Horizon 2020» are discussed; terms and conditions of participation in these calls are determined.
-
Rhythmic Interlimb Coordination Impairments and the Risk for Developing Mobility Limitations.
James, Eric G; Leveille, Suzanne G; Hausdorff, Jeffrey M; Travison, Thomas; Kennedy, David N; Tucker, Katherine L; Al Snih, Soham; Markides, Kyriakos S; Bean, Jonathan F
2017-08-01
The identification of novel rehabilitative impairments that are risk factors for mobility limitations may improve their prevention and treatment among older adults. We tested the hypothesis that impaired rhythmic interlimb ankle and shoulder coordination are risk factors for subsequent mobility limitations among older adults. We conducted a 1-year prospective cohort study of community-dwelling older adults (N = 99) aged 67 years and older who did not have mobility limitations (Short Physical Performance Battery score > 9) at baseline. Participants performed antiphase coordination of the right and left ankles or shoulders while paced by an auditory metronome. Using multivariable logistic regression, we determined odds ratios (ORs) for mobility limitations at 1-year follow-up as a function of coordination variability and asymmetry. After adjusting for age, sex, body mass index, Mini-Mental State Examination score, number of chronic conditions, and baseline Short Physical Performance Battery score, ORs were significant for developing mobility limitations based on a 1 SD difference in the variability of ankle (OR = 1.88; 95% confidence interval [CI]: 1.16-3.05) and shoulder (OR = 1.96; 95% CI: 1.17-3.29) coordination. ORs were significant for asymmetry of shoulder (OR = 2.11; 95% CI: 1.25-3.57), but not ankle (OR = 0.95; 95% CI: 0.59-1.55) coordination. Similar results were found in unadjusted analyses. The results support our hypothesis that impaired interlimb ankle and shoulder coordination are risk factors for the development of mobility limitations. Future work is needed to further examine the peripheral and central mechanisms underlying this relationship and to test whether enhancing coordination alters mobility limitations. © The Author 2016. Published by Oxford University Press on behalf of The Gerontological Society of America. All rights reserved. For permissions, please e-mail: journals.permissions@oup.com.
-
75 FR 55577 - Clean Water Act; Contractor Access to Confidential Business Information
2010-09-13
... ENVIRONMENTAL PROTECTION AGENCY [FRL-9200-8] Clean Water Act; Contractor Access to Confidential... Recovery Act (RCRA). Transfer of the information will allow the contractor and subcontractors to access... contractors and subcontractors over the history of the effluent guidelines program. EPA determined that this...
-
75 FR 82575 - Federal Acquisition Regulation; Personal Identity Verification of Contractor Personnel
2010-12-30
... 9000-AL60 Federal Acquisition Regulation; Personal Identity Verification of Contractor Personnel AGENCY... requirement of collecting from contractors all forms of Government-provided identification once they are no...D Inspector General Audit Report No. D-2009-005, entitled ``Controls Over the Contractor Common...
-
77 FR 60962 - Clean Water Act; Contractor Access to Confidential Business Information
2012-10-05
... ENVIRONMENTAL PROTECTION AGENCY 40 CFR Part 2 [FRL-9733-8] Clean Water Act; Contractor Access to... transfer of confidential business information to contractor, subcontractors, and consultants. SUMMARY: The... certain industries. We have determined that the contractors listed below require access [[Page 60963
-
77 FR 51496 - Federal Acquisition Regulation; Basic Safeguarding of Contractor Information Systems
2012-08-24
... Federal Acquisition Regulation; Basic Safeguarding of Contractor Information Systems AGENCY: Department of... Acquisition Regulation (FAR) to add a new subpart and contract clause for the basic safeguarding of contractor... information) that will be resident on or transiting through contractor information systems. DATES: Interested...
-
2011-01-25
...; Contractor Conflicts of Interest AGENCY: Environmental Protection Agency. ACTION: Notice. SUMMARY: In... control numbers in certain EPA regulations is consolidated in 40 CFR part 9. Abstract: EPA contractors... cleanup and enforcement and because its contractors are often involved in both activities, it is...
-
2011-12-28
... Activities; Proposed Collection; Comment Request; Contractor Cumulative Claim and Reconciliation (Renewal... identify the Docket ID Number EPA-HQ-OARM-2011-0997, Contractor Cumulative Claim and Reconciliation. Hand... information collection activity or ICR does this apply to? Affected entities: All contractors who have...
-
The main factor affecting the competitiveness of Contractor Company
Nurisra; Malahayati, Nurul; Mahmuddin
2018-05-01
Contractor companies must have the competitive advantage to compete in maintaining the survival of the company. Problems arise because quite a lot of advantages can be used and these advantages must be used appropriately to produce competitiveness for the company to continue to compete and to win the competition. This study aims to determine the main factors affecting the competitiveness of medium-class contractors in Banda Aceh. Data collection was obtained through questionnaires distributed to 31 middle-class contractors in Banda Aceh. Data processing and analysis is done by using descriptive analysis. Based on the result of descriptive analysis, it can be concluded that the most important competitiveness factor with a mean score value 4.52 is the relationship, and the factor that has the highest mean score value is the relationship with the government of 4.97, while the result of the ranking analysis is obtained 25 factor that is critical to the competitiveness of medium-class contractors in Banda Aceh.
-
ACED Federal Grant Contractor Tracking
Allegheny County / City of Pittsburgh / Western PA Regional Data Center — Dataset includes grant, project, and contractor awarded which are tracked for ensuring Davis-Bacon Act compliance where applicable. The 1931 Davis-Bacon Act...
-
International Nuclear Information System (INIS)
Beckman, W.H.; Cossel, S.C.; Alhadeff, N.; Lindamood, S.B.; Beers, J.A.
1993-10-01
The purpose of the Standards/Requirements Identification Program, developed partially in response to the Defense Nuclear Facilities Safety Board Recommendation 90-2, was to identify applicable requirements that established the Environmental Restoration Management Contractor's (ERMC) responsibilities and authorities under the Environmental Restoration Management Contract, determine the adequacy of these requirements, ascertain a baseline level of compliance with them, and implement a maintenance program that would keep the program current as requirements or compliance levels change. The resultant Standards/Requirements Identification Documents (S/RIDs) consolidate the applicable requirements. These documents govern the development of procedures and manuals to ensure compliance with the requirements. Twenty-four such documents, corresponding with each functional area identified at the site, are to be issued. These requirements are included in the contractor's management plan
-
Parladé, Meaghan V.; Iverson, Jana M.
2015-01-01
This study evaluated the extent to which developmental change in coordination of social communication in early infancy differentiates children eventually diagnosed with ASD from those not likely to develop the disorder. A prospective longitudinal design was used to compare 9 infants at heightened risk for ASD (HR) later diagnosed with ASD, to 13 HR infants with language delay, 28 HR infants with no diagnosis, and 30 low risk infants. Hierarchical Linear Modeling (HLM) analyses revealed that ASD infants exhibited significantly slower growth in coordinations overall and in gestures coordinated with vocalizations, even relative to HR infants with language delay. Disruption in the development of gesture-vocalization coordinations may result in negative cascading effects that negatively impact later social and linguistic development. PMID:25689930
-
Energy Technology Data Exchange (ETDEWEB)
Bodie, J.S.; Haymour, J. [Fraser Milner, Calgary, AB (Canada)
1999-10-01
The many factors that should be considered when distinguishing between an independent contractor and an employee from the perspective of tax laws were discussed. Some of the major areas where disputes regarding relationships between the employee and the independent contractor arise were reviewed with particular emphasis on some of the dangers associated with a change in characterization of these types of relationships. Ways in which to guard against these dangers were also presented. The courts have established the following four tests to determine a contractor`s status: (1) the control test, (2) the economic reality test, (3) the business integration test, and (4) the ownership of tools test. The control tests looks to the degree of control that an employer/recipient of services possesses over the work that is to be performed. The economic reality test looks to whether the contractor is actually in business for himself and is risking a loss. The business integration test examines the relationship between employer and contractor in terms of how economically dependent the contractor is on the employer and whether the task the contractor carries on forms an integral part of the business of the employer. The last test examines who owns the tools used by the contractor to carry out his duties. This presentation also reviewed how employers and contractors are responsible for adhering to Revenue Canada tax laws and certain liabilities regarding income taxes, Employment Insurance (EI) premiums, Canada Pension Plan (CPP) contributions and other amounts.
-
Task 10 -- Technology development integration. Semi-annual report, April 1--September 30, 1997
Energy Technology Data Exchange (ETDEWEB)
Erickson, T.A.; Daly, D.J.; Jones, M.L.
1997-12-31
Task 10 activities by the Energy and Environmental Research Center (EERC) have focused on the identification and integration of new cleanup technologies for use in the US Department of Energy (DOE) Environmental Management Program to address environmental issues within the nuclear defense complex. Under Subtask 10A, activities focused on a review of technology needs compiled by the Site Technology Coordination Groups as part of an ongoing assessment of the relevance of the EM Cooperative Agreement Program activities to EM site needs. Work under this subtask was completed August 31. Work under Task 10B had as its goal assisting in the definition and development of specific models to demonstrate several approaches to be used by DOE to encourage the commercialization of environmental technologies. This activity included identification and analysis of economic and regulatory factors affecting feasibility of commercial development of two specific projects and two general models to serve as a mechanism for the transfer of federally supported or developed environmental technologies to the private sector or for rapid utilization in the federal government`s efforts to clean up the weapons complex.
-
A Cognitive Systems Engineering Approach to Developing HMI Requirements for New Technologies
Fern, Lisa Carolynn
2016-01-01
This document examines the challenges inherent in designing and regulating to support human-automation interaction for new technologies that will deployed into complex systems. A key question for new technologies, is how work will be accomplished by the human and machine agents. This question has traditionally been framed as how functions should be allocated between humans and machines. Such framing misses the coordination and synchronization that is needed for the different human and machine roles in the system to accomplish their goals. Coordination and synchronization demands are driven by the underlying human-automation architecture of the new technology, which are typically not specified explicitly by the designers. The human machine interface (HMI) which is intended to facilitate human-machine interaction and cooperation, however, typically is defined explicitly and therefore serves as a proxy for human-automation cooperation requirements with respect to technical standards for technologies. Unfortunately, mismatches between the HMI and the coordination and synchronization demands of the underlying human-automation architecture, can lead to system breakdowns. A methodology is needed that both designers and regulators can utilize to evaluate the expected performance of a new technology given potential human-automation architectures. Three experiments were conducted to inform the minimum HMI requirements a detect and avoid system for unmanned aircraft systems (UAS). The results of the experiments provided empirical input to specific minimum operational performance standards that UAS manufacturers will have to meet in order to operate UAS in the National Airspace System (NAS). These studies represent a success story for how to objectively and systematically evaluate prototype technologies as part of the process for developing regulatory requirements. They also provide an opportunity to reflect on the lessons learned from a recent research effort in order to
-
2011-04-13
... Activities; Proposed Collection; Comment Request; Contractor Conflicts of Interest AGENCY: Environmental....regulations.gov . Title: Contractor Conflicts of Interest. ICR numbers: EPA ICR No. 1550.09, OMB Control No... control numbers in certain EPA regulations is consolidated in 40 CFR part 9. Abstract: EPA contractors...
-
78 FR 79692 - Clean Water Act; Contractor Access to Confidential Business Information
2013-12-31
... ENVIRONMENTAL PROTECTION AGENCY [FRL-9904-94-OW] Clean Water Act; Contractor Access to... Transfer of Confidential Business Information to Contractor, Subcontractors, and Consultants. SUMMARY: The... contractors listed below require access to CBI submitted to EPA under Section 308 of the Clean Water Act (CWA...
-
Roadmapping or development of future investments in environmental science and technology
Energy Technology Data Exchange (ETDEWEB)
Wilburn, D. (Dianne)
2002-01-01
This paper will summarize efforts in roadmapping SCFA technical targets, which could be used for selection of future projects. The timely lessons learned and insights will be valuable to other programs desiring to roadmap large amounts of workscope, but unsure how to successfully complete it, by adequately defining a strategy to develop alternatives and core technologies to ensure needed environmental technologies are available and allow delivery of viable alternatives. In early FY02, Los Alamos National Laboratory's Environmental Science and Waste Technology Program Office was working jointly with Idaho National Environmental Engineering Laboratory to define and develop science and technology mini-roadmaps. We were defining and developing these mini-roadmaps to provide direction and guidance for DOE's Environmental Management's (DOE-EM) Subsurface Contaminants Focus Area (SCFA) in their development of target technologies. DOE EM's Strategic Plan for Science and Technology provides guidance for meeting science and technology needs with a view of the desired future and the long-term strategy to attain it. Program and technology mini-roadmapping were to be used to establish priorities, set program and project direction, and identify the high-priority science and technology need areas according to this document. In the past, EM science and technology needs collection is achieved through the DOE Site Technology Coordination Groups (STCG) across the complex. A future system for needs collection has not been defined. However, there is a need for gap analyses and a technical approach for the prioritization of these needs for DOE-EM to be strategic and successful in their technology research, development, demonstration, and deployments. To define the R&D projects needed to solve particular problems and select the project with the largest potential payoff will require analysis for project selection. Mini-roadmaps could be used for setting goals and
-
Coordinating complex decision support activities across distributed applications
Adler, Richard M.
1994-01-01
Knowledge-based technologies have been applied successfully to automate planning and scheduling in many problem domains. Automation of decision support can be increased further by integrating task-specific applications with supporting database systems, and by coordinating interactions between such tools to facilitate collaborative activities. Unfortunately, the technical obstacles that must be overcome to achieve this vision of transparent, cooperative problem-solving are daunting. Intelligent decision support tools are typically developed for standalone use, rely on incompatible, task-specific representational models and application programming interfaces (API's), and run on heterogeneous computing platforms. Getting such applications to interact freely calls for platform independent capabilities for distributed communication, as well as tools for mapping information across disparate representations. Symbiotics is developing a layered set of software tools (called NetWorks! for integrating and coordinating heterogeneous distributed applications. he top layer of tools consists of an extensible set of generic, programmable coordination services. Developers access these services via high-level API's to implement the desired interactions between distributed applications.
-
Energy Technology Data Exchange (ETDEWEB)
Frazier, Christopher Rawls; Durfee, Justin David; Bandlow, Alisa; Gearhart, Jared Lee; Jones, Katherine A
2016-05-01
The Contingency Contractor Optimization Tool – Prototype (CCOT-P) database is used to store input and output data for the linear program model described in [1]. The database allows queries to retrieve this data and updating and inserting new input data.
-
Coordinating distributed work : Exploring situated coordination with gaming-simulation
van Laere, J.
2003-01-01
Organizational work has become more and more distributed nowadays. Information and communication technologies (ICT) provide opportunities to improve coordination of distributed work, but in practice many organizations struggle with integrating new organizational structures, new work practices and
-
77 FR 13153 - Information Collection; NASA Contractor Financial Management Reports
2012-03-05
..., [email protected] . SUPPLEMENTARY INFORMATION: I. Abstract The NASA Contractor Financial Management... NATIONAL AERONAUTICS AND SPACE ADMINISTRATION [Notice 12-019] Information Collection; NASA Contractor Financial Management Reports AGENCY: National Aeronautics and Space Administration (NASA). ACTION...
-
Survey of subsurface geophysical exploration technologies adaptable to an airborne platform
International Nuclear Information System (INIS)
Taylor, K.A.
1992-12-01
This report has been prepared by the US Department of Energy (DOE) as part of a Research Development Demonstration Testing and Evaluation (RDDT ampersand E) project by EG ampersand G Energy Measurement's (EG ampersand G/EM) Remote Sensing Laboratory. It examines geophysical detection techniques which may be used in Environmental Restoration/Waste Management (ER/WM) surveys to locate buried waste, waste containers, potential waste migratory paths, and aquifer depths. Because of the Remote Sensing Laboratory's unique survey capabilities, only those technologies which have been adapted or are capable of being adapted to an airborne platform were studied. This survey describes several of the available subsurface survey technologies and discusses the basic capabilities of each: the target detectability, required geologic conditions, and associated survey methods. Because the airborne capabilities of these survey techniques have not been fully developed, the chapters deal mostly with the ground-based capabilities of each of the technologies, with reference made to the airborne capabilities where applicable. The information about each survey technique came from various contractors whose companies employ these specific technologies. EG ampersand G/EM cannot guarantee or verify the accuracy of the contractor information; however, the data given is an indication of the technologies that are available
-
48 CFR 307.108-70 - Telecommuting of contractor employees.
2010-10-01
... 48 Federal Acquisition Regulations System 4 2010-10-01 2010-10-01 false Telecommuting of... Telecommuting of contractor employees. (a) SOWs/PWSs shall permit offerors or contractors to specify their own... telecommuting) for any part of an SOW/PWS, after determining that the work or any portion thereof must be...
-
23 CFR 635.110 - Licensing and qualification of contractors.
2010-04-01
... licensing contractors, who may bid for, be awarded, or perform Federal-aid highway contracts, shall be... competition, to prevent submission of a bid by, or to prohibit the consideration of a bid submitted by, any...) No contractor shall be required by law, regulation, or practice to obtain a license before submission...
-
Tapping global expertise in coal technology
Energy Technology Data Exchange (ETDEWEB)
Shepard, M
1986-01-01
The basic technology of fossil-fuel-fired electricity generation has remained virtually the same for 30 years. To encourage the development of new coal technology for US utilities, EPRI has signed contracts with power equipment manufacturers from Europe, Japan and the USA. These firms will work cooperatively to demonstrate improved designs, materials and procedures in existing commercial plants and large-scale laboratory facilities. The manufacturers will focus on boilers, turbines, balance-of-plant components and retrofit applications, and will validate individual components in separate installations and develop equipment specifications. EPRI and its contractors will spend approximately 25 million dollars over the next 5 years on developing improved coal-fired plant. (6 refs.)
-
The oil industry experience. Technology cooperation and capacity building
International Nuclear Information System (INIS)
1995-01-01
Technology cooperation is defined as a process of constructive interaction with local, national and international partners to select and apply appropriate technology systems to achieve environmentally sound forms of economic development. Capacity building is the process of constructive interaction between countries and the private sector designed to develop the capability and skills to achieve environmentally sound forms of economic development through the use of modern technologies and management systems, a competent workforce and appropriate laws and regulations. Twelve case histories are presented which demonstrate the efforts of the oil industry to work in partnership with governments, contractors, suppliers and communities in technology cooperation and capacity building to achieve the goals of Agenda 21 which emerged as an action plan from the Rio Earth Summit in 1992. (UK)
-
Developing a Free-Piston Stirling Convertor for advanced radioisotope space power systems
Qiu, Songgang; Augenblick, John E.; White, Maurice A.; Peterson, Allen A.; Redinger, Darin L.; Petersen, Stephen L.
2002-01-01
The Department of Energy (DOE) has selected Free-Piston Stirling Convertors as a technology for future advanced radioisotope space power systems. In August 2000, DOE awarded competitive Phase I, Stirling Radioisotope Generator (SRG) power system integration contracts to three major aerospace contractors, resulting in SRG conceptual designs in February 2001. All three contractors based their designs on the Technology Demonstration Convertor (TDC) developed by Stirling Technology Company (STC) for DOE. The contract award to a single system integration contractor for Phases II and III of the SRG program is anticipated in late 2001. The first potential SRG mission is targeted for a Mars rover. This paper provides a description of the Flight Prototype (FP) Stirling convertor design as compared to the previous TDC design. The initial flight prototype units are already undergoing performance tuning at STC. The new design will be hermetically scaled and will provide a weight reduction from approximately 4.8 kg to approximately 3.9 kg. .
-
Technical assistance contractor occurrence reporting and processing system
International Nuclear Information System (INIS)
1996-08-01
Members of the Uranium Mill Tailings Remedial Action (UMTRA) Project Technical Assistance Contractor (TAC) are responsible to notify management of TAC occurrence reporting and processing system (ORPS) classified occurrences .An ORPS occurrence is an unexpected or unplanned event on DOE property which causes bodily harm, death, damage to government property, exposure to toxic or hazardous substances above acceptable limits to workers, the environment, or general public. Examples of potential reportable occurrences include, but not limited to, site personnel exposures to airborne contaminants, incidents which could expose the general public to high levels of radiation or other contaminants, a vehicle accident resulting in property damage or personnel injuries. Listed TAC manager/staff contacts, with the assistance of TAC ORPS Program Coordinators, will determine if the occurrence is reportable under Department of Energy (DOE) Order M 232.1-2. The reportable occurrences will be classified as emergency, unusual, or off-normal. If determined to be reportable, listed TAC manager/staff will verbally report the details of the occurrence to the DOE Duty Officer within 2 hours of initial notification, and provide a written report of the event by noon the following work day
-
Energy Technology Data Exchange (ETDEWEB)
Durfee, Justin David; Frazier, Christopher Rawls; Bandlow, Alisa
2016-05-01
The Contingency Contractor Optimization Tool - Prototype (CCOT-P) requires several third-party software packages. These are documented below for each of the CCOT-P elements: client, web server, database server, solver, web application and polling application.
-
Selection of disposal contractor by multi criteria decision making methods
Directory of Open Access Journals (Sweden)
Cenker Korkmazer
2016-08-01
Full Text Available Hazardous waste is substance that threaten people and environment in case of improper storage, disposal and transport due to its concentration, physical and chemical properties. Companies producing hazardous waste as a result of several activities mostly do not have any own disposal facilities. In addition, they do not pay attention enough to determine the right contractor as a disposal facility. On the other hand, there are various qualitative and quantitative criteria affecting the selection of the contractor and conflicting with each other. The aim of the performed study is to assist one of these companies producing hazardous waste in the selection of the best contractor that eliminates hazardous waste economic and harmless way. In the study, contractor weights in percentage is calculated by using Analytic Network Process (ANP as one of the multi-criteria decision making (MCDM methods and widely used in the literature which considers both qualitative and quantitative criteria. In the next step, by the help of the mathematical model, contractors that will be given which type of hazardous waste are identified. This integrated approach can be used as a guide for similar firms.
-
Coordinating and Negotiating Blue Nile Water Resource Development
Geressu, R. T.; Harou, J. J.
2016-12-01
Many countries are proposing new reservoirs in transboundary river basins world-wide that impact downstream regions. Failure to consider and incorporate multiple stakeholder interests in system design and decision making could contribute to regional disputes. Negotiated introduction of new assets and associated coordination strategies (e.g. cost and power sharing arrangements) could reduce conflict and help achieve consensus. In multi-stakeholders problems, parties are likely to prioritize performance targets differently and hence will often prefer different water system designs, stalling negotiations. An ideal solution is where individual and group benefits are maximized by allocating (exchanging) resources according to the relative preferences of stakeholders. Hence, a negotiation support mechanism should be able to incorporate stakeholder preference information. In this paper, we propose a three-step search & deliberate, elicit preferences, and search & negotiate approach for supporting negotiations in complex infrastructure-environmental systems. The approach seeks to find designs and coordination mechanisms that are more beneficial than non-cooperative actions. The proposed approach is applied to a stylized Blue Nile reservoir design problem in Ethiopia seeking to set reservoir capacity and operating rules. We consider cost and energy performance metrics for Ethiopia and energy and irrigation water supply in Sudan. We use example stakeholder (i.e., Ethiopian and Sudanese) priorities for demonstration purpose. The result is an agreed system design and coordination schemes (co-financing and power trade). The application results demonstrate that incorporating coordination strategies, such as energy trade, cost sharing, and financing in assessing transboundary reservoir development options could help find compromise designs that different parties can support.
-
Energy research and technology development data collection strategies. The case of Greece
International Nuclear Information System (INIS)
Doukas, Haris; Papadopoulou, Alexandra G.; Nychtis, Christos; Psarras, John; Van Beeck, Nicole
2009-01-01
The European Union (EU) from the beginning of 2007 has focused its emphasis on the development of a new policy that puts energy back at the heart of EU action. Indeed, it has very often been stated that the difficulty and complexity of achieving green energy targets in the EU will require strengthened measures to promote implementation of new energy technologies (NET), as well as measures to support the related energy Research and Technology Development (R and TD). Often forgotten is the fact, that most of all, a European-wide co-ordinated forum is needed to continuously develop and sophisticate the monitoring and methodology results, bringing together specialised statisticians, energy researchers and experts on energy socio-economics. Today a nebulous picture prevails on the existence of categorized data with regards to energy Research and Technology Development (R and TD) expenditure. In this context, aim of this paper is the presentation of energy R and TD data collection strategies, as well as the related findings for the Greek energy market. (author)
-
Coordinated Development between Urban Tourism Economy and Transport in the Pearl River Delta, China
Directory of Open Access Journals (Sweden)
Qiuxia Zheng
2016-12-01
Full Text Available By selecting the panel data from 2005 to 2014 of 9 cities in the Pearl River Delta (PRD in China, this paper respectively establishes the evaluation index system of tourism economy and transport. It also applies a synthetic evaluation model and coupling coordination model to estimate comprehensive indices of tourism economy and transport system and their coordinated relationships. The results show that: (1 during 2005–2014, the synthetic indices of tourism economy generally presented constantly upward tendency and the synthetic indices of transport represented wave-like raising trend in the PRD region; (2 during 2005–2014, the 9 cities in the PRD region gradually tended to have coordinated development between tourism economy and transport, and the central area of the PRD region developed faster than the flanks; (3 the correlations between the tourism economy and transport of the cities with abundant tourism resources, developed economy, and advanced transport facilities were more remarkable, and the coordination degrees were higher. Besides, macro-policies, mega-events, and locations also impacted on coordinated development between the tourism economy and transport in the PRD region.
-
2012-03-23
... Information Collection; Independent Contractor Registration and Identification AGENCY: Mine Safety and Health...-00040, Independent Contractor Register. OMB last approved this information collection request (ICR) on...); or 202-693-9441 (facsimile). SUPPLEMENTARY INFORMATION: I. Background Independent contractors...
-
Braunstein, Jean; Janky, James M.
This paper describes the network coordination for the Health, Education, Telecommunications (HET) system. Specifically, it discusses HET network performance as a function of a specially-developed coordination system which was designed to link terrestrial equipment to satellite operations centers. Because all procedures and equipment developed for…
-
2010-07-23
...] Information Collection; Central Contractor Registration Requirements for Prime Grant Recipients AGENCY: Office... information collection requirement regarding Central Contractor Registration Requirements for Prime Grant... for the proper performance of functions of the Central Contractor Registration Requirements for Prime...
-
Energy Technology Data Exchange (ETDEWEB)
NONE
2001-05-01
This publication covers the activities and accomplishments of eight countries that participated in a Co-ordinated Research Project (CRP) on Public Acceptance and Market Development of Irradiated Food in Asia and the Pacific, as presented at a final Research Coordination Meeting held in Bangkok, 20-25 September 1998. The CRP was implemented through research agreements with Bangladesh, China (one each for Shanghai and Beijing), the Republic of Korea, Malaysia, Pakistan, the Philippines, Sri Lanka, Thailand and Viet Nam, from 1994 to 1998. The technical work undertaken to bring food irradiation technology to the marketplace to address food security, public health and trade needs, is described. This covered the establishment of quality assurance procedures, the determination of irradiation doses for nontraditional as well as traditional foods, the conduct of techno-economic feasibility, and the identification of industry and consumer needs. In the majority of cases, R and D activities were undertaken in partnership with industry. Developments in the establishment and harmonization of regulations on food irradiation were also monitored. The participants made commendable progress in the marketing of irradiated food and in the understanding and promotion of consumer acceptance of the technology. This was demonstrated in the marketing of close to 179,000 tons of different food and related products through normal trading channels. While the volume of food irradiated varied with the capacity of irradiation plants in participating countries, the work showed that consumers would accept irradiated foods and that trade benefits would ensue from the application of the technology. Information dissemination was found to be a critical factor in public acceptance. The discussions at the final Research Co-ordination Meeting, which are also summarized in this publication, focused on key issues and recommendations to bring about the wider commercialization of food irradiation for the
-
International Nuclear Information System (INIS)
2001-05-01
This publication covers the activities and accomplishments of eight countries that participated in a Co-ordinated Research Project (CRP) on Public Acceptance and Market Development of Irradiated Food in Asia and the Pacific, as presented at a final Research Coordination Meeting held in Bangkok, 20-25 September 1998. The CRP was implemented through research agreements with Bangladesh, China (one each for Shanghai and Beijing), the Republic of Korea, Malaysia, Pakistan, the Philippines, Sri Lanka, Thailand and Viet Nam, from 1994 to 1998. The technical work undertaken to bring food irradiation technology to the marketplace to address food security, public health and trade needs, is described. This covered the establishment of quality assurance procedures, the determination of irradiation doses for nontraditional as well as traditional foods, the conduct of techno-economic feasibility, and the identification of industry and consumer needs. In the majority of cases, R and D activities were undertaken in partnership with industry. Developments in the establishment and harmonization of regulations on food irradiation were also monitored. The participants made commendable progress in the marketing of irradiated food and in the understanding and promotion of consumer acceptance of the technology. This was demonstrated in the marketing of close to 179,000 tons of different food and related products through normal trading channels. While the volume of food irradiated varied with the capacity of irradiation plants in participating countries, the work showed that consumers would accept irradiated foods and that trade benefits would ensue from the application of the technology. Information dissemination was found to be a critical factor in public acceptance. The discussions at the final Research Co-ordination Meeting, which are also summarized in this publication, focused on key issues and recommendations to bring about the wider commercialization of food irradiation for the
-
Radiation exposures for DOE and DOE contractor employees, 1989
International Nuclear Information System (INIS)
Smith, M.H.; Eschbach, P.A.; Harty, R.; Millet, W.H.; Scholes, V.A.
1992-12-01
All US Department of Energy (DOE) and DOE contractors, are required to submit occupational radiation exposure records to a central depository. In 1989, data were required to be submitted for all employees who were required to be monitored in accordance with DOE Order 5480.11 and for all visitors who had a positive exposure. The data required included the external penetrating whole-body dose equivalent, the shallow dose equivalent, and a summary of internal depositions of radioactive material above specified limits. Data regarding the exposed individuals included the individual's age, sex, and occupational category. This report is a summary of the external penetrating whole-body dose equivalents and shallow dose equivalents reported by DOE and DOE contractors for the calendar year 1989. A total of 90,882 DOE and DOE contractor employees were reported to have been monitored for whole-body ionizing radiation exposure during 1989. This represents 53.6% of all DOE and DOE contractor employees and is an increase (4.3 %) from the number of monitored employees for 1988. In addition to the employees, 12,643 visitors were monitored
-
EDRP public local inquiry, UKAEA/BNFL precognition on: Contractor accommodation
International Nuclear Information System (INIS)
Scott, W.
1986-01-01
The availability of accommodation for contractors working on the proposed EDRP at Dounreay is discussed. It is predicted that the contractors could be accommodated without the need for special arrangement and with no adverse effect on the tourist industry. (U.K.)
-
78 FR 70076 - Large Scale Networking (LSN)-Middleware and Grid Interagency Coordination (MAGIC) Team
2013-11-22
... projects. The MAGIC Team reports to the Large Scale Networking (LSN) Coordinating Group (CG). Public... Coordination (MAGIC) Team AGENCY: The Networking and Information Technology Research and Development (NITRD... MAGIC Team meetings are held on the first Wednesday of each month, 2:00-4:00 p.m., at the National...
-
International Nuclear Information System (INIS)
Bodie, J.S.; Haymour, J.
1999-01-01
The many factors that should be considered when distinguishing between an independent contractor and an employee from the perspective of tax laws were discussed. Some of the major areas where disputes regarding relationships between the employee and the independent contractor arise were reviewed with particular emphasis on some of the dangers associated with a change in characterization of these types of relationships. Ways in which to guard against these dangers were also presented. The courts have established the following four tests to determine a contractor's status: (1) the control test, (2) the economic reality test, (3) the business integration test, and (4) the ownership of tools test. The control tests looks to the degree of control that an employer/recipient of services possesses over the work that is to be performed. The economic reality test looks to whether the contractor is actually in business for himself and is risking a loss. The business integration test examines the relationship between employer and contractor in terms of how economically dependent the contractor is on the employer and whether the task the contractor carries on forms an integral part of the business of the employer. The last test examines who owns the tools used by the contractor to carry out his duties. This presentation also reviewed how employers and contractors are responsible for adhering to Revenue Canada tax laws and certain liabilities regarding income taxes, Employment Insurance (EI) premiums, Canada Pension Plan (CPP) contributions and other amounts
-
Energy Technology Data Exchange (ETDEWEB)
Bodie, J.S.; Haymour, J. [Fraser Milner, Calgary, AB (Canada)
1999-07-01
The many factors that should be considered when distinguishing between an independent contractor and an employee from the perspective of tax laws were discussed. Some of the major areas where disputes regarding relationships between the employee and the independent contractor arise were reviewed with particular emphasis on some of the dangers associated with a change in characterization of these types of relationships. Ways in which to guard against these dangers were also presented. The courts have established the following four tests to determine a contractor's status: (1) the control test, (2) the economic reality test, (3) the business integration test, and (4) the ownership of tools test. The control tests looks to the degree of control that an employer/recipient of services possesses over the work that is to be performed. The economic reality test looks to whether the contractor is actually in business for himself and is risking a loss. The business integration test examines the relationship between employer and contractor in terms of how economically dependent the contractor is on the employer and whether the task the contractor carries on forms an integral part of the business of the employer. The last test examines who owns the tools used by the contractor to carry out his duties. This presentation also reviewed how employers and contractors are responsible for adhering to Revenue Canada tax laws and certain liabilities regarding income taxes, Employment Insurance (EI) premiums, Canada Pension Plan (CPP) contributions and other amounts.
-
32 CFR 806b.6 - Systems of records operated by a contractor.
2010-07-01
... 32 National Defense 6 2010-07-01 2010-07-01 false Systems of records operated by a contractor... ADMINISTRATION PRIVACY ACT PROGRAM Overview of the Privacy Act Program § 806b.6 Systems of records operated by a contractor. Contractors who are required to operate or maintain a Privacy Act system of records by contract...
-
Wu, Zezhou; Yu, Ann T W; Shen, Liyin
2017-02-01
The abundant generation of construction and demolition (C&D) waste presents a significant challenge to the sustainable development of the construction industry in Mainland China. As the implementer of construction activities, the contractor's C&D waste management performance plays an important role in C&D waste minimization. This paper aims to investigate the determinants of the contractor's C&D waste management behavior in Mainland China. The Theory of Planned Behavior (TPB) was selected as the basis of the theoretical model. In addition, three contextual constructs (i.e., economic viability, governmental supervision, and project constraints) were introduced, formulating the initial model. Based on the initial model, eight constructs were identified and seven hypotheses were proposed. A questionnaire survey was conducted to collect data and a Structural Equation Modeling (SEM) analysis was employed to test the proposed hypotheses. Results showed that the C&D waste management intention is not a significant determinant of contractor's C&D waste management behavior. The most important determinant is economic viability, followed by governmental supervision as the second most important determinant. Nevertheless, the construct of project constraints is an insignificant determinant for contractor's adoption of C&D waste management behavior. The research findings imply that, in Mainland China, the government, at this stage, plays an important role in guiding and promoting the contractor to exhibit better C&D waste management behavior. Copyright © 2016 Elsevier Ltd. All rights reserved.
-
Integrating Contractors into the Logistics Force
National Research Council Canada - National Science Library
Terrell, Ronald G
2006-01-01
... a panacea. For a combatant commander to effectively integrate them with his military force requires an understanding of the operational environment, contractor capabilities, acceptable levels of risk...
-
Carroll, Carol W.; Fleming, Mary; Hogenson, Pete; Green, Michael J.; Rasky, Daniel J. (Technical Monitor)
1995-01-01
NASA Ames Research Center and Rockwell International are partners in a Cooperative Agreement (CA) for the development of Thermal Protection Systems (TPS) for the Reusable Launch Vehicle (RLV) Technology Program. This Cooperative Agreement is a 30 month effort focused on transferring NASA innovations to Rockwell and working as partners to advance the state-of-the-art in several TPS areas. The use of a Cooperative Agreement is a new way of doing business for NASA and Industry which eliminates the traditional customer/contractor relationship and replaces it with a NASA/Industry partnership.
-
2013-04-23
...; Information Collection; Contractor Use of Interagency Fleet Management System Vehicles AGENCY: Department of... previously approved information collection requirement concerning contractor use of interagency fleet... Collection 9000- 0032, Contractor Use of Interagency Fleet Management System Vehicles, by any of the...
-
48 CFR 252.237-7023 - Continuation of Essential Contractor Services.
2010-10-01
... provide a written plan for continuing the performance of essential contractor services identified in...; and (v) The approach for communicating expectations to contractor employees regarding their roles and... or other designated representative as expeditiously as possible and use its best efforts to cooperate...
-
78 FR 29247 - Contractor Legal Management Requirements; Acquisition Regulations; Correction
2013-05-20
... DEPARTMENT OF ENERGY 48 CFR Part 952 RIN 1990-AA37 Contractor Legal Management Requirements; Acquisition Regulations; Correction AGENCY: Department of Energy. ACTION: Final rule; correction. SUMMARY: The... (78 FR 25795). In this document, DOE revised existing regulations covering contractor legal management...
-
Security training with interactive laser-video-disk technology
International Nuclear Information System (INIS)
Wilson, D.
1988-01-01
DOE, through its contractor EG and G Energy Measurements, Inc., has developed a state-of-the-art interactive-video system for use at the Department of Energy's Central Training Academy. Called the Security Training and Evaluation Shooting System (STRESS), the computer-driven decision shooting system employs the latest is laservideo-disk technology. STRESS is designed to provide realistic and stressful training for security inspectors employed by the DOE and its contractors. The system uses wide-screen video projection, sophisticated scenario-branching technology, and customized video scenarios especially designed for the DOE. Firing a weapon that has been modified to shoot ''laser bullets,'' and wearing a special vest that detects ''hits'': the security inspector encounters adversaries on the wide screen who can shoot or be shot by the inspector in scenarios that demand fast decisions. Based on those decisions, the computer provides instantaneous branching to different scenes, giving the inspector confrontational training with the realism and variability of real life
-
Energy Technology Data Exchange (ETDEWEB)
NONE
1997-04-01
This report summarizes a meeting held on February 19, 1997, in Washington, D.C. The meeting was held primarily to exchange information among the contractors involved in the U.S. Department of Energy`s efforts to improve the safety of Soviet-designed nuclear power plants. Previous meetings have been held on December 5-6, 1995, and May 22, 1996. The meetings are sponsored by the U.S. Department of Energy and coordinated by the Pacific Northwest National Laboratory. The U.S. Department of Energy works with countries to increase the level of safety at 63 Soviet-designed nuclear reactors operating in Armenia, Bulgaria, the Czech Republic, Hungary, Lithuania, Russia, Slovakia, and Ukraine. The work is implemented largely by commercial companies and individuals who provide technologies and services to the countries with Soviet-designed nuclear power plants. Attending the meeting were 71 representatives of commercial contractors, the U.S. Department of Energy, the U.S. Department of State, national laboratories, and other federal agencies. The presentations and discussions that occurred during the exchange are summarized in this report. While this report captures the general presentation and discussion points covered at the meeting, it is not a verbatim, inclusive record. To make the report useful, information presented at the meeting has been expanded to clarify issues, respond to attendees` requests, or place discussion points in a broader programmatic context. Appendixes A through F contain the meeting agenda, list of attendees, copies of presentation visuals and handouts, the Strategy Document discussed at the meeting, and a summary of attendees` post-meeting evaluation comments. As with past information exchanges, the participants found this meeting valuable and useful. In response to the participant`s requests, a fourth information exchange will be held later in 1997.
-
International Nuclear Information System (INIS)
1997-04-01
This report summarizes a meeting held on February 19, 1997, in Washington, D.C. The meeting was held primarily to exchange information among the contractors involved in the U.S. Department of Energy's efforts to improve the safety of Soviet-designed nuclear power plants. Previous meetings have been held on December 5-6, 1995, and May 22, 1996. The meetings are sponsored by the U.S. Department of Energy and coordinated by the Pacific Northwest National Laboratory. The U.S. Department of Energy works with countries to increase the level of safety at 63 Soviet-designed nuclear reactors operating in Armenia, Bulgaria, the Czech Republic, Hungary, Lithuania, Russia, Slovakia, and Ukraine. The work is implemented largely by commercial companies and individuals who provide technologies and services to the countries with Soviet-designed nuclear power plants. Attending the meeting were 71 representatives of commercial contractors, the U.S. Department of Energy, the U.S. Department of State, national laboratories, and other federal agencies. The presentations and discussions that occurred during the exchange are summarized in this report. While this report captures the general presentation and discussion points covered at the meeting, it is not a verbatim, inclusive record. To make the report useful, information presented at the meeting has been expanded to clarify issues, respond to attendees' requests, or place discussion points in a broader programmatic context. Appendixes A through F contain the meeting agenda, list of attendees, copies of presentation visuals and handouts, the Strategy Document discussed at the meeting, and a summary of attendees' post-meeting evaluation comments. As with past information exchanges, the participants found this meeting valuable and useful. In response to the participant's requests, a fourth information exchange will be held later in 1997
-
The Inadequacy of Existing Far Provisions to Ensure Contractor Environmental Compliance
National Research Council Canada - National Science Library
MacDonald, Edward
1997-01-01
This thesis focuses on situations where the obligation is on the contractor, and examines the existing FAR provisions and clauses to explore whether they are adequate to ensure government contractor...
-
Directory of Open Access Journals (Sweden)
Qing Yang
2014-12-01
Full Text Available From a holistic view, this paper addresses a perspective of coordinated development of economy, society, and environment for regional sustainability assessment. Firstly, a comprehensive indicator system for co-evaluating the level of economic, social, and environmental subsystems is presented based on a holistic understanding of regional sustainability. Then, a coordinated development index model focusing on the level of coordination among the subsystems as well as their comprehensive development level is established. Furthermore, an empirical study of all the provinces and municipalities is conducted by collecting the panel data from 2004 to 2010. The result shows that: (1 the coordinated developments of the most developed and the most underdeveloped regions stay stable while the regions with medium development level possess more fluctuant trends during the study years; (2 regional disparities are indicated according to the grading of CDI (the coordinated development index, which are further analyzed to be related to the local economic development patterns; (3 the conditions and causes of economic, social, and environmental development in real situations under different grades of CDI are discussed through detailed case studies of typical regions, which indicate specific suggestions of sustainable development for regions in the same pattern.
-
2012-09-20
..., Grid, and cloud projects. The MAGIC Team reports to the Large Scale Networking (LSN) Coordinating Group... Coordination (MAGIC) Team AGENCY: The Networking and Information Technology Research and Development (NITRD.... Dates/Location: The MAGIC Team meetings are held on the first Wednesday of each month, 2:00-4:00pm, at...
-
Energy Technology Data Exchange (ETDEWEB)
NONE
1998-01-01
Since the beginning of the joint FAO/IAEA programme on the research and development of insect pest control methodology, emphasis has been placed on the basic and applied aspects of implementing the sterile insect technique (SIT). Special emphasis has always been directed at the assembly of technological progress into workable systems that can be implemented in developing countries. The general intention is to solve problems associated with insect pests that have an adverse impact on production of food and fibre. For several insect species SIT has proven to be a powerful method for control. This includes the New World screwworm fly (Cochliomyia hominivorox), the Mediterranean fruit fly (Ceratitis capitata), the melon fly (Bactrocera cucurbitae), the Queensland fruit fly (Bactrocera tryoni) and one tsetse fly species (Glossina austeni). Improvements of the SIT are possible, especially through the use of molecular techniques. The final report of the Co-ordinated Research Programme on ``Genetic Engineering Technology for the Improvement of the Sterile Insect Technique`` highlights the progress made towards the development of transformation systems for non-drosophilid insects and the research aimed at the identification and engineering of potential target genes or traits. Refs, figs, tabs.
-
International Nuclear Information System (INIS)
1998-01-01
Since the beginning of the joint FAO/IAEA programme on the research and development of insect pest control methodology, emphasis has been placed on the basic and applied aspects of implementing the sterile insect technique (SIT). Special emphasis has always been directed at the assembly of technological progress into workable systems that can be implemented in developing countries. The general intention is to solve problems associated with insect pests that have an adverse impact on production of food and fibre. For several insect species SIT has proven to be a powerful method for control. This includes the New World screwworm fly (Cochliomyia hominivorox), the Mediterranean fruit fly (Ceratitis capitata), the melon fly (Bactrocera cucurbitae), the Queensland fruit fly (Bactrocera tryoni) and one tsetse fly species (Glossina austeni). Improvements of the SIT are possible, especially through the use of molecular techniques. The final report of the Co-ordinated Research Programme on ''Genetic Engineering Technology for the Improvement of the Sterile Insect Technique'' highlights the progress made towards the development of transformation systems for non-drosophilid insects and the research aimed at the identification and engineering of potential target genes or traits
-
2010-11-24
... Federal Acquisition Regulation Supplement; Contractor Insurance/Pension Review (DFARS Case 2009-D025... conducting a Contractor Insurance/Pension Review from Procedures, Guidance, and Information (PGI) to the... This final rule relocates requirements for Contractor Insurance/ Pension Review to DFARS 242.7302 from...
-
2013-09-30
... 9000-AM56 Federal Acquisition Regulation; Pilot Program for Enhancement of Contractor Employee... program enhancing whistleblower protections for contractor employees. DATES: Effective: September 30, 2013... contractor employees at FAR subpart 3.9. The pilot program is mandated by section 828, entitled ``Pilot...
-
Energy Technology Data Exchange (ETDEWEB)
Holst Joergensen, B.; Muenster, M.
2010-12-15
This report was commissioned by the Danish Climate Commission in 2009 to analyse how research, development and demonstration (RD and D) on sustainable energy technologies can contribute to make Denmark independent on fossil energy by 2050. It focuses on the RD and D investments needed as well as adequate framework conditions for Danish knowledge production and diffusion within this field. First part focuses on the general aspects related to knowledge production and the challenges related to research. Energy technologies are categorized and recent attempt to optimize Danish efforts are addressed, including RD and D prioritisation, public-private partnerships and international RD and D cooperation. Part two describes the development and organisation of the Danish public RD and D activities, including benchmark with other countries. The national energy RD and D programmes and their contribution to the knowledge value chain are described as well as the coordination and alignment efforts. Part Three illustrates three national innovation systems for highly different technologies - wind, fuel cells and intelligent energy systems. Finally, six recommendations are put forward: to make a national strategic energy technology plan; to enforce the coordination and synergy between national RD and D programmes; to strengthen social science research related to the transition to a sustainable energy system; to increase public RD and D expenditure to at least 0.1% of GDP per year; to strengthen international RD and D cooperation; and to make a comprehensive analysis of the capacity and competence needs for the energy sector. (Author)
-
Directory of Open Access Journals (Sweden)
Mohammad Taghipour
2015-12-01
Full Text Available Imbalance between anticipated and actual progress in the development of urban construction projects suggests that there are many obstacles and risks which not only causes the urban management be unsustainable, but the reconstruction and development of urban space is also seriously threatened. In this study, the library research on issues related to the risk of construction projects was done, then some interviews were conducted with experts and managers informed and involved in the projects, and finally questionnaires were distributed to identify and classify the impact of the risks of the implementation of the construction projects. After analyzing the data, the results indicated that the experts listed the most significant risks as the delays in the payment of contractors' claims and statements due to the lack of handling financial instruments, the governance of relationships rather than rules in the tenders resulting from employer actions, low commitment to the quality of work provided by their subcontractors, failure to complete the detail engineering by foreign contractors on time, weaknesses in contractors' financial resources, and offering lower prices than reasonable by contractors to win the tender. All of these require special attention and other kinds of risks are important at the next level. Finally, the solutions for eliminating or reducing risks in high-risk areas have been offered to provide tranquility for contractors and employers.
-
Site contractor participation in the DOE SWEIS process at Los Alamos, New Mexico
Energy Technology Data Exchange (ETDEWEB)
Pendergrass, A.; Garvey, D.
1997-12-01
The U.S. Department of Energy (DOE) prepares site-wide environmental impact statements (SWEIS) on sites that are to remain in operation in order to provide an estimate of the cumulative environmental impacts from projected future operations at the site. DOE has relied on outside contractors rather than the site management and operating (M&O) contractors to prepare EISs, in order to preclude the potential for conflict of interest. The site M&O contractors, who know the potential for conflict of interest. The site M&O contractors, who know the site best and are most familiar with existing information, are critical support for the contractor. The University of California (UC) is the site M&O contractor for Los Alamos National Laboratory (LANL) in Los Alamos, NM. The role of LANL (UC) personnel in DOE`s preparation process for the LANL SWEIS is described. 3 refs.
-
Beyond the design fix - New industrialisation in contractor's supplier relationships
DEFF Research Database (Denmark)
Koch, Christian; Frödell, M.; Josephson, P.E.
2010-01-01
by the Erabuild program, this paper presents 3 cases of long term transformation of contractor- supplier relations as general contractors outsource and commence professionalising purchasing moving it from project purchasing into strategic purchasing. It is suggested that “new industrialisation” is a long term...
-
48 CFR 509.308-1 - Testing performed by the contractor.
2010-10-01
... 48 Federal Acquisition Regulations System 4 2010-10-01 2010-10-01 false Testing performed by the... ADMINISTRATION COMPETITION AND ACQUISITION PLANNING CONTRACTOR QUALIFICATIONS First Article Testing and Approval 509.308-1 Testing performed by the contractor. In FSS solicitations and contracts that will require...